Monetary Damages In the event that the Partnership breaches its obligations set forth in Article 2, Article 3, or Article 6 with respect to a Protected Partner the Protected Partner’s sole right shall be to receive from the Partnership, and the Partnership shall pay to such Protected Partner as damages, an amount equal to:
(a) in the case of a violation of Articles 3 or 0, xxx xxxxxxxxx xxxxxxx, xxxxx and local income taxes incurred by the Protected Partner or an Indirect Owner as a result of the income or gain allocated to, or otherwise recognized by, such Protected Partner with respect to its Units by reason of such breach;
(b) in the case of a violation of Article 0, xxx xxxxxxxxx xxxxxxx xxxxx, and local income taxes incurred by the Protected Partner or an Indirect Owner with respect the Excess Protected Gain incurred with respect to the Gain Limitation Property that is allocable to such Protected Partner under the Partnership Agreement and Section 2.3 hereof (computed without regard to the principles set forth in the parenthetical in the first paragraph of Section 2.1); plus in the case of either (a) or (b), an amount equal to the aggregate federal, state, and local income taxes payable by the Protected Partner or an Indirect Owner as a result of the receipt of any payment required under this Section 4.1. For purposes of computing the amount of federal, state, and local income taxes required to be paid by a Protected Partner (or Indirect Owner), (i) any deduction for state income taxes payable as a result thereof actually allowed in computing federal income taxes shall be taken into account, and (ii) a Protected Partner’s (or Indirect Owner’s) tax liability shall be computed using the highest federal, state and local marginal income tax rates that would be applicable to such Protected Partner’s (or Indirect Owner’s) taxable income (taking into account the character and type of such income or gain) for the year with respect to which the taxes must be paid, without regard to any deductions, losses or credits that may be available to such Protected Partner (or Indirect Owner) that would reduce or offset its actual taxable income or actual tax liability if such deductions, losses or credits could be utilized by the Protected Partner (or Indirect Owner) to offset other income, gain or taxes of the Protected Partner(or Indirect Owner), either in the current year, in earlier years, or in later years).
Property Damage Lessee shall obtain and maintain insurance coverage on all of Lessee's personal property, Trade Fixtures, and Lessee Owned Alterations and Utility Installations. Such insurance shall be full replacement cost coverage with a deductible of not to exceed $1,000 per occurrence. The proceeds from any such insurance shall be used by Lessee for the replacement of personal property, Trade Fixtures and Lessee Owned Alterations and Utility Installations. Lessee shall provide Lessor with written evidence that such insurance is in force.
Damages Should the registration or the effectiveness thereof required by Sections 5.1 and 5.2 hereof be delayed by the Company or the Company otherwise fails to comply with such provisions, the Holder(s) shall, in addition to any other legal or other relief available to the Holder(s), be entitled to obtain specific performance or other equitable (including injunctive) relief against the threatened breach of such provisions or the continuation of any such breach, without the necessity of proving actual damages and without the necessity of posting bond or other security.
Violation; liability for unpaid wages; liquidated damages In the event of any violation of the clause set forth in paragraph (1.) of this section, the contractor and any subcontractor responsible therefor shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable to the United States (in the case of work done under contract for the District of Columbia or a territory, to such District or to such territory), for liquidated damages. Such liquidated damages shall be computed with respect to each individual laborer or mechanic, including watchmen and guards, employed in violation of the clause set forth in paragraph (1.) of this section, in the sum of $10 for each calendar day on which such individual was required or permitted to work in excess of the standard workweek of forty hours without payment of the overtime wages required by the clause set forth in paragraph (1.) of this section.
Contingent Liability Where we effect or arrange a Transaction, you should note that, depending upon the nature of the Transaction, you may be liable to make further payments when the Transaction fails to be completed or upon the earlier settlement or closing out of your position. You may be required to make further variable payments by way of margin against the purchase price of the investment, instead of paying (or receiving) the whole purchase (or sale) price immediately. The movement in the market price of your investment will affect the amount of margin payment you will be required to make. You need to monitor your margin levels on a daily basis. You agree to pay us on demand such sums by way of margin as are required from time to time as we may in our discretion reasonably require for the purpose of protecting ourselves against loss or risk of loss on present, future or contemplated Transactions under this Agreement. Please note that in the event that you fail to meet a margin call, we may immediately close out the position. Margin must be paid in cash in currency acceptable by us, as requested from time to time by the Company. Cash Margin paid to us is held as client money in accordance with the requirements of the Client Money Rules. Margin deposits shall be made by wire transfer, credit card, e-wallet or by such other means as The Company may direct. If there is an Event of Default or this Agreement terminates, we shall set-off the balance of cash margin owed by us to you against your obligations (as reasonably valued by us). The net amount, if any, payable between us following such set-off, shall take into account the Liquidation Amount payable under Clause 15 (Netting). You agree to execute such further documents and to take such further steps as we may reasonably require perfecting our security interest over and obtain legal title to the Secured Obligations. You undertake neither to create nor to have outstanding any security interest whatsoever over, nor to agree to assign or transfer, any of the cash margin transferred to us, except a lien routinely imposed on all securities in a clearing system in which such securities may be held. In addition, and without prejudice to any rights to which we may be entitled under this Agreement or any Applicable Regulations, we shall have a general lien on all cash held by us or our Associates or our nominees on your behalf until the satisfaction of the Secured Obligations.
Casualty Damage 18.1 Tenant shall give immediate notice (by telephone, confirmed in writing) to Landlord of any damage caused to the Premises by fire or other casualty, and if Landlord does not elect to terminate this Lease as provided in Section 18.2, Landlord shall proceed with reasonable diligence and at its sole cost and expense to rebuild and repair the Building and/or the Premises, as the case may be, but Landlord shall not be obligated to expend for such rebuilding and repair any amount in excess of the amount of the insurance proceeds actually recovered by Landlord and made available by any Superior Lessor or Superior Mortgagee as a result of such loss.
18.2 If the Building or the Premises shall be destroyed or substantially damaged by a casualty not covered by Landlord’s insurance, or if 25% or more of the Premises is damaged or rendered untenantable by a casualty covered by Landlord’s insurance, or if the Premises are not affected but 25% of the Building or such portion of the Common Facilities as shall render the Premises or the Building untenantable is damaged or rendered untenantable, then in any such event Landlord may elect either to terminate this Lease or to proceed to rebuild and repair the Premises or that portion of the Building so damaged. Landlord shall give written notice to Tenant of such election within 90 days after the occurrence of such casualty, or within 30 days after the adjustment of the insurance settlement, whichever is later. In the event that such notice of termination shall be given, this Lease shall terminate as of the date provided in such notice of termination (whether or not the Term shall have commenced) with the same effect as if that date were the Expiration Date, without prejudice, however, to Landlord’s rights and remedies against Tenant under the terms of this Lease. If at any time prior to Landlord giving the aforesaid notice of termination or commencing the repair pursuant to Section 18.1, there shall be a Successor Landlord, such Successor Landlord shall have a further period of 60 days from the date of so taking possession to terminate this Lease by notice to Tenant and in the event that such a notice of termination shall be given, this Lease shall terminate as of the date provided in such notice of termination (whether or not the Term shall have been commenced) if Tenant is not occupying any portion of the Premises or otherwise as of the date provided in such notice, with the same effect as if that date were the Expiration Date, without prejudice, however, to Landlord’s rights against Tenant under the terms of this Lease.
18.3 Subject to the provisions of Section 18.1, Landlord’s obligation to rebuild and repair under this Article XVIII shall in any event be limited to restoring Landlord’s Work, as described in the Work Letter, to substantially the condition in which the same existed prior to the casualty, and to proceed, at the sole cost and expense of Tenant, to rebuild, repair and restore Tenant’s Work and any additional Improvements made by Tenant during the Term, all to substantially the condition existing prior to such casualty.
18.4 During the period from the occurrence of the casualty until Landlord’s repairs are completed, the Basic Rent payable pursuant to Article V and Additional Rent payable pursuant to Articles VI and VII shall be abated in that proportion which the Premises area rendered untenantable bears to the entire Premises area; provided, however, there shall be no abatement of any other charges or items of Additional Rent provided for herein to be paid by Tenant; and further provided, however, that should Tenant or anyone claiming through or under Tenant occupy a portion of the Premises during the period the repair work is taking place and prior to the date the Premises are no longer untenantable, the Rent allocable to such reoccupied portion, based upon the proportion which the reoccupied portion of the Premises bears to the total area of the Premises, shall be payable by Tenant from the date of such occupancy.
18.5 Landlord shall not the liable for any inconvenience or annoyance to Tenant or injury to the business of Tenant resulting in any way from any such damage by fire or other casualty or the repair thereof.
18.6 Notwithstanding any of the foregoing provisions of this Article, if, by reason of any negligence or willful act on the part of Tenant or any of its employees, agents, licensees, invitees or contractors, either (a) Landlord or the Superior Lessor or the Superior Mortgagee shall be unable to collect all of the insurance proceeds (including rent insurance proceeds) applicable to damage or destruction of the Premises or the Building or the Project by fire or other casualty or (b) the Premises or the Building or the Project shall be damaged or destroyed or rendered completely or partially untenantable on account of fire or other casualty then, without prejudice to any other remedy which may be available against Tenant, the abatement of rent provided for in Section 18.4 shall not be effective to the extent of the uncollected insurance proceeds.
CAP ON MONETARY LIABILITY EXCEPT FOR DAMAGES ARISING OUT OF LIABILITY WHICH CANNOT BE LAWFULLY EXCLUDED OR LIMITED, OR , THE TOTAL AGGREGATE LIABILITY OF EITHER PARTY FOR ANY AND ALL CLAIMS AGAINST THE OTHER PARTY UNDER THIS AGREEMENT, WHETHER ARISING UNDER OR RELATED TO BREACH OF CONTRACT, TORT (INCLUDING NEGLIGENCE), STRICT LIABILITY, OR ANY OTHER LEGAL OR EQUITABLE THEORY, SHALL NOT EXCEED THE AMOUNT OF ALL PAYMENTS ACTUALLY RECEIVED BY NEOGOV FROM RESELLER IN CONNECTION WITH YOUR SERVICES IN THE 12 MONTH PERIOD PRECEDING THE DATE OF THE EVENT INITIALLY GIVING RISE TO SUCH LIABILITY. THE EXISTENCE OF ONE OR MORE CLAIMS WILL NOT ENLARGE THE LIMIT.
Delay Damages If the Commercial Operation Date is not achieved by the date set forth therefor in Section 3.1(a) (as extended pursuant to Section 3.1(c)), Seller shall pay to Buyer damages for each month from and after such date until the Commercial Operation Date at the rate of $1.50 per kwh of Contract Maximum Amount up to a maximum of twelve (12) months of delay, pro rated for partial months (“Delay Damages”). Delay Damages shall be due under this Section 3.2(a) without regard to whether Buyer exercises its right to terminate this Agreement pursuant to Section 9.3; provided, however, that if Buyer exercises its right to terminate this Agreement under Section 9.3, Delay Damages shall be due and owing to the extent that such Delay Damages were due and owing at the date of such termination. If the Facility has not achieved the Commercial Operation by the date set forth therefor in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), for any reason, Seller shall have the right to terminate this Agreement at any time after that deadline date (as so extended) until either the Facility achieves the Commercial Operation Date or Buyer terminates this Agreement under Section 9.3 (regardless of whether or not Seller elected to continue to construct the Project). In the event Seller so terminates this Agreement, Seller shall be liable to Buyer on the date of such termination for (x) the entire amount of Delay Damages that would otherwise accrue (or have accrued) by such date plus (y) the undrawn amount of any Development Period Security provided to Buyer by Seller; provided, however, that if Seller terminates this Agreement on the deadline set forth for the Commercial Operation Date in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), Seller shall not be required to pay any Delay Damages hereunder but shall forfeit the Development Period Security. Subject to the foregoing sentence, neither Party shall have any liability to the other Party with respect to a termination of this Agreement by Seller under this Section 3.2(b). Each Party agrees and acknowledges that (i) the damages that Buyer would incur due to Seller’s delay in achieving the Commercial Operation Date would be difficult or impossible to predict with certainty, and (ii) it is impractical and difficult to assess actual damages in the circumstances stated, and therefore the Delay Damages and other damages as agreed to by the Parties and set forth herein are a fair and reasonable calculation of such damages. Notwithstanding the foregoing, this Article shall not limit the amount of damages payable to Buyer if this Agreement is terminated by Buyer as a result of Seller’s failure to achieve the Commercial Operation Date. Any such termination damages shall be determined in accordance with Article 9. By the tenth (10th) day following the end of the calendar month in which Delay Damages first become due and continuing by the tenth (10th) day of each calendar month during the period in which Delay Damages accrue (and the following months if applicable), Buyer shall deliver to Seller an invoice showing Buyer’s computation of such damages and any amount due Buyer in respect thereof for the preceding calendar month. No later than ten (10) days after receiving such an invoice, Seller shall pay to Buyer, by wire transfer of immediately available funds to an account specified in writing by Buyer or by any other means agreed to by the Parties in writing from time to time, the amount set forth as due in such invoice. If Seller fails to pay such amounts when due, Buyer may draw upon the Development Period Security for payment of such Delay Damages, and Buyer may exercise any other remedies available for Seller’s default hereunder.
Contingent Liabilities Assume, guarantee, become liable as a surety, endorse, contingently agree to purchase, or otherwise be or become liable, directly or indirectly (including, but not limited to, by means of a maintenance agreement, an asset or stock purchase agreement, or any other agreement designed to ensure any creditor against loss), for or on account of the obligation of any person or entity, except by the endorsement of negotiable instruments for deposit or collection or similar transactions in the ordinary course of the Company’s business.
Liquidated damages, attorney's fees, waiver of vendor's liability, and waiver of statutes of limitations clauses should also be deleted or qualified with "to the extent permitted by the Constitution and laws of State of Texas." Not a negotiable term. Failure to agree will render your proposal non-responsive and it will not be considered. Do you agree to these terms? 64 Remedies The parties shall be entitled to exercise any right or Yes, I Agree remedy available to it either at law or in equity, subject to the choice of law, venue and service of process clauses limitations agreed herein. Nothing in this agreement shall commit the TIPS to an arbitration resolution of any disagreement under any circumstances. Any Claim arising out of or related to the Contract, except for those specifically waived under the terms of the Contract, may, after denial of the Board of Directors, be subject to mediation at the request of either party. Any issues not resolved hereunder MAY be referred to non-binding mediation to be conducted by a mutually agreed upon mediator as a prerequisite to the filing of any lawsuit over such issue(s). The parties shall share the mediator’s fee and any associated filing fee equally. Mediation shall be held in Camp or Xxxxx County, Texas. Agreements reached in mediation shall be reduced to writing, and will be subject to the approval by the District's Board of Directors, signed by the Parties if approved by the Board of Directors, and, if signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Do you agree to these terms? 65 Remedies Explanation of No Answer 66 Choice of Law The agreement between the Vendor and TIPS/ESC Yes Region 8 and any addenda or other additions resulting from this procurement process, however described, shall be governed by, construed and enforced in accordance with the laws of the State of Texas, regardless of any conflict of laws principles. THIS DOES NOT APPLY to a vendor's agreement entered into with a TIPS Member, as the Member may be located outside Texas. Not a negotiable term. Failure to agree will render your proposal non-responsive and it will not be considered. Do you agree to these terms?
