Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.
CONSTRUCTION OF THE PROJECT/ APARTMENT The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the [Apartment/Plot] and accepted the floor plan, payment plan and the specifications, amenities and facilities [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent Authorities and shall also strictly abide by the bye-laws, FAR and density norms and provisions prescribed by the [Please insert the relevant State laws]and shall not have an option to make any variation /alteration / modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of the Agreement.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Completion of the Project The Participating County acknowledges it is obligated to undertake and complete the design and construction of the Project in compliance with all of the applicable terms and conditions of the Project Documents and the Participating County agrees to use its best efforts to cause the completion of design and construction of the Project in compliance with the applicable terms and conditions of such documents. The Participating County agrees to complete the Project in accordance with this Agreement and consistent with the scope, cost and schedule established by the Board and attached hereto in Exhibit A, as such scope, cost and schedule may be modified with the approval of Finance and the recognition of the Board.
Use of the Property The Tenant agrees with the Landlord as follows:-
3.1 To use the Room or Studio (as applicable) only as a single private residence for occupation by the Tenant personally and not to allow visitors to remain in the Room or in the Flat or Studio (as applicable) overnight unless the Tenant has registered the visitor at reception and obtained the Landlord’s consent to the visitor remaining in the Room or the Flat or Studio (as applicable) overnight such consent not to be unreasonably withheld or delayed provided that no overcrowding occurs and (where applicable) the other occupiers of the Flat do not raise any objection
3.2 The Tenant shall not:
3.2.1 use the Room Studio Flat or Building for the purposes of conducting a business
3.2.2 keep any pets or other animals on or in the Room Studio Flat or Building without the prior written consent of the Landlord
3.2.3 play or use any musical instrument or television radio or other means of reproducing sound so that the sound is audible outside the Room Flat Studio or Building
3.2.4 connect to the telephone line the internet or any other systems
3.2.5 store bicycles in the Room Flat Studio or Building but to store any bicycle in the designated bicycle areas of the Building only and in the event of the Landlord removing any bicycle stored in breach of this clause to pay to the Landlord within 7 days of written demand £25 before the release of the bicycle to the Tenant
3.2.6 store or keep or use any unlawful substance or materials in the Room Flat Studio or Building at any time and to report to the Landlord or any of its employees the presence of any such unlawful substance or materials
3.2.7 keep store or use in the Room Flat Studio or Building any inflammable or dangerous articles, any lighted candles electronic cigarettes incense sticks shisha pipes naked flame appliances portable heater lamp or other portable apparatus fed by paraffin or liquid gas and to comply with all of the Landlord’s requirements relating to fire safety as set out in the Fire Safety Agreement which is available for inspection at the relevant onsite management reception
3.2.8 keep or use in the Room Flat Studio or Building any electrical heating and/or electrical cooking equipment and/or multiway adaptors;
3.2.9 bring into or keep in the Room Flat Studio or Building any other electrical items (“the Items”) unless the Tenant has first produced by prior appointment the Items to the Landlord’s officer in the relevant onsite management reception for Portable Appliance Testing (“XXX”) and thereafter obtained the approval of the Landlord to the keeping and using of the Items in the Room or the Flat or Studio, ( as applicable) which approval will be given if the Items are in good safe working order and meet the XXX requirements
3.2.10 expose or allow to be hung any laundry washing or other items so as to be visible from outside of the Room Flat Studio or Building and not to dry clothes on the storage heaters
3.2.11 not to bring into or keep in the Room Flat Studio or Building any washing machine
3.2.12 glue stick nail tack screw fix or fasten (whether with Blue-Tack or similar materials) anything whatsoever to the interior or the exterior of the Room Flat Studio or Building
3.2.13 smoke (including electronic cigarettes) or use non-prescription drugs within the Room Flat Studio or Building
3.2.14 part with the keys or access fob to the Room Flat Studio or Building and to report immediately any loss of the same to the Landlord and to pay to the Landlord before the Landlord issues any replacements the sum of £20 for each replacement key and £15 for each replacement access fob (and if a key or access fob is found and returned by the student after a replacement has been issued and the cost charged, the refund of the cost is at the Landlord’s discretion and in any event an administrative fee may be charged.)
3.2.15 damage or force or in any way misuse any locks in the Room Flat Studio or Building and in the event of default to pay to the Landlord on demand all reasonable costs (including an additional administration charge) reasonably incurred by the Landlord in replacing the same and/or making good all damage caused
3.2.16 connect to or trail wires from the telephone apparatus and/or any television in the Room Flat Studio or Building to protect the health and safety of the Tenant and (where applicable) the occupiers of the Building
3.2.17 tamper with any fire safety equipment in the Room Flat Studio or Building including without limitation fire extinguishers, smoke alarms, emergency exit signs and break glass alarm points
3.2.18 cause a nuisance annoyance or interference or threaten or abuse any other residents in the Building any employees servants or agents of the Landlord or the owners and occupiers of neighbouring, adjoining or adjacent property or the owners of occupiers of them;
3.2.19 do anything that has the effect of invalidating the insurance that the Landlord has taken out in relation to the Building
3.2.20 use the Room or the Flat or the Studio for immoral or illegal purposes or otherwise commit or be involved in any criminal activity
3.3 The Tenant agrees to:
3.3.1 where applicable, open the windows in the Room or the Studio to the tilt position for at least 30 minutes each day (provided that the Tenant is in occupation) to ventilate the Room or Studio and not to open the windows in the Room beyond the tilt position save in emergencies.
3.3.2 always to use the extractor fan in the bathroom when using the bathroom and not to disable the extractor fan except for safety reasons in an emergency
3.3.3 use best endeavours to ensure that the Tenant’s visitors comply with the Tenant’s obligations under this Agreement while present in the Room Flat Studio or the Building
3.3.4 comply with additional obligations or restrictions set out in any management scheme or other regulations reasonably required by the Landlord which may be notified to the Tenant in writing from time to time.
3.4 Unless otherwise expressly provided, the obligations and liabilities of the Tenant under this agreement are joint and several. This means that where, there is more than one tenant of the Studio Flat or the Building the Tenant will be liable for all sums due under the agreement, not just liable for a proportionate part.
Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements.
(b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.
Use of the Premises A. The dwelling unit shall be used only as a private residence for Tenant and Tenant’s household members, except that Tenant and the household members may request an exception for certain limited incidental activities on a case by case basis in the dwelling unit if the Authority has given prior written consent to do so. All exceptions will require prior written approval and, if the activity will continue in the following year, a new exception request will need to be submitted for approval.
B. Tenant shall give prior notice to the Authority of any guest staying overnight at Tenant’s premises and any such overnight stay is deemed an accommodation for the guest. Reasonable accommodation for a guest is permitted only so long as the guest is not provided accommodations in or upon the premises, including the dwelling unit, for more than a total of fourteen (14) days in a twelve (12) month period, except with the express written permission of the Authority made upon written request from Tenant. As used in the Lease, “guest” means a person present in the dwelling unit or elsewhere upon the premises, other than Tenant or the household members, who is so present with the consent of the Tenant or one of the household members.
C. Tenant, any of the household members and any guest shall only use the dwelling unit or any other portion of the premises for lawful purposes permitted under the Lease and shall comply with all applicable rules and regulations of the Authority and with all applicable federal, state and local laws.
D. Tenant, the household members and any guests, shall use not use the utilities furnished by the Authority so as to waste the utilities through excess utility consumption, and shall also use and operate all utilities, whether or not furnished by the Authority, so as to comply with all applicable laws, regulations or guidelines of any governmental entity regulating utilities or fuels.
E. Tenant, or any of the household members, are prohibited from entering upon the Development for any reason if the Tenant has been evicted through the judicial process; (2) the Tenant is issued an eviction notice, appeals the eviction to the hearing office and the hearing officer upholds the City’s decision; and/or (3) the Tenant fails to appeal the eviction notice within the requisite time period.
COMMENCEMENT AND COMPLETION OF THE PROJECT Section 3.01 The Project
(a) The Company intends and expects, together with any Sponsor Affiliate, to (i) construct and acquire the Project, and (ii) meet the Contract Minimum Investment Requirement within the Investment Period. The Company anticipates that the first Phase of the Project will be placed in service during the calendar year ending December 31, 2020.
(b) Pursuant to the FILOT Act and subject to Section 4.03 hereof, the Company and the County hereby agree that the Company and any Sponsor Affiliates shall identify annually those assets which are eligible for FILOT payments under the FILOT Act and which the Company or any Sponsor Affiliate selects for such treatment by listing such assets in its annual PT-300S form (or comparable form) to be filed with the Department (as such may be amended from time to time) and that by listing such assets, such assets shall automatically become Economic Development Property and therefore be exempt from all ad valorem taxation during the Exemption Period. Anything contained in this Fee Agreement to the contrary notwithstanding, the Company and any Sponsor Affiliates shall not be obligated to complete the acquisition of the Project. However, if the Company, together with any Sponsor Affiliates, does not meet the Contract Minimum Investment Requirement within the Investment Period, the provisions of Section 4.03 hereof shall control.
(c) The Company may add to the Land such real property, located in the same taxing District in the County as the original Land, as the Company, in its discretion, deems useful or desirable. In such event, the Company, at its expense, shall deliver an appropriately revised Exhibit A to this Fee Agreement, in form reasonably acceptable to the County.
Scope of the Project Under this Agreement, the scope of the Project (the “Scope of the Project”) shall mean and include:
(a) construction of the Project Highway on the Site set forth in Schedule- A and as specified in Schedule-B together with provision of Project Facilities as specified in Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D;
(b) maintenance of the Project Highway in accordance with the provisions of this Agreement and in conformity with the requirements set forth in Schedule-E; and
(c) performance and fulfilment of all other obligations of the Contractor in accordance with the provisions of this Agreement and matters incidental thereto or necessary for the performance of any or all of the obligations of the Contractor under this Agreement.
Development of the Project 4.1 TSP's obligations in development of the Project:
a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project;
b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with:
i. the Electricity Act and the Rules made thereof;
ii. the Grid Code;
iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020.
iv. Safety/ security Guidelines laid down by the Government;
v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement;
c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code.
d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement;
e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities;
f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities;
g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities;
h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this;
i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India;
j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above.
k. to comply with all its obligations undertaken in this Agreement.
4.2 Roles of the Nodal Agency in implementation of the Project:
4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia:
a. appoint an Independent Engineer within 90 days of the Effective Date
b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project;
c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and
d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc
e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and
f. perform any other responsibility (ies) as specified in this Agreement.
