Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.
Resignation and Removal of Escrow Agent Escrow Agent may resign from the performance of its duties hereunder at any time by giving thirty (30) days' prior written notice to the parties or may be removed, with or without cause, by the parties, acting jointly, by furnishing a Joint Written Direction to Escrow Agent, at any time by the giving of ten (10) days' prior written notice to Escrow Agent as provided herein below. Upon any such notice of resignation or removal, the representatives of the Investor(s) and the Company identified in Sections 13a.(iv) and 13b.(iv), below, jointly shall appoint a successor Escrow Agent hereunder, which shall be a commercial bank, trust company or other financial institution with a combined capital and surplus in excess of $10,000,000.00. Upon the acceptance in writing of any appointment of Escrow Agent hereunder by a successor Escrow Agent, such successor Escrow Agent shall thereupon succeed to and become vested with all the rights, powers, privileges and duties of the retiring Escrow Agent, and the retiring Escrow Agent shall be discharged from its duties and obligations under this Escrow Agreement, but shall not be discharged from any liability for actions taken as Escrow Agent hereunder prior to such succession. After any retiring Escrow Agent's resignation or removal, the provisions of this Escrow Agreement shall inure to its benefit as to any actions taken or omitted to be taken by it while it was Escrow Agent under this Escrow Agreement. The retiring Escrow Agent shall transmit all records pertaining to the Escrow Funds and shall pay all funds held by it in the Escrow Funds to the successor Escrow Agent, after making copies of such records as the retiring Escrow Agent deems advisable and after deduction and payment to the retiring Escrow Agent of all fees and expenses (including court costs and attorneys' fees) payable to, incurred by, or expected to be incurred by the retiring Escrow Agent in connection with the performance of its duties and the exercise of its rights hereunder.
Cost of Repairs 54.1 Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor's cost if the loss or damage arises from the Contractor's acts or omissions.
Complete Taking If at any time during the Fee Term title to or temporary use of the entire Project should become vested in a public or quasi-public authority by virtue of the exercise of a taking by condemnation, inverse condemnation or the right of eminent domain, or by voluntary transfer under threat of such taking, or in the event that title to a portion of the Project shall be taken rendering continued occupancy of the Project commercially infeasible in the judgment of the Sponsor, the Sponsor shall have the option to terminate this Fee Agreement as of the time of vesting of title by sending written notice to the County within a reasonable period of time following such vesting.
Completion of the Project The Participating County acknowledges it is obligated to undertake and complete the design and construction of the Project in compliance with all of the applicable terms and conditions of the Project Documents and the Participating County agrees to use its best efforts to cause the completion of design and construction of the Project in compliance with the applicable terms and conditions of such documents. The Participating County agrees to complete the Project in accordance with this Agreement and consistent with the scope, cost and schedule established by the Board and attached hereto in Exhibit A, as such scope, cost and schedule may be modified with the approval of Finance and the recognition of the Board.
Removal of Tenant’s Property Upon the expiration or earlier termination of this Lease or the termination of Tenant's right of possession of the Premises only, Tenant shall have the right, at its sole cost and expense, for a period of fifteen ( 15) days thereafter to remove Tenant's Property, Distinctive Property and the Financed Personalty, respectively, from the Premises, provided that Tenant shall pay to Landlord Rent due under Article 3 hereof for the actual number of days which elapse during such fifteen (15) day period until the Tenant's Property, Distinctive Property and the Financed Personalty, as applicable, are removed from the Premises. If and to the extent that Tenant fails to remove any of such property by the expiration of said fifteen (15) day period, Landlord agrees that Tenant Lender, TE Lender and Franchisor each shall have the right for a period of forty (45) days thereafter to remove the same from the Premises, provided that Tenant shall pay to Landlord Rent due hereunder for the actual number of days which elapse until Tenant Lender, TE Lender or Franchisor remove the same from the Premises during such forty five (45) day period. If and to the extent that any such property remains on the Premises on the sixtieth (60th) day after such termination, the same shall be deemed abandoned, and at Landlord's option shall become the property of Landlord and may be sold or disposed of as Land-lord may determine; provided, however, that Landlord shall not use, suffer or permit the use of any Distinctive Property unless the attributes or features thereof associated with Tenant or Franchisor are removed or obliterated. Any and all damage to the Building caused by or resulting from the removal of Tenant's Property, Distinctive Property or Financed Personalty shall promptly be repaired at no cost or expense to Landlord and Tenant shall be liable for such cost and expense unless such repairs are made by Tenant, Franchisor or TE Lender, as the case may be.
Provisioning Line Splitting and Splitter Space 3.8.1 The Data LEC, Voice CLEC or BellSouth may provide the splitter. When Southern Telecom or its authorized agent owns the splitter, Line Splitting requires the following: a non-designed analog Loop from the serving wire center to the NID at the End User’s location; a collocation cross connection connecting the Loop to the collocation space; a second collocation cross connection from the collocation space connected to a voice port; the high frequency spectrum line activation, and a splitter. The Loop and port cannot be a Loop and port combination (i.e. UNE-P), but must be individual stand-alone Network Elements. When BellSouth owns the splitter, Line Splitting requires the following: a non designed analog Loop from the serving wire center to the NID at the End User’s location with CFA and splitter port assignments, and a collocation cross connection from the collocation space connected to a voice port.
3.8.2 An unloaded 2-wire copper Loop must serve the End User. The meet point for the Voice CLEC and the Data LEC is the point of termination on the MDF for the Data LEC's cable and pairs.
3.8.3 The foregoing procedures are applicable to migration to Line Splitting Service from a UNE-P arrangement, BellSouth Retail Voice Service, BellSouth High Frequency Spectrum (CO Based) Line Sharing.
3.8.4 For other migration scenarios to line splitting, BellSouth will work cooperatively with CLECs to develop methods and procedures to develop a process whereby a Voice CLEC and a Data LEC may provide services over the same Loop.
Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.
Premises Building Project and Common Areas 1.1 Premises, Building, Project and Common Areas.
COMMENCEMENT AND COMPLETION OF THE PROJECT Section 3.01 The Project
(a) The Company intends and expects, together with any Sponsor Affiliate, to (i) construct and acquire the Project, and (ii) meet the Contract Minimum Investment Requirement within the Investment Period. The Company anticipates that the first Phase of the Project will be placed in service during the calendar year ending December 31, 2020.
(b) Pursuant to the FILOT Act and subject to Section 4.03 hereof, the Company and the County hereby agree that the Company and any Sponsor Affiliates shall identify annually those assets which are eligible for FILOT payments under the FILOT Act and which the Company or any Sponsor Affiliate selects for such treatment by listing such assets in its annual PT-300S form (or comparable form) to be filed with the Department (as such may be amended from time to time) and that by listing such assets, such assets shall automatically become Economic Development Property and therefore be exempt from all ad valorem taxation during the Exemption Period. Anything contained in this Fee Agreement to the contrary notwithstanding, the Company and any Sponsor Affiliates shall not be obligated to complete the acquisition of the Project. However, if the Company, together with any Sponsor Affiliates, does not meet the Contract Minimum Investment Requirement within the Investment Period, the provisions of Section 4.03 hereof shall control.
(c) The Company may add to the Land such real property, located in the same taxing District in the County as the original Land, as the Company, in its discretion, deems useful or desirable. In such event, the Company, at its expense, shall deliver an appropriately revised Exhibit A to this Fee Agreement, in form reasonably acceptable to the County.
