Liquidated Damages Relating to Delivery Sample Clauses

Liquidated Damages Relating to Delivery. Subject to Vendor’s receipt of Purchaser’s Purchase Order(s) therefor, Vendor will deliver Equipment that meets or exceeds the Specifications in accordance with the Equipment Delivery timeframes specified in Exhibit U for all Markets launched after the Effective Date. The Equipment Delivery timeframes specified in Exhibit U are only applicable if Company has (i) provided a procurement forecast in accordance with this Agreement and provided a specific forecast of its intended purchases of such Equipment a minimum of [***] prior to Vendor’s receipt of the Purchase Order(s) for such Equipment unless otherwise agreed *** Certain information on this page has been omitted and filed separately with the Commission. Cricket Communications Proprietary and Confidential Information to by the parties, and (ii) issued a Purchase Order for a quantity of Equipment that is no more than [***] of the forecasted quantity, and (iii) issued Purchase Order(s) for such Equipment in accordance with Vendor’s standard lead times as specified in Exhibit U. Vendor will pay to Company as Liquidated Damages, an amount equal to one and [***] of the Net Price of the delayed Equipment [***] that delivery of such Equipment is delayed past the Equipment Delivery Dates in Exhibit U (pro-rated on a daily basis for periods of time less than one week), provided, however, that in the event Vendor does delay in delivering Equipment but Commercial Launch nevertheless occurs on or before the date agreed by the parties, then the Liquidated Damages that would otherwise be payable by Vendor for such delay in delivery will not be payable.
Sample 1
AutoNDA by SimpleDocs

Related to Liquidated Damages Relating to Delivery

  • Certain Rules Relating to the Payment of Additional Amounts (a) Upon the request, and at the expense of the Borrower, each Lender and Agent to which the Borrower is required to pay any additional amount pursuant to Subsection 4.10 or 4.11, and any Participant in respect of whose participation such payment is required, shall reasonably afford the Borrower the opportunity to contest, and reasonably cooperate with the Borrower in contesting, the imposition of any Non-Excluded Tax giving rise to such payment; provided that (i) such Lender or Agent shall not be required to afford the Borrower the opportunity to so contest unless the Borrower shall have confirmed in writing to such Lender or Agent its obligation to pay such amounts pursuant to this Agreement and (ii) the Borrower shall reimburse such Lender or Agent for its reasonable attorneys’ and accountants’ fees and disbursements incurred in so cooperating with the Borrower in contesting the imposition of such Non-Excluded Tax; provided, however, that notwithstanding the foregoing no Lender or Agent shall be required to afford the Borrower the opportunity to contest, or cooperate with the Borrower in contesting, the imposition of any Non-Excluded Taxes, if such Lender or Agent in its sole discretion in good faith determines that to do so would have an adverse effect on it.

  • Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.

  • Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.

  • Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.

  • Covenants Relating to Rule 144 For so long as the Company is subject to the reporting requirements of Section 13 or 15 of the Securities Act, the Company covenants that it will file the reports required to be filed by it under the Securities Act and Section 13(a) or 15(d) of the Exchange Act and the rules and regulations adopted by the Commission thereunder. If the Company ceases to be so required to file such reports, the Company covenants that it will upon the request of any Holder of Registrable Securities (a) make publicly available such information as is necessary to permit sales pursuant to Rule 144 under the Securities Act, (b) deliver such information to a prospective purchaser as is necessary to permit sales pursuant to Rule 144A under the Securities Act and it will take such further action as any Holder of Registrable Securities may reasonably request, and (c) take such further action that is reasonable in the circumstances, in each case, to the extent required, from time to time, to enable such Holder to sell its Registrable Securities without registration under the Securities Act within the limitation of the exemptions provided by (i) Rule 144 under the Securities Act, as such Rule may be amended from time to time, (ii) Rule 144A under the Securities Act, as such rule may be amended from time to time, or (iii) any similar rules or regulations hereafter adopted by the Commission. Upon the request of any Holder of Registrable Securities, the Company will deliver to such Holder a written statement as to whether it has complied with such requirements and of the Securities Act and the Exchange Act (at any time after it has become subject to the reporting requirements of the Exchange Act), a copy of the most recent annual and quarterly report(s) of the Company, and such other reports, documents or stockholder communications of the Company, and take such further actions consistent with this Section 8(a), as a Holder may reasonably request in availing itself of any rule or regulation of the Commission allowing a Holder to sell any such Registrable Securities without registration.

  • Damages; Attorneys Fees Nothing contained herein shall be construed to prevent the Company or the Executive from seeking and recovering from the other damages sustained by either or both of them as a result of its or his breach of any term or provision of this Agreement. Each party shall bear its own costs and attorneys’ fees.

  • Payment of Damages The indemnification required hereunder shall be made by periodic payments of the amount thereof during the course of the investigation or defense, within 10 days as and when reasonably specific bills are received or loss, liability, claim, damage or expense is incurred and reasonable evidence thereof is delivered. In calculating any amount to be paid by an indemnifying party by reason of the provisions of this Agreement, the amount shall be reduced by all tax benefits and other reimbursements (including, without limitation, insurance proceeds) credited to or received by the other party related to the Damages.

  • Certain Matters Relating to the Determination of LIBOR LIBOR shall be calculated by the Securities Administrator in accordance with the definition of LIBOR. Until all of the LIBOR Certificates are paid in full, the Securities Administrator will at all times retain at least four Reference Banks for the purpose of determining LIBOR with respect to each LIBOR Determination Date. The Securities Administrator initially shall designate the Reference Banks (after consultation with the Depositor). Each “Reference Bank” shall be a leading bank engaged in transactions in Eurodollar deposits in the international Eurocurrency market, shall not control, be controlled by, or be under common control with, the Securities Administrator and shall have an established place of business in London. If any such Reference Bank should be unwilling or unable to act as such or if the Securities Administrator should terminate its appointment as Reference Bank, the Securities Administrator shall promptly appoint or cause to be appointed another Reference Bank (after consultation with the Depositor). The Securities Administrator shall have no liability or responsibility to any Person for (i) the selection of any Reference Bank for purposes of determining LIBOR or (ii) any inability to retain at least four Reference Banks which is caused by circumstances beyond its reasonable control. The Interest Rate for each Class of LIBOR Certificates for each Interest Accrual Period shall be determined by the Securities Administrator on each LIBOR Determination Date so long as the LIBOR Certificates are outstanding on the basis of LIBOR and the respective formulae appearing in footnotes corresponding to the LIBOR Certificates in the table relating to the Certificates in the Preliminary Statement. The Securities Administrator shall not have any liability or responsibility to any Person for its inability, following a good-faith reasonable effort, to obtain quotations from the Reference Banks or to determine the arithmetic mean referred to in the definition of LIBOR, all as provided for in this Section 4.04 and the definition of LIBOR. The establishment of LIBOR and each Interest Rate for the LIBOR Certificates by the Securities Administrator shall (in the absence of manifest error) be final, conclusive and binding upon each Holder of a Certificate and the Trustee.

  • Definitions of Key Terms Relating to Additional Rent As used in this Article 4, the following terms shall have the meanings hereinafter set forth:

  • Remedies relating to Accounts Upon the occurrence of an Event of Default and during the continuation thereof, whether or not the Administrative Agent has exercised any or all of its rights and remedies hereunder, (i) each Grantor will promptly upon request of the Administrative Agent instruct all account debtors to remit all payments in respect of Accounts to a mailing location selected by the Administrative Agent and (ii) the Administrative Agent shall have the right to enforce any Grantor’s rights against its customers and account debtors, and the Administrative Agent or its designee may notify any Grantor’s customers and account debtors that the Accounts of such Grantor have been assigned to the Administrative Agent or of the Administrative Agent’s security interest therein, and may (either in its own name or in the name of a Grantor or both) demand, collect (including without limitation by way of a lockbox arrangement), receive, take receipt for, sell, xxx for, compound, settle, compromise and give acquittance for any and all amounts due or to become due on any Account, and, in the Administrative Agent’s discretion, file any claim or take any other action or proceeding to protect and realize upon the security interest of the holders of the Secured Obligations in the Accounts. Each Grantor acknowledges and agrees that the Proceeds of its Accounts remitted to or on behalf of the Administrative Agent in accordance with the provisions hereof shall be solely for the Administrative Agent’s own convenience and that such Grantor shall not have any right, title or interest in such Accounts or in any such other amounts except as expressly provided herein. The Administrative Agent and the holders of the Secured Obligations shall have no liability or responsibility to any Grantor for acceptance of a check, draft or other order for payment of money bearing the legend “payment in full” or words of similar import or any other restrictive legend or endorsement or be responsible for determining the correctness of any remittance. Each Grantor hereby agrees to indemnify the Administrative Agent and the holders of the Secured Obligations from and against all liabilities, damages, losses, actions, claims, judgments, costs, expenses, charges and reasonable attorneys’ fees suffered or incurred by the Administrative Agent or the holders of the Secured Obligations (each, an “Indemnified Party”) because of the maintenance of the foregoing arrangements except as relating to or arising out of the gross negligence or willful misconduct of an Indemnified Party or its officers, employees or agents. In the case of any investigation, litigation or other proceeding, the foregoing indemnity shall be effective whether or not such investigation, litigation or proceeding is brought by a Grantor, its directors, shareholders or creditors or an Indemnified Party or any other Person or any other Indemnified Party is otherwise a party thereto.

Time is Money Join Law Insider Premium to draft better contracts faster.