LIMITATION OF CONTRACTOR’S LIABILITY Except as specified in any separate writing between the Contractor and an END USER, Contractor’s total liability under this Agreement, whether for breach of contract, warranty, negligence, strict liability, in tort or otherwise, but excluding its obligation to indemnify H-GAC, is limited to the price of the particular products/services sold hereunder, and Contractor agrees either to refund the purchase price or to repair or replace product(s) that are not as warranted. In no event will Contractor be liable for any loss of use, loss of time, inconvenience, commercial loss, loss of profits or savings or other incidental, special or consequential damages to the full extent such use may be disclaimed by law. Contractor understands and agrees that it shall be liable to repay and shall repay upon demand to END USER any amounts determined by H-GAC, its independent auditors, or any agency of State or Federal government to have been paid in violation of the terms of this Agreement.
Limitation of Liability of the Adviser The Adviser shall not be liable for any error of judgment or mistake of law or for any loss arising out of any investment or for any act or omission in the execution and management of the Fund, except for willful misfeasance, bad faith or gross negligence in the performance of its duties and obligations hereunder. As used in this Article 6, the term "Adviser" shall include Directors, officers and employees of the Adviser as well as that corporation itself.
LIMITATION OF OUR LIABILITY We are not responsible or liable to you or any supplementary cardmember for: • any delay or failure by a merchant to accept the card, • goods and services you charge to your account, including any dispute with a merchant about goods and services charged to your account, • any costs, damages or expenses arising out of our failure to carry out our obligations under this agreement if that failure is caused by a third party or because of a systems failure, data processing failure, industrial dispute or other action outside our control, and • loss of profits or any incidental, indirect, consequential, punitive or special damages regardless of how they arise. For example, we will not be liable to you or any supplementary cardmember for any malfunction or failure of the card or refusal by a merchant to accept the card. Clause required under the Consumer Protection Act. (Open credit contract for the use of a credit card)
Limitation of Trust’s Liability The Sub-Advisor acknowledges that it has received notice of and accepts the limitations upon the Trust's liability set forth in its Declaration of Trust. The Sub-Advisor agrees that (i) the Trust's obligations to the Sub-Advisor under this Agreement (or indirectly under the Advisory Agreement) shall be limited in any event to the assets of the Fund and (ii) the Sub-Advisor shall not seek satisfaction of any such obligation from the holders of shares of the Fund nor from any Trustee, officer, employee or agent of the Trust.
Limitation of Seller's Liability This paragraph limits the liability of the seller. This is a usual provision, but flexible, ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ . ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ , ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ .
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Limitation of Liability of Escrow Agent The Escrow Agent will not be liable to any of the Parties hereunder for any action taken or omitted to be taken by it under or in connection with this Agreement, except for losses directly, principally and immediately caused by its bad faith, willful misconduct or gross negligence. Under no circumstances will the Escrow Agent be liable for any special, indirect, incidental, consequential, exemplary, aggravated or punitive losses or damages hereunder, including any loss of profits, whether foreseeable or unforeseeable. Notwithstanding the foregoing or any other provision of this Agreement, in no event will the collective liability of the Escrow Agent under or in connection with this Agreement to any one or more Parties, except for losses directly caused by its bad faith or willful misconduct, exceed the amount of its annual fees under this Agreement or the amount of three thousand dollars ($3,000.00), whichever amount shall be greater.
Limitation of Liability of Sub-Adviser (a) The Sub-Adviser shall be liable for losses resulting from its own acts or omissions caused by the Sub-Adviser’s willful misfeasance, bad faith or gross negligence in the performance of its duties hereunder or its reckless disregard of its duties under this Agreement, and nothing herein shall protect the Sub-Adviser against any such liability to the shareholders of the Fund or to the Adviser. Except as provided in the previous sentence, the Sub-Adviser shall not be liable to the Fund or to any shareholder of the Fund or to the Adviser for any claim or loss arising out of any investment or other act or omission in the performance of the Sub-Adviser’s duties under this Agreement, or for any loss or damage resulting from the imposition by any government of exchange control restrictions which might affect the liquidity of the Fund’s assets maintained with custodians or securities depositories in foreign countries, or from any political acts of any foreign governments to which such assets might be exposed, or for any tax of any kind (other than taxes on the Sub-Adviser’s income), including without limitation any statutory, governmental, state, provincial, regional, local or municipal imposition, duty, contribution or levy imposed by any government or governmental agency upon or with respect to such assets or income earned with respect thereto (collectively “Taxation”). Notwithstanding the foregoing sentence and the provisions of Section 5(b), the Sub-Adviser shall be liable for taxes or tax penalties incurred by the Fund, or by any legal or beneficial owner of the Fund’s shares, for any failure of the Portfolio to qualify as a regulated investment company under Subchapter M, or to meet the diversification requirements of Section 817(h), of the Internal Revenue Code of 1986, as amended, to the extent resulting from the Sub-Adviser’s management of the Portfolio.
(b) In the event the Sub-Adviser is assessed any Taxation in respect of the assets, income or activities of the Portfolio, the Adviser and the Fund jointly will indemnify the Sub-Adviser for all such amounts wherever imposed, together with all penalties, charges, costs and interest relating thereto and all expenditures, including reasonable attorney’s fees, incurred by the Sub-Adviser in connection with the defense or settlement of any such assessment. The Sub-Adviser shall undertake and control the defense or settlement of any such assessment, including the selection of counsel or other professional advisers, provided that the selection of such counsel and advisers and the settlement of any assessment shall be subject to the approval of the Adviser and the Fund, which approvals shall not be unreasonably withheld. The Adviser and the Fund shall have the right to retain separate counsel and assume the defense or settlement on behalf of the Adviser and the Fund, as the case may be, of any such assessment if representation of the Adviser and the Fund by counsel selected by the Sub-Adviser would be inappropriate due to actual or potential conflicts of interest.
Advisor’s Liability The Advisor shall have responsibility for the accuracy and completeness (and liability for the lack thereof) of the statements in each Fund’s offering materials (including the prospectus, the statement of additional information, and advertising and sales materials), except for information supplied by the co-administrators or the Trust or another third party for inclusion therein. The Advisor will not be liable for any error of judgment or mistake of law or for any loss suffered by Advisor or by the Trust in connection with the performance of this Agreement, except a loss resulting from a breach of fiduciary duty with respect to the receipt of compensation for services or a loss resulting from willful misfeasance, bad faith or gross negligence on its part in the performance of its duties or from reckless disregard by it of its duties under this Agreement.
Limitation of Liability of Sub-Adviser and Indemnification Sub-Adviser shall not be liable for any costs or liabilities arising from any error of judgment or mistake of law or any loss suffered by the Fund or the Trust in connection with the matters to which this Contract relates except a loss resulting from willful misfeasance, bad faith or gross negligence on the part of Sub-Adviser in the performance by Sub-Adviser of its duties or from reckless disregard by Sub-Adviser of its obligations and duties under this Contract. Any person, even though also an officer, partner, employee, or agent of Sub-Adviser, who may be or become a Trustee, officer, employee or agent of the Trust, shall be deemed, when rendering services to a Fund or the Trust or acting with respect to any business of a Fund or the Trust to be rendering such service to or acting solely for the Fund or the Trust and not as an officer, partner, employee, or agent or one under the control or direction of Sub-Adviser even though paid by it.
