Routine Maintenance, Construction, and Repair The NYISO or Connecting Transmission Owner may interrupt interconnection service or curtail the output of the Small Generating Facility and temporarily disconnect the Small Generating Facility from the New York State Transmission System or Distribution System when necessary for routine maintenance, construction, and repairs on the New York State Transmission System or Distribution System. The NYISO or the Connecting Transmission Owner shall provide the Interconnection Customer with five Business Days notice prior to such interruption. The NYISO and Connecting Transmission Owner shall use Reasonable Efforts to coordinate such reduction or temporary disconnection with the Interconnection Customer.
Construction and Maintenance There are on-going maintenance, renovation and construction projects taking place in and around the residences. The work typically takes place during regular business hours, but may begin earlier or extend into evenings or weekends. On-going construction or renovation projects will continue through midterm and final exam periods. The University will take measures to ensure that prudent construction practices are followed, but there may be noise, dust and temporary interruption of some services. Residents may be required to temporarily or permanently relocate to facilitate construction or renovation to their residence area. There will be no compensation or reduction to your residence fees due to disruption and/or relocation.
Operation and Maintenance of Properties The Borrower will, and will cause each of its Subsidiaries to:
(a) operate its Oil and Gas Properties and other material Properties or cause such Oil and Gas Properties and other material Properties to be operated in a careful and efficient manner in accordance with the practices of the industry and in compliance with all applicable contracts and agreements and in compliance with all Governmental Requirements, including, without limitation, applicable proration requirements and Environmental Laws, and all applicable laws, rules and regulations of every other Governmental Authority from time to time constituted to regulate the development and operation of its Oil and Gas Properties and the production and sale of Hydrocarbons and other minerals therefrom, except, in each case, where the failure to comply could not reasonably be expected to have a Material Adverse Effect.
(b) keep and maintain all Property material to the conduct of its business in good working order and condition, ordinary wear and tear excepted preserve, maintain and keep in good repair, working order and efficiency (ordinary wear and tear excepted) all of its material Oil and Gas Properties and other material Properties, including, without limitation, all material equipment, machinery and facilities.
(c) promptly pay and discharge, or make reasonable and customary efforts to cause to be paid and discharged, all delay rentals, royalties, expenses and indebtedness accruing under the leases or other agreements affecting or pertaining to its Oil and Gas Properties and will do all other things necessary to keep unimpaired their rights with respect thereto and prevent any forfeiture thereof or default thereunder.
(d) promptly perform or make reasonable and customary efforts to cause to be performed, in accordance with industry standards and in all material respects, the obligations required by each and all of the assignments, deeds, leases, sub-leases, contracts and agreements affecting its interests in its Oil and Gas Properties and other material Properties.
(e) to the extent the Borrower or one of its Subsidiaries is not the operator of any Property, the Borrower shall use reasonable efforts to cause the operator to comply with this Section 8.06.
Listing and Maintenance Requirements Compliance The Company has not in the two years preceding the date hereof received written notice from any stock exchange, market or trading facility on which the Common Stock is or has been listed or quoted to the effect that the Company is not in compliance with the listing, maintenance or other requirements of such exchange, market, trading or quotation facility. The Company has no reason to believe that it does not now or will not in the future meet any such requirements.
Maintenance of Hazard Insurance; Maintenance of Primary Insurance Policies (a) The Master Servicer shall maintain, for each Mortgage Loan, hazard insurance with extended coverage in an amount that is at least equal to the lesser of
(i) the maximum insurable value of the improvements securing the Mortgage Loan and
(ii) the greater of (y) the outstanding principal balance of the Mortgage Loan and (z) an amount such that the proceeds of the policy are sufficient to prevent the Mortgagor or the mortgagee from becoming a co-insurer. Each policy of standard hazard insurance shall contain, or have an accompanying endorsement that contains, a standard mortgagee clause. Any amounts collected under the policies (other than the amounts to be applied to the restoration or repair of the related Mortgaged Property or amounts released to the Mortgagor in accordance with the Master Servicer's normal servicing procedures) shall be deposited in the Certificate Account. Any cost incurred in maintaining any insurance shall not, for the purpose of calculating monthly distributions to the Certificateholders or remittances to the Trustee for their benefit, be added to the principal balance of the Mortgage Loan, notwithstanding that the Mortgage Loan so permits. Such costs shall be recoverable by the Master Servicer out of late payments by the related Mortgagor or out of Liquidation Proceeds to the extent permitted by Section 3.09. No earthquake or other additional insurance is to be required of any Mortgagor or maintained on property acquired in respect of a Mortgage other than pursuant to any applicable laws and regulations in force that require additional insurance. If the Mortgaged Property is located at the time of origination of the Mortgage Loan in a federally designated special flood hazard area and the area is participating in the national flood insurance program, the Master Servicer shall maintain flood insurance for the Mortgage Loan. The flood insurance shall be in an amount equal to the least of (i) the original principal balance of the related Mortgage Loan, (ii) the replacement value of the improvements that are part of the Mortgaged Property, and (iii) the maximum amount of flood insurance available for the related Mortgaged Property under the national flood insurance program. If the Master Servicer obtains and maintains a blanket policy insuring against hazard losses on all of the Mortgage Loans, it shall have satisfied its obligations in the first sentence of this Section 3.10. The policy may contain a deductible clause on terms substantially equivalent to those commercially available and maintained by comparable servicers. If the policy contains a deductible clause and a policy complying with the first sentence of this Section 3.10 has not been maintained on the related Mortgaged Property, and if a loss that would have been covered by the required policy occurs, the Master Servicer shall deposit in the Certificate Account, without any right of reimbursement, the amount not otherwise payable under the blanket policy because of the deductible clause. In connection with its activities as Master Servicer of the Mortgage Loans, the Master Servicer agrees to present, on behalf of itself, the Depositor, and the Trustee for the benefit of the Certificateholders, claims under any blanket policy.
(b) The Master Servicer shall not take any action that would result in non-coverage under any applicable Primary Insurance Policy of any loss that, but for the actions of the Master Servicer, would have been covered thereunder. The Master Servicer shall not cancel or refuse to renew any Primary Insurance Policy that is in effect at the date of the initial issuance of the Certificates and is required to be kept in force hereunder unless the replacement Primary Insurance Policy for the canceled or non-renewed policy is maintained with a Qualified Insurer. The Master Servicer need not maintain any Primary Insurance Policy if maintaining the Primary Insurance Policy is prohibited by applicable law. The Master Servicer agrees, to the extent permitted by applicable law, to effect the timely payment of the premiums on each Primary Insurance Policy, and any costs not otherwise recoverable shall be recoverable by the Master Servicer from the related liquidation proceeds. In connection with its activities as Master Servicer of the Mortgage Loans, the Master Servicer agrees to present, on behalf of itself, the Trustee and the Certificateholders, claims to the insurer under any Primary Insurance Policies and, in this regard, to take any reasonable action in accordance with the Servicing Standard necessary to permit recovery under any Primary Insurance Policies respecting defaulted Mortgage Loans. Any amounts collected by the Master Servicer under any Primary Insurance Policies shall be deposited in the Certificate Account or the Collection Account (as applicable).
Repairs and Maintenance It is the responsibility of the Tenant(s) to notify the Landlord immediately of any needed repair or unsafe condition existing around or in the Premises including but not limited to cracks in the foundation, cracks in plaster, moisture in walls and ceiling, buckling sheetrock or siding, or any leaks. If Xxxxxx(s) fails to immediately notify Landlord of visible problems, which result in damage to the unit, then Tenant(s) becomes liable for cost of resultant damage. All repairs necessary to maintain premises shall be done by or under the direction of the Landlord, at the Landlord’s expense, except those caused by negligence or acts of Tenant(s), Tenant’s agents, or invitees, which repairs shall be made at the sole cost of the Tenant(s). Such repairs shall be made to conform to the original condition of the Premises at the time the Tenant(s) took possession. Although the Landlord repairs normal wear and tear items, the adage “you broke it you pay to fix it” applies to the Tenant(s) and it applies during tenancy as well as at the end of tenancy. In addition, if a Tenant(s) calls for maintenance for which no such maintenance is needed (false call), Tenant(s) will be charged for the service call. Any repairs, including labor, material, and parts used, which are the responsibility of the Tenant(s), must be pre-approved in writing by the Landlord. Landlord shall be the sole judge as to what repairs are necessary. Landlord shall have no obligation to repair any defective condition, nor shall any defense or remedy be available to the Tenant(s), where the defective condition complained of was caused by the Tenant, Xxxxxx’s family, invitee, licensee, or other person acting under the control or direction of the Tenant(s), or where the Tenant unreasonably fails to notify the Landlord of the condition or allow the Landlord access to the Premises for purposes of the repair. Before exercising any of the remedies in accordance with the Landlord-Tenant Act, Tenant(s) must be current in rent. Tenant(s) shall be responsible for all broken glass. Tenant(s) shall not paint, re-wallpaper, or otherwise redecorate or make alterations to the Premises without the written consent of the Landlord. If written consent is given, such alterations shall be at the expense of the Tenant(s) and shall become part of the Premises and the Owner’s property upon termination of this Lease and tenancy. Tenant(s) shall not permit any act or thing deemed hazardous by Landlord due to potential risk of fire or which will increase the rate of insurance on said Premises. In case the Premises or surrounding areas shall be damaged by fire, rain, wind, or other cause beyond the control of the Landlord or the Tenant, then the Premises or surrounding areas shall be repaired within a reasonable time at the expense of the Landlord; and in case the damage is so extensive as to render the Premises unfit for human habitation, the rent shall cease until such time as the Premises will be put in repair. In case of total destruction, the rent shall be paid until the time of such destruction and from thenceforth this Lease Agreement shall cease and come to an end. In the event, the damage is caused by the act of the Tenant(s), or someone in or on the Premises by reason of Tenant’s permission or consent, there shall be no reduction of rent and Tenant(s) shall be liable for all costs of repair. Should Landlord notify Tenant(s) of intent to clean, replace carpets or paint the Premises, moving furniture and wall hangings shall be the duty and expense of the Tenant(s). Tenant(s) understands there will be no rent reductions, adjustments, or other compensation due to repairs or interruptions of service except as provided by law.
Preservation, Maintenance, and Protection of the Property Inspections. Borrower will not destroy, damage, or impair the Property, allow the Property to deteriorate, or commit waste on the Property. Whether or not Borrower is residing in the Property, Borrower must maintain the Property in order to prevent the Property from deteriorating or decreasing in value due to its condition. Unless Lender determines pursuant to Section 5 that repair or restoration is not economically feasible, Borrower will promptly repair the Property if damaged to avoid further deterioration or damage. If insurance or condemnation proceeds are paid to Lender in connection with damage to, or the taking of, the Property, Borrower will be responsible for repairing or restoring the Property only if Xxxxxx has released proceeds for such purposes. Lender may disburse proceeds for the repairs and restoration in a single payment or in a series of progress payments as the work is completed, depending on the size of the repair or restoration, the terms of the repair agreement, and whether Borrower is in Default on the Loan. Lender may make such disbursements directly to Borrower, to the person repairing or restoring the Property, or payable jointly to both. If the insurance or condemnation proceeds are not sufficient to repair or restore the Property, Borrower remains obligated to complete such repair or restoration. Lender may make reasonable entries upon and inspections of the Property. If Lender has reasonable cause, Xxxxxx may inspect the interior of the improvements on the Property. Lender will give Borrower notice at the time of or prior to such an interior inspection specifying such reasonable cause.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.
Listing and Maintenance Requirements The Common Stock is registered pursuant to Section 12(b) or 12(g) of the Exchange Act, and the Company has taken no action designed to, or which to its knowledge is likely to have the effect of, terminating the registration of the Common Stock under the Exchange Act nor has the Company received any notification that the Commission is contemplating terminating such registration. The Company has not, in the 12 months preceding the date hereof, received notice from any Trading Market on which the Common Stock is or has been listed or quoted to the effect that the Company is not in compliance with the listing or maintenance requirements of such Trading Market. The Company is, and has no reason to believe that it will not in the foreseeable future continue to be, in compliance with all such listing and maintenance requirements.
