Landlord Delivery of Premises Sample Clauses

Landlord Delivery of Premises. On the Effective Date (the “Delivery Date”) Landlord shall deliver the Premises to Tenant in its as-is condition. Provided, however, as of the Delivery Date all structural elements of the Building and base Building systems shall be in compliance with all applicable Governmental Requests in all material respects. No later than the Commencement Date, Landlord shall, at its sole cost and expense, complete construction of a multi-tenant corridor on the second (2nd) floor of the Building to demise the Premises from the remainder of the second floor. Such corridor shall be constructed in compliance with all Governmental Requirements and pursuant to plans prepared by Tenant and approved by Landlord, such approval not to be unreasonably withheld. In the event that Tenant is unable to obtain a building permit for the construction of the Premises or certificate of occupancy for the completed Premises solely due to the Building failing to comply with Governmental Requirements or Landlord’s failure to perform any of its obligations under this Lease, then, Landlord shall immediately correct such failure at its sole cost and expense and any actual delay caused to Tenant’s completion of the Tenant Improvements solely as a result of such failure (taking into account any Tenant interference or delay) shall extend the Commencement Date by the number of days of such actual delay. Taking of possession by Tenant shall establish that the Premises are in good and satisfactory condition on the Delivery Date and any alleged defects or deficiencies are waived by the Tenant except to the extent Landlord is required to correct the same pursuant to the express terms of the Lease. Landlord shall not be subject to any liability to Tenant for, and the validity of this Lease and Tenant’s obligations hereunder shall not be affected by, any failure of Landlord to give access to the Premises to Tenant on or by any particular date provided that the Commencement Date shall be extended for each day beyond the Effective Date on which Landlord fails to deliver possession of the Premises as set forth herein. Tenant acknowledges that no representations as to the condition of the Premises or Building have been made by Landlord, unless such are expressly set forth in this Lease.
Sample 1
AutoNDA by SimpleDocs

Related to Landlord Delivery of Premises

  • Delivery of Premises If the Landlord shall be unable to give possession of the Premises, exclusively the Suite 200 Premises and the Suite 246 Premises, on the Fourth Expansion Premises Commencement Date by reason of (i) the Landlord work is not substantially complete, (ii) the holding over or retention of possession of any tenant, tenants or occupants, or (iii) for any other reason, then Landlord shall not be subject to any liability for the failure to give possession on said date. Under such circumstances the Base Rent to be paid herein shall not commence until the Premises (exclusively the Suite 200 Premises and the Suite 246 Premises) are made available to Tenant by Landlord, and no such failure to give possession on the Fourth Expansion Premises Commencement Date shall affect the validity of this Sixth Amendment to Office Building Lease or the obligations of the Tenant hereunder. The Base Rents due hereunder will be adjusted at the time that any or all of the Fourth Expansion Premises are delivered to Tenant substantially complete to reflect the same underlying effective rent of the rent structure specific to each suite with the lease expiration dates to remain unchanged. Notwithstanding the foregoing, if the Fourth Expansion Premises Commencement Date for the Suite 200 Premises together with the Suite 246 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the Sixth Amendment to Office Building Lease without any liability to the Landlord. Separately, if the Fourth Expansion Premises Commencement Date-Suite 240 Premises has not occurred within ninety (90) days after the Fourth Expansion Premises Commencement Date-Suite 240 Premises, the Tenant, by written notice to the Landlord given within ten (10) days after the expiration of such ninety (90) day period, may terminate the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease for the Suite 240 Premises not delivered in said time frame without any liability to the Landlord. If Landlord’s failure to complete Tenant’s improvements within ninety (90) days after the Fourth Expansion Premises Commencement Date and/or Fourth Expansion Premises Commencement Date-Suite 240 Premises is result of Tenant Delay, Tenant shall not have the option to terminate the Sixth Amendment to Office Building Lease or the terms of lease for the Suite 240 Premises in the Sixth Amendment to Office Building Lease.

  • Expansion of Premises Provided that the demising wall is erected in the location specified on Exhibit A attached hereto, for purposes of calculating Fixed Monthly Rent and Tenant’s Share the parties hereby stipulate that the Expansion Premises contains approximately 9,271 square feet of Rentable Area and approximately 7,836 square feet of Usable Area. As of the Expansion Date, the definition of the Premises shall be revised to include both the Existing Premises and the Expansion Space, and wherever in the Lease the word “Premises” is found, it shall thereafter refer to both the Existing Premises and the Expansion Space together, as if the same had been originally included in said Lease, subject to the terms and conditions of this First Amendment. Landlord and Tenant agree that a recalculation of the Usable Area of the Expansion Space shall be made after the Expansion Date by Xxxxxxxxx Systems, Inc., an independent planning firm, using the 2010 ANSI/BOMA Standard set forth collectively by the American National Standards Institute and the Building Owners and Managers Association (“ANSI/BOMA Standard”), as a guideline, and that Landlord is utilizing a deemed add-on factor of 18.31% to compute the Rentable Area of the Expansion Space. Tenant and Landlord agree to document the revised Usable Area as documented by Xxxxxxxxx Systems, and the other matters specified below that will be determined upon such Usable Area being confirmed, in the Memorandum (as defined in Section 4 below). Landlord and Tenant further agree that the Rentable Area of the Expansion Space shall be calculated on the basis of 1.1831 times the estimated Usable Area, regardless of what actual common areas of the Building may be, or whether they may be more or less than 18.31% of the total estimated Usable Area of the Building, and is provided solely to give a general basis for comparison and pricing of this space in relation to other spaces in the market area. Landlord and Tenant further agree that once the Rentable Area and Usable Area of the Expansion Space have been determined as specified hereinabove, even if later either party alleges that the actual Rentable Area or Usable Area of the Expansion Space is more or less than the figures stated herein; and whether or not such figures are inaccurate, for all purposes of the Lease, the Rentable and Usable figures agreed upon shall be conclusively deemed to be the Rentable Area, or Usable Area of the Expansion Space, as the case may be. Notwithstanding any adjustment in the Usable Area and/or Rentable Area as determined pursuant to this Section 4, and provided the demising wall is erected in the location indicated on Exhibit A attached hereto and the Expansion Space plan as depicted on Exhibit A is not modified after this First Amendment is executed, there shall be no change in the Fixed Monthly Rent due for the Expansion Space as set forth in Section 5.2, below or in Tenant’s Share as set forth in Section 6, below. As of the Expansion Date, the total Usable Area of the Premises shall be 27,983 square feet and the total Rentable Area of the Premises shall be 31,338 square feet, subject to confirmation of the Usable Area and Rentable Area as provided above. [***] = CONFIDENTIAL INFORMATION HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION. CONFIDENTIAL TREATMENT HAS BEEN REQUESTED WITH RESPECT TO THIS OMITTED INFORMATION. If the demising wall is erected in a location different from that as indicated on Exhibit A attached hereto, or if the Expansion Space plan as depicted on Exhibit A is otherwise modified after this First Amendment is executed, and if as a result the Rentable Area of the Expansion Space is increased or decreased pursuant to this Section 4 then (a) the Fixed Monthly Rent commencing on the first calendar day of the thirteenth (13th) calendar month after the Expansion Date shall be recalculated based on $2.13 per square foot of Rentable Area of the Expansion Space, per month; (b) thereafter, the Fixed Monthly Rent shall be adjusted to result in an increase of three percent (3%) per annum, cumulative over the Expansion Term; (c) as of the Expansion Date, Security Deposit for the Expansion Space shall be adjusted to an amount equal to one month’s Fixed Monthly Rent for the Expansion Space due during the last year of the Term; (d) as of the Expansion Date, if the Usable Area of the Expansion Space is increased or decreased pursuant to this Section 4, then “Tenant’s Share” as set forth herein for the Expansion Space shall be increased or decreased equally, by dividing the newly calculated Usable Area of the Expansion Space by the Usable Area of the Building; (e) the Allowance shall equal $32.50 per square foot of Rentable Area within Expansion Space; and (f) all other amounts based on the Usable Area of the Expansion Space or Rentable Area of the Expansion Space shall be adjusted appropriately. Landlord and Tenant shall promptly execute a memorandum (the “Memorandum”) confirming the finalized Delivery Date, Expansion Date, the Fixed Monthly Rent escalation dates as described in Section 5.b. below, and the other matters specified above as soon as they are determined. Tenant shall execute the Memorandum and return it to Landlord within fifteen (15) business days after receipt thereof. Failure of Tenant to timely execute and deliver the Memorandum shall constitute an acknowledgement by Tenant that the statements included in such Memorandum are true and correct.

  • Lease of Premises Landlord hereby leases to Tenant and Tenant hereby leases from Landlord the Premises for the Term and upon the terms, covenants and conditions provided in this Lease.

  • Delivery of the Premises When Landlord’s Work is Substantially Complete, subject to the remaining terms and provisions of this Section 3(e), Tenant shall accept the Premises. Tenant’s taking possession and acceptance of the Premises shall not constitute a waiver of: (i) any warranty with respect to workmanship (including installation of equipment) or material (exclusive of equipment provided directly by manufacturers), (ii) any non-compliance of Landlord’s Work with applicable Legal Requirements, or (iii) any claim that Landlord’s Work was not completed substantially in accordance with the TI Construction Drawings (subject to Minor Variations and such other changes as are permitted hereunder) (collectively, a “Construction Defect”). Tenant shall have one year after Substantial Completion within which to notify Landlord of any such Construction Defect discovered by Tenant, and Landlord shall use reasonable efforts to remedy or cause the responsible contractor to remedy any such Construction Defect within 30 days thereafter. Notwithstanding the foregoing, Landlord shall not be in default under the Lease if the applicable contractor, despite Landlord’s reasonable efforts, fails to remedy such Construction Defect within such 30-day period, in which case Landlord shall have no further obligation with respect to such Construction Defect other than to cooperate, at no cost to Landlord, with Tenant should Tenant elect to pursue a claim against such contractor. Tenant shall be entitled to receive the benefit of all construction warranties and manufacturer’s equipment warranties relating to equipment installed in the Premises. If requested by Tenant, Landlord shall attempt to obtain extended warranties from manufacturers and suppliers of such equipment, but the cost of any such extended warranties shall be borne solely out of the TI Fund. Landlord shall promptly undertake and complete, or cause to be completed, all punch list items.

  • Landlord’s Option to Repair Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, in which event this Lease shall terminate, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice will include a termination date giving Tenant sixty (60) days to vacate the Premises, but this Lease may be so terminated Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies or that portion of the proceeds from Landlord’s insurance policies allocable to the Building or the Project, as the case may be; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; (v) the damage occurs during the last twelve (12) months of the Lease Term; or (vi) any owner of any other portion of the Project, other than Landlord, does not intend to repair the damage to such portion of the Project; provided, however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or Common Areas necessary to Tenant’s occupancy and as a result of such damage the Premises are unfit for occupancy, and provided that Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and either (a) the repairs cannot, in the reasonable opinion of Landlord’s contractor, be completed within two hundred seventy (270) days after being commenced, or (b) the damage occurs during the last twelve months of the Lease Term and will reasonably require in excess of ninety (90) days to repair, Tenant may elect, no earlier than sixty (60) days after the date of the damage and not later than ninety (90) days after the date of such damage, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Tenant.

  • Inspection of Premises At all reasonable times Agent and each Lender shall have full access to and the right to audit, check, inspect and make abstracts and copies from each Borrower’s books, records, audits, correspondence and all other papers relating to the Collateral and the operation of each Borrower’s business. Agent, any Lender and their agents may enter upon any premises of any Borrower at any time during business hours and at any other reasonable time, and from time to time, for the purpose of inspecting the Collateral and any and all records pertaining thereto and the operation of such Borrower’s business.

  • Sale of Premises by Landlord In the event of any sale of the Building, Landlord shall be and is hereby entirely freed and relieved of all liability under any and all of its covenants and obligations contained in or derived from this Lease arising out of any act, occurrence or omission occurring after the consummation of such sale; and the purchaser, at such sale or any subsequent sale of the Premises shall be deemed, without any further agreement between the parties or their successors in interest or between the parties and any such purchaser, to have assumed and agreed to carry out any and all of the covenants and obligations of the Landlord under this Lease.

  • CONSTRUCTION OF PREMISES Landlord will diligently perform “Landlord’s Work” and Tenant will diligently perform “Tenant’s Work” (if any) as described in the Workletter attached as Exhibit “F” in accordance with the Workletter and the rest of this Lease. Landlord’s Work will be deemed substantially completed even if Landlord has not completed “punch list” or other minor items, as long as (i) Landlord agrees to use reasonable efforts to complete these items within thirty (30) days of signing the punch-list, excluding any items which require special materials or equipment that are unavailable; and (ii) the punch-list items can be completed after Tenant’s occupancy without causing substantial interference with Tenant’s use of the Premises. Tenant’s final punch list will be submitted to Landlord with in fifteen (15) days after Landlord notifies Tenant that Landlord’s Work is substantially completed. Substantial completion of Landlord’s Work will be deemed to have occurred on the earlier of: the date as of which Landlord’s architect certifies in good faith that Landlord’s Work has been substantially completed in substantial conformance with the plans and specifications therefore (or the date as of which such substantial completion would have occurred but for any delays or Tenant’s Work for which Tenant is responsible); or the date that the applicable governmental authorities issue a temporary or final certificate of occupancy for the Premises (or the date as of which such a certificate of occupancy reasonable could have been issued but for any delays or Tenant’s Work for which Tenant is responsible). If and as long as Tenant does not interfere in any way with the construction process (by causing disharmony, scheduling or coordinating difficulties, etc.) Tenant, may, at Tenant’s sole risk and expense, enter the Premises 30 days prior to the substantial completion of Landlord’s Work (“Early Access Period”) for the purposes of installing Tenant’s decorations, movable furniture and business fixtures. The determination of such interference by Landlord shall be conclusive. The Early Access Period shall commence upon Tenant’s receipt of Landlord’s notice of same. For the time period commencing on the date that Landlord’s Work is substantially complete and ending on the date that is ten days after such substantial completion (the “Fixture Period”), Tenant shall have the right to access the Premises for the purposes of installing its furniture, fixtures, audio/visual, security, and other equipment Any access by Tenant prior to the Lease Commencement Date shall be subject to all the terms and conditions of this Lease, except that Tenant shall not be obligated to pay rent during the Fixture Period.

  • Acceptance of Premises Lessee hereby acknowledges: (a) that it has been advised by the Broker(s) to satisfy itself with respect to the condition of the Premises (including but not limited to the electrical and fire sprinkler systems, security, environmental aspects, seismic and earthquake requirements, and compliance with the Americans with Disabilities Act and applicable zoning, municipal, county, state and federal laws, ordinances and regulations and any covenants or restrictions of record (collectively, "Applicable Laws") and the present and future suitability of the Premises for Lessee's intended use; (b) that Lessee has made such investigation as it deems necessary with reference to such matters, is satisfied with reference thereto, and assumes all responsibility therefore as the same relate to Lessee's occupancy of the Premises and/or the terms of this Lease; and (c) that neither Lessor, nor any of Lessor's agents, has made any oral or written representations or warranties with respect to said matters other than as set forth in this Lease.

  • Landlord Repairs Notwithstanding anything contrary herein, Landlord shall repair, replace and restore the foundation, exterior and interior load-bearing walls, roof structure and roof covering and tuckpointing of the Property; provided, however, that (i) all costs and expenses so incurred by Landlord to repair, replace and restore the above items shall constitute Operating Expenses; provided, however, that with respect to any costs incurred in the replacement context, those costs shall not constitute an Operating Expense except to the extent that such costs so qualify under SECTION 3.1.1(vii); and (ii) notwithstanding (i) above, in the event that any such repair, replacement or restoration is necessitated by any or all of the matters set forth in SECTIONS 13.1(a) through (d) above (collectively, "TENANT NECESSITATED REPAIRS"), then Tenant shall be required to reimburse Landlord for all costs and expenses that Landlord incurs in order to perform such Tenant Necessitated Repairs, and such reimbursement shall be paid, in full, within 10 days after Landlord's delivery of demand therefor. Landlord agrees to commence the repairs, replacements or restoration described in this SECTION 13.2 within a reasonable period of time after receiving from Tenant written notice of the need for such repairs.

Time is Money Join Law Insider Premium to draft better contracts faster.