Rent Abatement Except for the negligence or willful act of Tenant or its agents, employees, contractors or invitees, if all or any part of the Premises are rendered untenantable by fire or other casualty and this Lease is not terminated, Monthly Base Rent and Rent Adjustments shall xxxxx for that part of the Premises which is untenantable on a per diem basis from the date of the casualty until Landlord has Substantially Completed the repair and restoration work in the Premises which it is required to perform, provided, that as a result of such casualty, Tenant does not occupy the portion of the Premises which is untenantable during such period.
Base Rent Lessee shall pay Base Rent and other rent or charges, as the same may be adjusted from time to time, to Lessor in lawful money of the United States, without offset or deduction, on or before the day on which it is due under the terms of this Lease. Base Rent and all other rent and charges for any period during the term hereof which is for less than one full month shall be prorated based upon the actual number of days of the month involved. Payment of Base Rent and other charges shall be made to Lessor at its address stated herein or to such other persons or at such other addresses as Lessor may from time to time designate in writing to Lessee.
Minimum Monthly Rent (Section 1.5): Tenant shall pay to Landlord Minimum Monthly Rent for the Premises during the Extended Term in accordance with the schedule and in the amount set forth below: 01/01/13-07/31/13 $ 1,776.25 per month $ 8,645.00 per month $ 10,421.25 per month 08/01/13-07/31/14 $ 1,827.00 per month $ 8,892.00 per month $ 10,719.00 per month 08/01/14-07/31/15 $ 1,877.75 per month $ 9,139.00 per month $ 11,016.75 per month
No Rent Abatement Tenant shall continue to pay all Rent due or accruing under this Lease during any Clean-up, and shall not be entitled to any reduction, offset or deferral of any Base Rent or Additional Rent due or accruing under this Lease during any such Clean-up.
Fixed Rent (a) Commencing as of the Rent Commencement Date, Tenant shall pay Fixed Rent to Landlord, or Landlord’s designee as designated in a written notice to Tenant at such address as Landlord shall from time to time designate by written notice to Tenant. Except as hereinafter provided, the Fixed Rent shall be due and payable in the amounts set forth on Schedule 2 hereto for the respective periods shown on such Schedule 2. Fixed Rent shall be due and payable in advance on the first day of each month (or if such first day is not a business day, the first business day of each month), commencing on the Date of Rent Commencement, during the Term (each such date being referred to herein as a “Due Date”). Notwithstanding the foregoing, from the Date of Rent Commencement until Tenant is notified otherwise by Landlord and Lender, Fixed Rent shall be paid by wire transfer to the account specified in the rent direction letter from Landlord to Tenant delivered concurrently with the execution and delivery of this Lease.
(b) If the Lease Commencement Date or Rent Commencement Date shall be on any day other than the first day of a calendar month, then all amounts to be paid on such dates shall be prorated on a per diem basis.
(c) If any installment of Fixed Rent is not paid on the respective Due Date, Tenant shall pay Landlord interest on such overdue payment at the Lease Default Rate, accruing from the Due Date of such payment until the same is paid; provided, however, the foregoing obligation to pay the Default Rate shall not be required for the first late payment of Fixed Rent in any calendar year so long as such delay in payment does not continue for longer than a period of ten (10) days. All Fixed Rent and Additional Rent shall be payable in U.S. Dollars.
(d) Commencing as of the Lease Commencement Date, all taxes, costs, expenses, and other amounts which Tenant is required to pay pursuant to this Lease (other than Fixed Rent), together with every fine, penalty, interest and cost which may be added in accordance herewith for non-payment or late payment thereof shall constitute additional rent (“Additional Rent”). All Additional Rent due to Landlord (or its designee) shall be paid directly by Tenant within thirty (30) days after Landlord gives written notice that payment is due, unless otherwise provided in this Lease, in which case, the Additional Rent shall be paid as otherwise so provided. Unless otherwise provided herein, Additional Rent payable by Tenant to a third (3rd) party (i.e., utility charges, maintenance contracts, supply contracts, vendor contracts, etc.) shall be paid as and when the same shall be due and payable pursuant to Tenant’s agreement or other arrangement with the applicable third (3rd) party. If Tenant shall fail to pay any such Additional Rent or any other sum due hereunder when the same shall become due (after the expiration of the applicable cure periods therefor), Landlord shall have all rights, powers and remedies with respect thereto as are provided herein or by Law in the case of non-payment of any Fixed Rent and shall, except as expressly provided herein, have the right (after the expiration of the applicable cure periods thereof), not sooner than ten (10) days after notice to Tenant (except in the event of an emergency, as reasonably determined by Landlord, in which case prior notice shall not be necessary) of its intent to do so, to pay the same on behalf of Tenant, and Tenant shall repay such amounts to Landlord on demand. Tenant shall pay to Landlord interest at the Lease Default Rate on all overdue Additional Rent and other sums due hereunder, in each case paid by Landlord or Lender on behalf of Tenant, from the date of payment by Landlord or Lender until repaid by Tenant.
Basic Rent The periodic rent payable for the Aircraft throughout the Basic Term pursuant to Section 3.02 of the Lease, adjusted pursuant to Article 3 of the Lease. Basic Term. The period commencing at the beginning of the day on the Delivery Date and ending at the end of the day on July 15, 2023, or such earlier date on which the Lease shall be terminated as provided therein.
Minimum Rent The defined term “Minimum Rent” set forth in Section 1.66 of the Lease is deleted in its entirety and replaced with the following:
Monthly Rent a. Commencing as of the Commencement Date, and continuing thereafter on or before the first day of each calendar month during the term hereof, Tenant shall pay to Landlord, as monthly rent for the Premises, the Monthly Rent specified in Paragraph 2 above. If Tenant’s obligation to pay Monthly Rent hereunder commences on a day other than the first day of a calendar month, or if the term of this Lease terminates on a day other than the last day of a calendar month, then the Monthly Rent payable for such partial month shall be appropriately prorated on the basis of a thirty (30)-day month. Monthly Rent and the Additional Rent specified in Paragraph 7 shall he paid by Tenant to Landlord, in advance, without deduction, offset, prior notice or demand, in immediately available funds of lawful money of the United States of America, or by good check as described below, to the lockbox location designated by Landlord, or to such other person or at such other place as Landlord may from time to time designate in writing. Payments made by check must be drawn either on a California financial institution or on a financial institution that is a member of the federal reserve system. Notwithstanding the foregoing, Tenant shall pay to Landlord together with Tenant’s execution of this Lease an amount equal to the Monthly Rent payable for the first full calendar month of the Lease term after Tenant’s obligation to pay Monthly Rent shall have commenced hereunder, which amount shall be applied to the Monthly Rent first due and payable hereunder.
b. All amounts payable by Tenant to Landlord under this Lease, or otherwise payable in connection with Tenant’s occupancy of the Premises, in addition to the Monthly Rent hereunder and Additional Rent under Paragraph 7, shall constitute rent owed by Tenant to Landlord hereunder.
c. Any rent not paid by Tenant to Landlord when due shall bear interest from the date due to the date of payment by Tenant at an annual rate of interest (the “Interest Rate”) equal to the lesser of (i) twelve percent (12%) per annum or (ii) the maximum annual interest rate allowed by law on such due date for business loans (not primarily for personal, family or household purposes) not exempt from the usury law. Notwithstanding the foregoing, Landlord shall give Tenant notice of non-payment of rent when due and five (5) days after delivery of such notice to cure such non-payment once in each calendar year before assessing interest in such calendar year pursuant to this Paragraph 5.c. Failure by Tenant to pay rent when due, including any interest accrued under this subparagraph, shall constitute an Event of Default (as defined in Paragraph 25 below) giving rise to all the remedies afforded Landlord under this Lease and at law for nonpayment of rent.
d. No security or guaranty which may now or hereafter be furnished to Landlord for the payment of rent due hereunder or for the performance by Tenant of the other terms of this Lease shall in any way be a bar or defense to any of Landlord’s remedies under this Lease or at law.
e. Notwithstanding anything to the contrary in this Lease: (i) in no event may any rent under this Lease be based in whole or in part on the income or profits derived from the Premises, except for percentage rent based on gross (not net) receipts or sales; (ii) if the holder of a Superior Interest (as defined in Paragraph 21 below) succeeds to Landlord’s interest in the Lease (“Successor Landlord”) and the Successor Landlord is advised by its counsel that all or any portion of the rent payable under this Lease is or may be deemed to be “unrelated business income” within the meaning of the Internal Revenue Code or regulations issued thereunder, such Successor Landlord may, at its option, unilaterally amend the calculation of rent so that none of the rent payable to Landlord under the Lease will constitute “unrelated business income,” but the amendment will not increase Tenant’s payment obligations or other liability under this Lease or reduce the Landlord’s obligations under this Lease and (iii) upon the Successor Landlord’s request, Tenant shall execute any document such holder deems necessary to effect the foregoing amendment to this Lease.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Lease Year Lease Year" means each consecutive twelve-month period beginning with the Commencement Date, except that if the Commencement Date is not the first day of a calendar month, then the first Lease Year shall be the period from the Commencement Date through the final day of the twelve months after the first day of the following month, and each subsequent Lease Year shall be the twelve months following the prior Lease Year.
