Additional Responsibilities This paragraph applies to all phases of Architect's work.
(a) Architect shall be responsible for the professional quality, technical accuracy, timely completion and coordination of all of Architect's work, including that performed by Architect's consultants, and including designs, Drawings, Specifications, reports and other services, irrespective of Owner's approval or acquiescence in same. Architect shall, without additional compensation, correct or revise any errors, omissions or other deficiencies in his work.
(b) Architect shall be responsible, in accordance with applicable law, to Owner for all loss or damage to Owner caused by Architect's negligent act or omission; except that Architect hereby irrevocably waives and excuses Owner and its attorneys from compliance with any requirement to obtain a certificate of review as a condition precedent to commencement of an action, including any such requirements set forth in Section 00-00-000, C.R.S. or similar statute.
(c) Architect's professional responsibility shall comply with the standard of care applicable to the type of engineering and architectural services provided, commensurate with the size, scope and nature of the Project.
(d) Architect shall be completely responsible for the safety of Architect's employees in the execution of work under this Agreement, shall provide all necessary safety equipment for said employees, and shall hold harmless and indemnify and defend Owner from any and all claims, suits, loss or injury to Architect's employees.
(e) Architect acknowledges that, due to the nature of architectural and related professional services and the impact of same on the Project, the Owner has a substantial interest in the personnel and consultants to whom Architect assigns principal responsibility for services performed under this Agreement. Consequently, Architect represents that Architect has selected and intends to employ or assign the key personnel and consultants identified in Appendix C - "Identification of Personnel, Subcontractors and Task Responsibility", attached hereto for the Project assignments and areas of responsibility stated therein. Within 10 days of execution of this Agreement, Owner shall have the right to object in writing to employment on the Project of any such key person, consultant or assignment of principal responsibility, in which case Architect will employ alternate personnel for such function or reassign such responsibility to another to whom Owner has no reasonable objection. Thereafter, Architect shall not assign or reassign Project work to any person to whom Owner has reasonable objection. Within 5 days of execution of this Agreement, Architect shall designate in writing a Project representative who shall have complete authority to bind Architect, and to whom Owner should address communications.
(f) Promptly after execution of this Agreement and upon receipt of authorization from Owner to proceed, Architect shall submit to Owner for approval a schedule showing the order in which Architect proposes to accomplish his work, with dates on which he will commence and complete each major work item. The schedule shall provide for performance of the work in a timely manner so as to not delay Owner's time table for achievement of interim tasks and final completion of Project work, provided however, the Architect will not be responsible for delays beyond his control.
(g) Before undertaking any work which Architect considers beyond or in addition to the scope of work and services which Architect has contractually agreed to perform under the terms of this Agreement, Architect shall advise Owner in writing (i) that Architect considers the work beyond the scope of this Agreement, (ii) the reasons the Architect believes the out of scope or additional work should be performed, and (iii) a reasonable estimate of the cost of such work. Architect shall not proceed with such out of scope or additional work until authorized in writing by Owner. The compensation for such authorized work shall be negotiated, but in the event the parties fail to negotiate or are unable to agree as to compensation, then Architect shall be compensated for his direct costs and professional time at the rates set forth in Appendix B - "Fee Schedule".
Landlord’s Responsibilities (a) Landlord shall correct, repair or replace, at Landlord's sole cost and expense and not as a Project Cost, any non-compliance of the Building exterior and the Common Areas with all applicable building permits and codes in effect as of the Commencement Date, including, without limitation, the provisions of Title III of the Americans With Disabilities Act ("ADA") in effect as of the Commencement Date. Said costs of compliance shall be Landlord's sole cost and shall not be part of Project Costs. Landlord shall correct, repair or replace any non-compliance of the Building exterior and the Common Areas with any revisions or amendments to the ADA in effect after the Commencement Date, provided that the amortized cost of such repairs or replacements (amortized over the useful life thereof using a market cost of funds reasonably determined by Landlord) shall be included as Project Costs payable by Tenant. All other ADA compliance issues which pertain to the Premises, including, without limitation, in connection with Tenant's construction of any alterations or other improvements in the Premises (and any resulting ADA compliance requirements in the Common Areas), the Tenant Improvements and the operation of Tenant's business and employment practices in the Premises, shall be the responsibility of Tenant at its sole cost and expense. Landlord shall, during the initial Lease Term, correct, repair or replace, at Landlord's sole cost and expense and not as a Project Cost, any failure of the structural components of the roof, foundations, footings and load-bearing walls of the Building. The repairs, corrections or replacements required of Landlord or of Tenant under the foregoing provisions of this Section 2.4 shall be made promptly following notice of non-compliance from any applicable governmental agency.
(b) Landlord warrants to Tenant that the Shell Building Improvements as defined in the Discovery Outline Specifications (as defined in the Work Letter) and the Tenant Improvements to be completed pursuant to the Work Letter shall be free from defects in workmanship or materials for a period of twelve (12) months from the Commencement Date. Landlord shall promptly rectify any non-compliance at its sole cost and expense after receipt of written notice from Tenant within such time setting forth the nature and extent of any such non-compliance. Landlord shall obtain customary warranties and guaranties from the contractor(s) performing the Tenant Improvement work and/or the manufacturers of equipment installed but shall be under no obligation to incur additional expense in order to obtain or extend such warranties. If after expiration of the initial twelve (12) months of the Lease Term, Tenant is required to make repairs to any component of the Premises or any of its systems for which Landlord may have obtained a warranty, Landlord shall, upon request by Tenant, use its good faith efforts to pursue its rights under any such warranties for the benefit of Tenant. Landlord shall be under no obligation to incur any expense in connection with asserting rights under such warranties or guaranties against either the contractor or the manufacturer, but shall use reasonable good faith efforts to enforce such warranties and guaranties for Tenant's benefit.
(c) Notwithstanding the provisions of Section 7.2 of this Lease, Landlord agrees to maintain and repair, at its sole cost and expense and not as an Operating Expense the structural components of the roof and Building, including floor/ceiling slabs, columns, beams, walls and the foundations and footings of the Building during the initial Lease Term. If a non-compliance with the foregoing warranty exists, Landlord shall, promptly after receipt of the written notice from Tenant setting forth the nature and extent of such non-compliance, rectify same at Landlord's sole cost and expense.
Tenant’s Responsibilities Except as expressly provided in Paragraph 10.1 above, Tenant shall, at its sole cost, maintain the entire Premises and every part thereof, including without limitation, windows, skylights, window frames, plate glass, freight docks, doors and related hardware, interior walls and partitions, and the electrical, plumbing, lighting, heating and air conditioning systems in good order, condition and repair. Tenant shall deliver to Landlord, every six (6) months during the Lease Term, a certificate of maintenance or its equivalent, signed by a licensed HVAC repair and maintenance contractor and stating that the heating and air conditioning systems servicing the Premises have been inspected, serviced and are in good order, condition and repair. Tenant's failure to deliver said certificate or its equivalent within thirty (30) days following written notice from Landlord that said certificate is past due shall be a Default by Tenant. If Tenant fails to make repairs or perform maintenance work required of Tenant hereunder within fifteen (15) days after notice from Landlord specifying the need for such repairs or maintenance work, Landlord or Landlord's agents may, in addition to all other rights and remedies available hereunder or by law and without waiving any alternative remedies, enter into the Premises and make such repairs and/or perform such maintenance work. If Landlord makes such repairs and/or performs such maintenance work, Tenant shall reimburse Landlord upon demand and as Additional Rent, for the cost of such repairs and/or maintenance work. Landlord shall have no liability to Tenant for any damage, inconvenience or interference with the use of the Premises by Tenant or Tenant's agents as a result of Landlord performing any such repairs or maintenance (unless such damage, inconvenience or interference is caused by the gross negligence or willful misconduct of Landlord or its agents, employees or contractors); provided, however, under no circumstances shall Landlord be liable to Tenant for claims of lost profits, loss of business or lost income. Tenant shall reimburse Landlord, on demand and as Additional Rent, for the cost of damage to the Premises and/or Common Area caused by Tenant or Tenant's agents, employees or contractors. Tenant expressly waives the benefits of any statute now or hereafter in effect (including without limitation the provisions of subsection 1 of Section 1932, Section 1941 and Section 1942 of the California Civil Code and any similar law, statute or ordinance now or hereafter in effect) which would otherwise afford Tenant the right to make repairs at Landlord's expense (or to deduct the cost of such repairs from Rentals due hereunder) or to terminate this Lease because of Landlord's failure to keep the Premises in good and sanitary order.
Contractor’s General Responsibilities The Contractor, regardless of any delegation or subcontract entered by the Contractor, shall be responsible for the following when providing information technology staff augmentation services:
3.1 The Contractor is responsible for the comprehensive management of Staff. Staff shall not be deemed an employee of the State or deemed to be entitled to any benefits associated with such employment and the Contractor shall be responsible for the administration and maintenance of all employment and payroll records, payroll processing, remittance of payroll and taxes, and all administrative tasks required by state and federal law associated with payment of Staff.
3.2 The Contractor shall provide Staff in accordance with Customer Requests for Quote (RFQ), and as described in Contract Exhibit J, Job Family Descriptions document. Customers may include detailed scopes of work, specific requirements of the work to be performed, and any requirements of Staff within the Request for Quote.
3.3 The Contractor shall possess the professional and technical staff necessary to allocate, outsource, and manage qualified Staff to perform the services requested by the Customer.
3.4 The Contractor shall provide Customers with Staff who have sufficient skill and experience to perform the services assigned to them.
3.5 The Contractor is responsible for ensuring that all information technology staff augmentation services furnished under the Contract meet the professional standards and quality that prevails among information technology professionals in the same discipline and of similar knowledge and skill engaged in related work throughout Florida under the same or similar circumstances.
3.6 The Contractor shall provide, at its own expense, training necessary for keeping Contractor’s Staff abreast of industry advances and for maintaining proficiency in equipment and systems that are available on the commercial market.
3.7 The Contractor shall, at its own expense, be responsible for adhering to the Contract background screening requirements, testing, evaluations, advertising, recruitment, and disciplinary actions of Contractor’s Staff.
3.8 The Contractor, throughout the term of the Contract, shall maintain all licenses, permits, qualifications, insurance, and approvals of whatever nature that are legally required for Contractor and Staff to perform the information technology staff augmentation services.
3.9 Contractor shall be responsible for all costs associated with the administration of this Contract.
3.10 The Contractor shall adhere to all work policies, procedures, and standards established by the Department and Customer.
3.11 The Contractor shall ensure that Staff conform with the Customer’s policies in all respects while on the Customer’s premises, and is responsible for obtaining all rules, regulations, policies, etc.
3.12 Contractor shall only provide information technology staff augmentation services for those Job Titles awarded to the Contractor and shall be paid on an hourly basis. Contracts resulting from this solicitation should not be structured as fixed-price agreements or used for any services requiring authorization for payment of milestone tasks.
Tenant Responsibilities Tenant will keep the Leased Premises and the fixtures and equipment therein in good order and condition, will take good care thereof and will suffer no waste or damage thereto. Tenant will promptly repair at its own expense any damage to the Leased Premises caused by bringing into the premises any property for Tenant's use or by the installation or removal of such property, regardless of fault or by who such damage shall be caused, unless caused by Landlord, its agents, employees or contractors; and, in default of such repairs by Tenant, Landlord shall make the same and Tenant agrees to pay the costs thereof to Landlord promptly upon Landlord's demand therefor. At the expiration or other termination of the Lease Term, Tenant will surrender the Leased Premises broom clean and in the same order and condition in which they were on the Rent Commencement Date, ordinary wear and tear excepted. All repairs and maintenance required to be performed by Tenant shall be made or performed immediately upon the occurrence of the necessity therefor, and shall be made or performed in a first class manner, using first class materials, by a contractor approved by Landlord and bonded unless waived by Landlord, and shall be made or performed in accordance with (i) all laws and all applicable governmental codes and requirements, and (ii) insurance requirements. Maintenance and repair of equipment such as kitchen fixtures, auxiliary air-conditioning equipment, private bathroom fixtures and any other type of special equipment, together with related plumbing or electrical services, whether installed by Tenant or by Landlord on behalf of Tenant, shall be the sole responsibility of Tenant, and Landlord shall have no obligation in connection therewith. If Tenant refuses or neglects to promptly commence and complete repairs or maintenance necessary to satisfy the provisions of this Section, the Landlord may, but shall not be required to, make and complete said repairs or maintenance and Tenant shall pay the cost therefor (including overhead) to Landlord upon demand, as Additional Rent.
Landlord’s Responsibility During the term of this Lease, Landlord shall maintain in good condition and repair, and replace as necessary, the roof, exterior walls, foundation and structural frame of the Building and the parking and landscaped areas, the costs of which shall be included in Operating Expenses; provided, however, that to the extent any of the foregoing items require repair because of the negligence, misuse, or default of Tenant, its employees, agents, customers or invitees, Landlord shall make such repairs solely at Tenant's expense.
Tenant’s Responsibility (a) Except to the extent contributed to by a Landlord Party and except for those matters listed in Section 9.5(a) for which the Landlord shall be responsible, the Tenant shall be solely responsible and liable for any work required by any governmental authority having jurisdiction with respect to any Contaminants on, in or under the Premises during the Term of the Lease. Except (i) as caused by or contributed to by a Landlord Party, and (ii) for those matters listed in Section 9.5(a), the Tenant shall indemnify, defend (utilizing counsel satisfactory to the Landlord) and hold harmless the Landlord and the Landlord’s respective officers, directors, beneficiaries, shareholders, partners, agents and employees from all Claims arising out of or in any way connected with any Release of any Contaminants that occurs during the Term of this Lease, at, in, on, from, under, or about the Premises or the Building, or which arises at any time from the Tenant’s use or occupancy of the Premises, or from the Tenant’s failure to provide all information, make all submissions, and take steps required by all authorities under Environmental Law.
(b) Upon the occurrence of any material Release of a Contaminant at the Premises and upon the Tenant becoming aware of such Release, the Tenant shall immediately give written notice to the Landlord. In any event, the Tenant shall immediately take all steps required by Environmental Law to remedy or otherwise address the situation giving rise to any Release.
(c) If any work is required in accordance with this section 9.2 the Tenant shall prepare all necessary studies, plans and proposals and submit them to the Landlord for approval, which approved shall not be unreasonably withheld, provide all bonds and other security required by any lawful governmental authorities and carry out the work required. In carrying out such work, the Tenant shall keep the Landlord fully informed of the progress of the work. If the Landlord has reasonable grounds for believing that the Tenant will not promptly or properly carry out such work, the Landlord may, in its sole discretion, elect to carry out all such work, or any part of it, and if the Landlord does so, the Tenant shall pay for all costs in connection therewith, within thirty (30) days after the Landlord has incurred the costs and made written demand to the Tenant.
(d) The Tenant covenants, acknowledges and agrees that its obligations and liabilities under this Section shall survive the expiration or earlier termination of this Lease.
Tenant Responsibility Good housekeeping is expected of everyone. Tenant agrees to keep quarters clean and in a sanitary condition. The Tenants agree not to permit any deterioration or destruction to occur while they are occupying the property.
Custodial Responsibilities (a) Each Custodian shall provide access to the Mortgage Loan Documents in possession of the applicable Custodian regarding the related Mortgage Loans and REO Property and the servicing thereof to the Trustee, the Certificateholders, the FDIC, and the supervisory agents and examiners of the FDIC, such access being afforded only upon reasonable prior written request and during normal business hours at the office of the applicable Custodian. Each Custodian shall allow representatives of the above entities to photocopy any of the records and documentation and shall provide equipment for that purpose at the expense of the person requesting such access.
(b) Each Custodian may resign from its obligations hereunder upon 60 days' prior written notice to the Trustee, the Depositor, the Securities Administrator and the Servicers. Such resignation shall take effect upon (i) the appointment of a successor Custodian reasonably acceptable to the Depositor within such 60 day period; and (ii) delivery of all Mortgage Loan Files to the successor Custodian. The Trustee shall have the right, but not the obligation, to become the successor Custodian. If no successor Custodian is appointed within 60 days after written notice of such Custxxxxx'x xesignation is received by the Trustee, the applicable Custxxxxx xxx petition a court of competent jurisdiction to appoint a successor Custodian. Upon such resignation and appointment of succesxxx Xxxxxdian, the applicable Custodian shall, at such Custodian's expense, xxxxxxxx transfer to the successor Custodian, as directed in writing by the Trustee, all applicable Mortgage Files being administered under this Agreement. Notwithstanding the foregoing, the Trust Fund, not the applicable Custodian, shall bear the costs relating to the transfer of Mortgage Files if such Custodian shall resign with cause (including such Custodian's resignation due to the failure of such Custodian to be paid xxx xxxx due to such Custodian hereunder).
(c) For so long as reports are required to be filed with the Commission under the Exchange Act with respect to the Trust, each Custodian shall not utilize any Subcontractor for the performance of its duties hereunder if such Subcontractor would be "participating in the servicing function" within the meaning of Item 1122 of Regulation AB without the prior written consent of the Depositor, in its sole discretion.
(d) Each Custodian shall indemnify the Depositor, the Sponsor, the Securities Administrator and any director, officer, employee, agent and affiliate of the Depositor, the Sponsor or the Securities Administrator and hold them harmless against any and all claims, losses, damages, penalties, fines, forfeitures, reasonable and necessary legal fees and related costs, judgments, and any other costs, fees and expenses that any of them may sustain in any way related to (i) the failure of the applicable Custodian to deliver when required any assessment of compliance required to be delivered by the applicable Custodian or (ii) any material misstatement or omission contained in any assessment of compliance provided to be delivered by the applicable Custodian. This indemnity shall survive the termination of this Agreement or the earlier resignation or removal of the applicable Custodian.
(e) Notwithstanding anything in this Agreement to the contrary, no Custodian shall be required to deliver, or to cause to be delivered, an assessment of compliance or accountant's attestation report pursuant to Section 3.23 for any fiscal year of the Trust in which the Custodian's Weighted Average Percentage is 5% or less. The "Custodian's Weighted Average Percentage" means, for each fiscal year of the Trust and each Custodian, the quotient, expressed as a percentage, of (A) the aggregate of the Stated Principal Balance for each Distribution Date in such fiscal year of the Mortgage Loans for which such Custodian acted as Custodian divided by (B) the aggregate of the Pool Stated Principal Balance for each Distribution Date in such fiscal year.
Professional Responsibilities Other activities to support the delivery of the Xxxxxx Xxxxxx Business Plan and Xxxxxx Mission Strategic Plan, as requested by your manager • As an employee, be responsible under the Work Health & Safety Act for the health and safety of all persons they come into contact with, during employment • All hazards and injuries must be reported through the normal process as set out in Xxxxxx Mission’s Work Health, Safety and Rehabilitation Quality Management System and site procedures • Participate in the review and maintenance of industry specific and internal audit processes, as per Xxxxxx Mission’s standard policy and procedures • In relation to Xxxxxx Mission and the Uniting Church in Australia, attend such functions, meetings, seminars, training courses as directed by your supervisor • In relation to Xxxxxx Mission attend worship services as encouraged by your supervisor • Participate on a quarterly basis in Xxxxxx Mission’s Employee contribution and development process • Take responsibility for personal career development and training • Participate in Xxxxxx Mission’s Orientation program, so as to gain an understanding of, and • promote, the application of the EEO, Affirmative Action, Privacy Act, Work Health & Safety Act and other relevant legislation • Administer Xxxxxx Mission’s philosophy of care and other relevant policy documents as appropriate • Demonstrate responsible stewardship of all resources, and willingness to report impropriety in keeping with the values of Xxxxxx Mission • Ensure the reputation and integrity of Xxxxxx Mission is maintained at all times • Maintain confidentiality
