Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Maintenance and Support NCR Voyix is solely responsible for providing any maintenance and support services with respect to the Software as specified in the Agreement, or as required under applicable law. The parties acknowledge that Apple has no obligation whatsoever to furnish any maintenance and support services with respect to the Software.
Network Maintenance and Management 38.1 The Parties will work cooperatively to implement this Agreement. The Parties will exchange appropriate information (for example, maintenance contact numbers, network information, information required to comply with law enforcement and other security agencies of the government, escalation processes, etc.) to achieve this desired result.
38.2 Each Party will administer its network to ensure acceptable service levels to all users of its network services. Service levels are generally considered acceptable only when End Users are able to establish connections with little or no delay encountered in the network. Each Party will provide a twenty four (24)-hour contact number for Network Traffic Management issues to the other’s surveillance management center.
38.3 Each Party maintains the right to implement protective network traffic management controls, such as “cancel to”, “call gapping” or seven (7)-digit and ten (10)-digit code gaps, to selectively cancel the completion of traffic over its network, including traffic destined for the other Party’s network, when required to protect the public-switched network from congestion as a result of occurrences such as facility failures, switch congestion or failure or focused overload. Each Party shall immediately notify the other Party of any protective control action planned or executed.
38.4 Where the capability exists, originating or terminating traffic reroutes may be implemented by either Party to temporarily relieve network congestion due to facility failures or abnormal calling patterns. Reroutes shall not be used to circumvent normal trunk servicing. Expansive controls shall be used only when mutually agreed to by the Parties.
38.5 The Parties shall cooperate and share pre-planning information regarding cross-network call-ins expected to generate large or focused temporary increases in call volumes to prevent or mitigate the impact of these events on the public-switched network, including any disruption or loss of service to the other Party’s End Users. Facsimile (FAX) numbers must be exchanged by the Parties to facilitate event notifications for planned mass calling events.
38.6 Neither Party shall use any Interconnection Service provided under this Agreement or any other service related thereto or used in combination therewith in any manner that interferes with or impairs service over any facilities of AT&T-21STATE, its affiliated companies or other connecting telecommunications carriers, prevents any carrier from using its Telecommunications Service, impairs the quality or the privacy of Telecommunications Service to other carriers or to either Party’s End Users, causes hazards to either Party’s personnel or the public, damage to either Party’s or any connecting carrier’s facilities or equipment, including any malfunction of ordering or billing systems or equipment. Upon such occurrence either Party may discontinue or refuse service, but only for so long as the other Party is violating this provision. Upon any such violation, either Party shall provide the other Party notice of the violation at the earliest practicable time.
38.7 AT&T TENNESSEE hereby commits to provide Disaster Recovery to CLEC according to the plan below.
38.7.1 AT&T TENNESSEE Disaster Recovery Plan
38.7.2 In the unlikely event of a disaster occurring that affects AT&T TENNESSEE’s long-term ability to deliver traffic to a CLEC, general procedures have been developed by AT&T TENNESSEE to hasten the recovery process in accordance with the Telecommunications Service Priority (TSP) Program established by the FCC to identify and prioritize telecommunication services that support national security or emergency preparedness (NS/EP) missions. A description of the TSP Program as it may be amended from time to time is available on AT&T TENNESSEE’s Wholesale – Southeast Region Web site. Since each location is different and could be affected by an assortment of potential problems, a detailed recovery plan is impractical. However, in the process of reviewing recovery activities for specific locations, some basic procedures emerge that appear to be common in most cases.
38.7.3 These general procedures should apply to any disaster that affects the delivery of traffic for an extended time period. Each CLEC will be given the same consideration during an outage, and service will be restored as quickly as possible. AT&T TENNESSEE reserves the right to make changes to these procedures as improvements become available or as business conditions dictate.
38.7.4 This plan will cover the basic recovery procedures that would apply to every CLEC.
Operation and Maintenance Manuals Receipts for transmittal of Operation and Maintenance Manuals, Brochures and Data to the Design Professional (or Commissioning Agent) as required by Section 6.1.1.5.
Maintenance and Insurance (a) The Company shall maintain or cause to be maintained, at its own expense, all of its assets and properties in good working order and condition, making all necessary repairs thereto and renewals and replacements thereof.
(b) The Company shall maintain or cause to be maintained, at its own expense, insurance in form, substance and amounts (including deductibles), which the Company deems reasonably necessary to the Company's business, (i) adequate to insure all assets and properties of the Company, which assets and properties are of a character usually insured by persons engaged in the same or similar business against loss or damage resulting from fire or other risks included in an extended coverage policy; (ii) against public liability and other tort claims that may be incurred by the Company; (iii) as may be required by the Transaction Documents and/or applicable law and (iv) as may be reasonably requested by Secured Party, all with adequate, financially sound and reputable insurers.
Maintenance and Inspection Consultant shall maintain complete and accurate records with respect to all costs and expenses incurred under this Agreement. All such records shall be clearly identifiable. Consultant shall allow a representative of City during normal business hours to examine, audit, and make transcripts or copies of such records and any other documents created pursuant to this Agreement. Consultant shall allow inspection of all work, data, documents, proceedings, and activities related to the Agreement for a period of three (3) years from the date of final payment under this Agreement.
Contract Monitoring The criminal background checks required by this rule shall be national in scope, and must be conducted at least once every three (3) years. Contractor shall make the criminal background checks required by Paragraph IV.G.1 available for inspection and copying by DRS personnel upon request of DRS.
Personnel, Office Space, and Facilities of Manager The Manager at its own expense shall furnish or provide and pay the cost of such office space, office equipment, office personnel, and office services as the Manager requires in the performance of its investment advisory and other obligations under this Agreement.
Use of Subservicers and Subcontractors (a) The Master Servicer shall cause any Subservicer used by the Master Servicer (or by any Subservicer) for the benefit of the Depositor to comply with the provisions of Section 3.16 and this Article XI to the same extent as if such Subservicer were the Master Servicer (except with respect to the Master Servicer's duties with respect to preparing and filing any Exchange Act Reports or as the Certifying Person). The Master Servicer shall be responsible for obtaining from each Subservicer and delivering to the Depositor any servicer compliance statement required to be delivered by such Subservicer under Section 3.16, any assessment of compliance and attestation required to be delivered by such Subservicer under Section 11.07 and any certification required to be delivered to the Certifying Person under Section 11.05 as and when required to be delivered. As a condition to the succession to any Subservicer as subservicer under this Agreement by any Person (i) into which such Subservicer may be merged or consolidated, or (ii) which may be appointed as a successor to any Subservicer, the Master Servicer shall provide to the Depositor, at least 15 calendar days prior to the effective date of such succession or appointment, (x) written notice to the Depositor of such succession or appointment and (y) in writing and in form and substance reasonably satisfactory to the Depositor, all information reasonably requested by the Depositor in order to comply with its reporting obligation under Item 6.02 of Form 8-K.
(b) It shall not be necessary for the Master Servicer, any Subservicer or the Trustee to seek the consent of the Depositor or any other party hereto to the utilization of any Subcontractor. The Master Servicer or the Trustee, as applicable, shall promptly upon request provide to the Depositor (or any designee of the Depositor, such as the Master Servicer or administrator) a written description (in form and substance satisfactory to the Depositor) of the role and function of each Subcontractor utilized by such Person (or in the case of the Master Servicer or any Subservicer), specifying (i) the identity of each such Subcontractor, (ii) which (if any) of such Subcontractors are "participating in the servicing function" within the meaning of Item 1122 of Regulation AB, and (iii) which elements of the Servicing Criteria will be addressed in assessments of compliance provided by each Subcontractor identified pursuant to clause (ii) of this paragraph. As a condition to the utilization of any Subcontractor determined to be a Reporting Subcontractor, the Master Servicer or the Trustee, as applicable, shall cause any such Subcontractor used by such Person (or in the case of the Master Servicer or any Subservicer) for the benefit of the Depositor to comply with the provisions of Sections 11.07 and 11.09 of this Agreement to the same extent as if such Subcontractor were the Master Servicer (except with respect to the Master Servicer's duties with respect to preparing and filing any Exchange Act Reports or as the Certifying Person) or the Trustee, as applicable. The Master Servicer or the Trustee, as applicable, shall be responsible for obtaining from each Subcontractor and delivering to the Depositor and the Master Servicer, any assessment of compliance and attestation required to be delivered by such Subcontractor under Section 11.05 and Section 11.07, in each case as and when required to be delivered.
Quality Management System Supplier hereby undertakes, warrants and confirms, and will ensue same for its subcontractors, to remain certified in accordance with ISO 9001 standard or equivalent. At any time during the term of this Agreement, the Supplier shall, if so instructed by ISR, provide evidence of such certifications. In any event, Supplier must notify ISR, in writing, in the event said certification is suspended and/or canceled and/or not continued.
