Price Schedule, Payment Terms and Billing, and Price Adjustments (a) Price Schedule: Price Schedule under this Contract is set forth in Exhibit B.
Data Universal Number System (DUNS) number Requirement Grantee will provide their valid DUNS number contemporaneous with execution of this Agreement.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
Unit Prices If unit prices are stated in the Contract Documents or subsequently agreed upon, and if the quantities originally contemplated are so changed in a Change Order that application of the agreed unit prices to the quantities of work proposed will cause substantial inequity to the Owner or the Contractor, the applicable unit prices shall be equitably adjusted as provided in the Special Conditions or as agreed to by the parties and incorporated into the Change Order.
Required Vendor Sales Reporting By responding to this Solicitation, you agree to report to TIPS all sales made under any awarded Agreement with TIPS. Vendor is required to report all sales under the TIPS contract to TIPS. If the TIPS Member entity requesting a price from the awarded Vendor requests the TIPS contract, Vendor must include the TIPS Contract number on any communications with the TIPS Member entity. If awarded, you will be provided access to the Vendor Portal. To report sales, login to the TIPS Vendor Portal and click on the PO’s and Payments tab. Pages 3-7 of the Vendor Portal User Guide will walk you through the process of reporting sales to TIPS. Please refer to the TIPS Accounting FAQ’s for more information about reporting sales and if you have further questions, contact the Accounting Team at xxxxxxxxxx@xxxx-xxx.xxx. The Vendor or vendor assigned dealers are responsible for keeping record of all sales that go through the TIPS Agreement and submitting same to TIPS.
Contractor Sales Reporting Vendor Management Fee Contractor Reports Master Contract Sales Reporting. Contractor shall report total Master Contract sales quarterly to Enterprise Services, as set forth below. Master Contract Sales Reporting System. Contractor shall report quarterly Master Contract sales in Enterprise Services’ Master Contract Sales Reporting System. Enterprise Services will provide Contractor with a login password and a vendor number. The password and vendor number will be provided to the Sales Reporting Representative(s) listed on Contractor’s Bidder Profile. Data. Each sales report must identify every authorized Purchaser by name as it is known to Enterprise Services and its total combined sales amount invoiced during the reporting period (i.e., sales of an entire agency or political subdivision, not its individual subsections). The “Miscellaneous” option may be used only with prior approval by Enterprise Services. Upon request, Contractor shall provide contact information for all authorized purchasers specified herein during the term of the Master Contract. If there are no Master Contract sales during the reporting period, Contractor must report zero sales. Due dates for Master Contract Sales Reporting. Quarterly Master Contract Sales Reports must be submitted electronically by the following deadlines for all sales invoiced during the applicable calendar quarter: March 31: April 30 June 30: July 31 September 30: October 31 December 31: January 31 Vendor Management Fee. Contractor shall pay to Enterprise Services a vendor management fee (“VMF”) of 1.50 percent on the purchase price for all Master Contract sales (the purchase price is the total invoice price less applicable sales tax). The sum owed by Contractor to Enterprise Services as a result of the VMF is calculated as follows: Amount owed to Enterprise Services = Total Master Contract sales invoiced (not including sales tax) x .0150. The VMF must be rolled into Contractor’s current pricing. The VMF must not be shown as a separate line item on any invoice unless specifically requested and approved by Enterprise Services. Enterprise Services will invoice Contractor quarterly based on Master Contract sales reported by Contractor. Contractors are not to remit payment until they receive an invoice from Enterprise Services. Contractor’s VMF payment to Enterprise Services must reference this Master Contract number, work request number (if applicable), the year and quarter for which the VMF is being remitted, and the Contractor’s name as set forth in this Master Contract, if not already included on the face of the check. Failure to accurately report total net sales, to submit a timely usage report, or remit timely payment of the VMF, may be cause for Master Contract termination or the exercise of other remedies provided by law. Without limiting any other available remedies, the Parties agree that Contractor’s failure to remit to Enterprise Services timely payment of the VMF shall obligate Contractor to pay to Enterprise Services, to offset the administrative and transaction costs incurred by the State to identify, process, and collect such sums. The sum of $200.00 or twenty-five percent (25%) of the outstanding amount, whichever is greater, or the maximum allowed by law, if less. Enterprise Services reserves the right, upon thirty (30) days advance written notice, to increase, reduce, or eliminate the VMF for subsequent purchases, and reserves the right to renegotiate Master Contract pricing with Contractor when any subsequent adjustment of the VMF might justify a change in pricing. Annual Master Contract Sales Report. Upon request, Contractor shall provide to Enterprise Services a detailed annual Master Contract sales report. Such report shall include, at a minimum: Product description, part number or other Product identifier, per unit quantities sold, and Master Contract price. This report must be provided in an electronic format that can be read by compatible with MS Excel. Small Business Inclusion. Upon Request by Enterprise Services, Contractor shall provide, within thirty (30) days, an Affidavit of Amounts Paid. Such Affidavit of Amounts Paid either shall state, if applicable, that Contractor still maintains its MWBE certification or state that its subcontractor(s) still maintain(s) its/their MWBE certification(s) and specify the amounts paid to each certified MWBE subcontractor under this Master Contract. Contractor shall maintain records supporting the Affidavit of Amounts Paid in accordance with this Master Contract’s records retention requirements.
Contract Price and Payment In consideration of the Contractor's due and proper performance of its obligations under the Contract, the Contractor may charge the Authority or, as the case may be, any Beneficiary the Contract Price in accordance with this Clause 6. The only sums payable by the Authority or any Beneficiary to the Contractor for the provision of the Services shall be the Contract Price. All other costs, charges, fees and expenses of whatever kind arising out of or in connection with the Contract shall be the responsibility of the Contractor. In accordance with the Contract, where the Contractor is required to provide Deliverables, the Authority or any Beneficiary shall be entitled to withhold payment of the Contract Price pending receipt and acceptance of the Deliverables in accordance with the Specification. Unless otherwise agreed in writing by the Authority or any Beneficiary and the Contractor, within 15 days of the end of each calendar month, the Contractor shall invoice the Authority or, as the case may be, any Beneficiary for any Services provided by the Contractor in that calendar month. Such invoice shall be rendered on the Contractor's own invoice form clearly marked with the Authority’s or the Beneficiary's order number (if any). Invoices must show the period to which they relate and the aspects of the Services for which payment is claimed together with the agreed charging rates and any other details the Authority or the Beneficiary may require. Failure to provide such information will entitle the Authority or the Beneficiary to delay payment of the Contract Price until such information is provided. Subject to Clauses 6.3 and 6.6, the Authority or any Beneficiary shall pay any invoice submitted by the Contractor in accordance with Clause 6.4 within 30 days of receipt by the Authority or the Beneficiary of such invoice. The Authority or the Beneficiary shall pay such invoice(s) by BACS (Bank Automated Clearing System) if it so chooses or any alternate means as agreed between the Authority or the Beneficiary and the Contractor. The Authority and any Beneficiary shall be entitled to deduct from any monies due or to become due to the Contractor any monies owing to the Authority or the Beneficiary from the Contractor. Where the performance of the Contractor does not meet the required standard then a deduction as set out in the Specification or as agreed by the Parties may be made. Except where otherwise stated in the Order, the Contract Price is exclusive of VAT which shall be payable, if applicable, by the Authority or any Beneficiary in addition to such Contract Price. The invoice provided to the Authority or any Beneficiary by the Contractor in accordance with Clause 6.4 shall show the VAT calculations separately. The Contractor will keep accurate books and records in relation to the provision of the Services in accordance with sound and prudent financial management. All such books and records shall be made available to the Authority at regular intervals of not less than quarterly. In the event of the Authority or any Beneficiary breaching Clause 6.5, the Contractor shall be entitled to charge interest on the outstanding amount owed by the Authority or such Beneficiary in accordance with the Late Payment of Commercial Debts (Interest) Act 1998. Subject to Clauses 6.12 and 6.13, the Contract Price shall not be subject to any increase whatsoever by the Contractor during the Contract Period. In the event that the Contract is varied under Clauses 22 or 23 in such a way as to affect the Contract Price and if agreement between the Parties cannot be reached on the adjustment to the Contract Price within 3 months both Parties shall jointly act to resolve the dispute in accordance with Clause 24. If the adjusted Contract Price is not so agreed or certified until after such variation has taken effect, the Authority or any Beneficiary shall continue to pay the Contractor at the rate current prior to the variation but shall pay to the Contractor or be entitled to recover from the Contractor as the case may be such sum if any as is equal to the difference between the amount which should have been paid in accordance with the adjusted Contract Price and the amount which was actually paid. In the event that the Contract ends or is terminated otherwise than at the end of a complete year, the sum payable by the Authority or any Beneficiary under Clause 6 shall be one twelfth of the annual sum which would otherwise have been payable for the complete year for each completed month.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
JOC - PRICING OF Regular Hours Coefficient What is your regular hours coefficient for the RS Means Price Book? (FAILURE TO RESPOND PROHIBITS PART 2 JOC EVALUATION)
FORMAT AND CONTENT FOR REGISTRY OPERATOR MONTHLY REPORTING Registry Operator shall provide one set of monthly reports per gTLD, using the API described in draft-‐xxxxxx-‐icann-‐registry-‐interfaces, see Specification 2, Part A, Section 9, reference 5, with the following content. ICANN may request in the future that the reports be delivered by other means and using other formats. ICANN will use reasonable commercial efforts to preserve the confidentiality of the information reported until three (3) months after the end of the month to which the reports relate. Unless set forth in this Specification 3, any reference to a specific time refers to Coordinated Universal Time (UTC). Monthly reports shall consist of data that reflects the state of the registry at the end of the month (UTC).
