Invoice of Final Cost Sample Clauses

Invoice of Final Cost. Within nine (9) months after completion of the construction of the EPE Interconnection Facilities, Interconnection System Upgrades on the EPE Transmission System, and the Protective Equipment on the EPE Transmission System, EPE shall provide an invoice of the final costs associated with EPE's review and approval of the EPE Interconnection Facilities and final costs of the Interconnection System Upgrades and the Protective Equipment on the EPE Transmission System and the net amount due, if any, from Generator allowing for any payments made by Generator pursuant to this Agreement. The final cost invoice shall set forth in reasonable detail the actual costs incurred by or on behalf of EPE in reviewing, approving, designing, procuring, constructing, installing and testing the EPE Interconnection Facilities, the Protective Equipment, and Interconnection System Upgrades, and shall set forth such costs in sufficient detail to enable Generator to compare the actual costs with the estimates and to ascertain deviations, if any, from the cost estimates. Generator shall reimburse EPE for the amount of such invoice within thirty (30) days after receipt of such invoice, unless such day is not a Business Day, in which case Generator shall make payment on the next Business Day. To the extent that the estimated costs for the Interconnection System Upgrades and the Protective Equipment on the EPE Transmission System already paid by Generator exceed the final, actual costs that Generator is obligated to pay hereunder for Interconnection System Upgrades and the Protective Equipment on the EPE Transmission System, EPE shall refund to Generator an amount equal to the difference within thirty (30) days of the issuance of the invoice of the final cost.
AutoNDA by SimpleDocs

Related to Invoice of Final Cost

  • Invoice Format Invoices furnished by Contractor under this Agreement must be in a form acceptable to the Controller and City, and must include a unique invoice number. Payment shall be made by City as specified in 3.3.6 or in such alternate manner as the Parties have mutually agreed upon in writing.

  • Invoice The original and duplicate invoices covering each and every shipment made against this order showing Contract number, Vendor number, and other essential particulars, must be forwarded promptly to the ordering agency concerned by the Vendor to whom the order is issued. Delays in receiving invoice and also errors and omissions on statements will be considered just cause for withholding settlement without losing discount privileges. All accounts are to be carried in the name of the agency or institution receiving the goods, and not in the name of the Division of Purchases.

  • Billing Statement The billing statement shall show the work authorization number for each work authorization included in the billing, the total amount earned to the date of submission, and the amount due and payable as of the date of the current billing statement for each work authorization. The billing statement shall indicate if the work has been completed or if the billing is for partial completion of the work. The fixed fee will be paid in proportion to the percentage of work completed per work authorizations.

  • Invoice Certification When and if requested by DXC, as a condition precedent to payment thereof, Supplier shall separately certify each invoice as follows: “We certify that contract deliverables listed hereon were produced in compliance with all applicable requirements of Sections 6, 7, and 12 of the Fair Labor Standards Act, as amended, and of regulations and orders of the U.S. Department of Labor issued under Section 14 thereof. We further certify that any and all additional contract deliverables will be produced in compliance with same.”

  • Invoice Disputes If you believe any delivered software or service does not conform to the warranties in this Agreement, you will provide us with written notice within thirty (30) days of your receipt of the applicable invoice. The written notice must contain reasonable detail of the issues you contend are in dispute so that we can confirm the issue and respond to your notice with either a justification of the invoice, an adjustment to the invoice, or a proposal addressing the issues presented in your notice. We will work with you as may be necessary to develop an action plan that outlines reasonable steps to be taken by each of us to resolve any issues presented in your notice. You may withhold payment of the amount(s) actually in dispute, and only those amounts, until we complete the action items outlined in the plan. If we are unable to complete the action items outlined in the action plan because of your failure to complete the items agreed to be done by you, then you will remit full payment of the invoice. We reserve the right to suspend delivery of all SaaS Services, including maintenance and support services, if you fail to pay an invoice not disputed as described above within fifteen (15) days of notice of our intent to do so.

  • Monthly Billing Statements The Engineer shall request reimbursement of costs incurred by submitting the original and one copy of an itemized billing statement in a form acceptable to the State. The Engineer is authorized to submit requests for reimbursement no more frequently than monthly and no later than ninety (90) days after costs are incurred.

  • Notice of Overpayment If the Contractor receives a vendor overpayment notice or a letter communicating the existence of an overpayment from DSHS, the Contractor may protest the overpayment determination by requesting an adjudicative proceeding. The Contractor’s request for an adjudicative proceeding must: a. Be received by the Office of Financial Recovery (OFR) at Post Office Box 9501, Olympia, Washington 98507-9501, within twenty-eight (28) calendar days of service of the notice; b. Be sent by certified mail (return receipt) or other manner that proves OFR received the request; c. Include a statement as to why the Contractor thinks the notice is incorrect; and d. Include a copy of the overpayment notice. Timely and complete requests will be scheduled for a formal hearing by the Office of Administrative Hearings. The Contractor may be offered a pre-hearing or alternative dispute resolution conference in an attempt to resolve the overpayment dispute prior to the hearing. Failure to provide OFR with a written request for a hearing within twenty-eight (28) days of service of a vendor overpayment notice or other overpayment letter will result in an overpayment debt against the Contractor. DSHS may charge the Contractor interest and any costs associated with the collection of this overpayment. DSHS may collect an overpayment debt through lien, foreclosure, seizure and sale of the Contractor’s real or personal property; order to withhold and deliver; or any other collection action available to DSHS to satisfy the overpayment debt.

  • Invoice Submission All invoices submitted by Contractor shall include the City Contract Number, an assigned Invoice Number, and an Invoice Date. Contractor shall be provided with a cover sheet for invoicing. This cover sheet must be filled out correctly and submitted with each invoice. Contractor shall submit the original invoice through the responsible City Project Manager at: City of Ocala Engineer’s Office, Attn: Xxxxx Xxxxxxxxxx, 0000 XX 00xx Xxxxxx, Xxxxxxxx 000, Xxxxx, Xxxxxxx 00000, E-Mail: xxxxxxxxxxx@xxxxxxx.xxx.

  • Notice of Final Withdrawal Promptly after receipt by the Paying Agent of notice that the Escrow Agent has requested a Final Withdrawal or that a Final Withdrawal will be made, the Paying Agent shall cause notice of the distribution of the Final Withdrawal to be mailed to each of the Receiptholders at its address as it appears in the Register. Such notice shall be mailed not less than 15 days prior to the Final Withdrawal Date. Such notice shall set forth: (i) the Final Withdrawal Date and the date for determining Receiptholders of record who shall be entitled to receive distributions in respect of the Final Withdrawal, (ii) the amount of the payment in respect of the Final Withdrawal for each $1,000 face amount Certificate (based on information provided by the Pass Through Trustee) and the amount thereof constituting unused Deposits (as defined in the Deposit Agreement) and interest thereon, and (iii) if the Final Withdrawal Date is the same date as a Regular Distribution Date, the total amount to be received on such date for each $1,000 face amount Certificate (based on information provided by the Pass Through Trustee). Such mailing may include any notice required to be given to Certificateholders in connection with such distribution pursuant to the Pass Through Trust Agreement.

  • Final Invoice Within six months after completion of the construction of the Connecting Transmission Owner’s Attachment Facilities and the System Upgrade Facilities and System Deliverability Upgrades, Connecting Transmission Owner shall provide an invoice of the final cost of the construction of the Connecting Transmission Owner’s Attachment Facilities and the System Upgrade Facilities and System Deliverability Upgrades, determined in accordance with Attachment S to the NYISO OATT, and shall set forth such costs in sufficient detail to enable Developer to compare the actual costs with the estimates and to ascertain deviations, if any, from the cost estimates. Connecting Transmission Owner shall refund to Developer any amount by which the actual payment by Developer for estimated costs exceeds the actual costs of construction within thirty (30) Calendar Days of the issuance of such final construction invoice.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!