Lease Commencement Notwithstanding anything contained herein to the contrary, if Lessor, for any reason whatsoever, including Lessor's negligence except as provided for in Article 27(b), cannot deliver possession of the Premises, as provided for in Article 27(a), to Lessee at the commencement of the agreed Term as set forth in Article 2, this Lease shall not be void or voidable, nor shall Lessor be liable to Lessee for any loss or damage resulting therefrom, but in that event, the Term shall be for the full term as specified above to commence from and after the date Lessor shall have delivered possession of the Premises to Lessee or from the date Lessor would have delivered possession of the Premises to Lessee but for Lessee's failure to timely supply to Lessor such drawings and/or information required by Exhibit C or for any other reason attributable to Lessee (herein the "Commencement Date") and to expire midnight of the day immediately preceding Term anniversary of the Commencement Date, and if requested by Lessor, Lessor and Lessee shall, ratify and confirm said Commencement and Expiration Dates by completing and signing Exhibit G attached hereto and made a part hereof.
Lease Commencement Date The earlier to occur of (i) the date upon which Tenant first commences to conduct business in the Premises, and (ii) the later to occur of (A) November 1, 2018 and (B) the date upon which the Premises are Ready for Occupancy (as that term is defined in Section 5.1 of the Tenant Work Letter attached hereto as Exhibit B (the “Tenant Work Letter”)).
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Rent Commencement Date The "Rent Commencement Date" shall be the date that Tenant first uses the Premises or any portion thereof for any purpose permitted under this lease. In the event this lease pertains to a building or building interior finish to be constructed, the "Rent Commencement Date" shall be the date upon which the buildings and other improvements erected and to be erected upon the premises shall have been substantially completed in accordance with the plans and specifications described on Exhibit "C" attached hereto and incorporated herein by reference, provided however, that if Landlord shall be delayed in such substantial completion as a result of: (i) Tenant's failure to agree to plans, specifications, and cost estimates, within a reasonable period of time; (ii) Tenant's request for materials, finishes or installations other than Landlord's standard; (iii) Tenant's changes in plans; the commencement date and the payment of rent hereunder shall be accelerated by the number of days of such delay, and provided further that if Landlord cannot substantially complete the premises as a result of any events (i) through (iii) above, Landlord may as its election complete so much of Landlord's work as may be practical under the circumstances and, by written notice to Tenant, establish the commencement date as the date of such partial completion, subject to any applicable accelerations due to delays resulting from events (i) through (iii) above. Taking possession by Tenant shall be deemed conclusively to establish that said buildings and other improvements have been completed in accordance with the plans and specifications and that the premises are in good and satisfactory condition, as of when possession was so taken. Tenant acknowledges that no representations as to the repair of the premises have been made by Landlord, unless such are expressly set forth in the lease. After such "Rent Commencement Date" Tenant shall, upon demand, execute and deliver to Landlord a letter of acceptance of delivery of the premises. In the event of any dispute as to substantial completion of work performed, execute or required to be performed by Landlord, the certificate of Landlord's architect or general contractor shall be conclusive.
Payment Delay Notwithstanding any other terms of this Agreement, no payments will be made to CONTRACTOR until COUNTY is satisfied that work of such value has been rendered pursuant to this Agreement. However, COUNTY will not unreasonably withhold payment and, if a dispute exists, the withheld payment shall be proportional only to the item in dispute.
Project Commencement The Grantee shall begin the grant-funded project <<on or before insert date>> <<within 90 days of the original start date of the grant term or grant execution date, whichever is later,>>, unless otherwise approved by System Agency. If project commencement is delayed, the Grantee must submit in writing to the assigned contract manager, the steps taken to initiate the project, the reasons for the delay, and the expected start date. System Agency may require Grantee to take immediate remedial or corrective action in response to any delay.
Construction Commencement The Connecting Transmission Owner shall commence construction of the Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades for which it is responsible as soon as practicable after the following additional conditions are satisfied:
5.6.1 Approval of the appropriate Governmental Authority has been obtained for any facilities requiring regulatory approval;
5.6.2 Necessary real property rights and rights-of-way have been obtained, to the extent required for the construction of a discrete aspect of the Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades;
5.6.3 The Connecting Transmission Owner has received written authorization to proceed with construction from the Developer by the date specified in Appendix B hereto; and
5.6.4 The Developer has provided security to the Connecting Transmission Owner in accordance with Article 11.5 by the dates specified in Appendix B hereto.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Service Commencement Date The date the Transmission Provider begins to provide service pursuant to the terms of an executed Service Agreement, or the date the Transmission Provider begins to provide service in accordance with Section 15.3 or Section 29.1 under the Tariff.
Pre-Commencement Phase Services The services required to be provided by the Contractor for the Pre- Commencement Phase of the Project in accordance with the Contract Documents.
