Products and Completed Operations Personal Injury Liability Contractual Liability The policy shall be on an occurrence form and limits shall not be less than: $1,000,000 Each Occurrence $2,000,000 General Aggregate $1,000,000 Products/Completed Operations Aggregate $1,000,000 Personal & Advertising Injury Automotive Liability: The Party shall carry automotive liability insurance covering all motor vehicles, including hired and non-owned coverage, used in connection with the Agreement. Limits of coverage shall not be less than $500,000 combined single limit. If performance of this Agreement involves construction, or the transport of persons or hazardous materials, limits of coverage shall not be less than $1,000,000 combined single limit.
Commercial General Liability and Business Auto Liability will be endorsed to provide primary and non-contributory coverage The Commercial General Liability Additional Insured endorsement will include on-going and completed operations and will be submitted with the
Assignment Liability Indemnity Force Majeure Consequential Damages and Default Notwithstanding any other provision of this Agreement, the liability, indemnification and insurance provisions of the Transmission Operating Agreement (“TOA”) or other applicable operating agreements shall apply to the relationship between the System Operator and the Interconnection Transmission Owner and the liability, indemnification and insurance provisions of the Tariff apply to the relationship between the System Operator and the Interconnection Customer and between the Interconnecting Transmission Owner and the Interconnection Customer.
Civil Liability 47.01 If any civil action is brought against any employee covered by this Agreement for an alleged tort committed by the employee in the performance of their assigned duties, (a “workplace claim”) then:
LIABILITY PROVISION The liability provision for the Service Provider to compensate for any proven damages is limited to the agreement value.
Defect Liability Period The defect liability period (if any) shall be as per Special Conditions of Contract of Part-B.
Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS.
RESPONDENT LIABILITY FOR DAMAGE TO GOVERNMENT PROPERTY The Respondent shall be liable for all damages to government-owned, leased, or occupied property and equipment caused by the Respondent and its employees, agents, subcontractors, and suppliers, including any delivery or cartage company, in connection with any performance pursuant to the Contract. The Respondent shall notify the City of Xxxxxx Procurement Manager in writing of any such damage within one (1) calendar day.
Defects Liability Period Defects liability period shall start for Instructed works immediately the works are certified as Complete by the Engineer. The period of Defects liability shall be prescribed in the Appendix to the Contract. SUBCLAUSE 49.2 – COMPLETION OF OUTSTANDING WORK AND REMEDYING DEFECTS Add At the time of End of Defects Liability Inspection, no defect arising from the permanent works existing shall be acceptable for taking over. The Inspection team shall verify and satisfy themselves that all the outstanding works and defects arising out of the works have been attended to sufficiently. Routine Maintenance works/PBC Works shall also be inspected at the time of End of Defects Liability Inspection and should comply to the specifications of the PBC Works.
Contractual Liability Liability for payments under the Plan shall be the responsibility of the:
