Equipment Maintenance If this Contract involves computer or telecommunications hardware or other mechanical or electrical Equipment maintenance (use of the word "Equipment" means all the foregoing) as a Deliverable, then, during the warranty period and during any period covered by annual maintenance, the Contractor will provide Equipment maintenance to keep the Equipment in or restore the Equipment to good working order. This maintenance will include preventative and remedial maintenance, installation of safety changes, and installation of engineering changes based upon the specific needs of the individual item of Equipment. This maintenance will also include the repair, replacement, or exchange deemed necessary to keep the Equipment in good working order. For purposes of this Contract, Equipment restored to good working condition means Equipment that performs in accordance with the manufacturer's published specifications. The Contractor will exert its best efforts to perform all fault isolation and problem determination attributed to the Equipment covered under this Contract. The following services are outside the scope of this Contract:
1. Repair and replacement work or increase in maintenance time as a result of damage or loss resulting from accident, casualty, neglect, misuse, or abuse if such is the State's fault (and beyond normal wear and tear), damage resulting from improper packing or failure to follow prescribed shipping instruction (If such is done by the State), failure of electrical power, air conditioning or humidity control, use of supplies not approved by the original manufacturer of the Equipment as describe or included in the Contractor's proposal, or causes other than ordinary use of Equipment.
2. All information necessary for the State to perform the maintenance, including but not limited to logic diagrams, maintenance manuals and system and unit schematics with all changes noted.
3. A listing of spare parts and their recommended replacement schedule that will enable the State to create a centralized inventory of spare parts.
Maintenance and Repairs (1) Except for matters specified under Paragraph 4 above and Paragraph 8A(3) below as being Landlord's obligation, Tenant shall, at Tenant's sole cost and expense, maintain the Premises in good order, condition and repair, ordinary wear and tear and damage by fire and casualty excepted, including: the interior surfaces of the ceilings, walls and floors; all doors and interior windows; furnishings installed within the Premises; all equipment installed by or at the expense of Tenant; and all plumbing, heating, ventilating, electrical and lighting facilities and fixtures; all landscaping, parking lots, fences and signs located within the Premises.
(2) In the event that Tenant fails to maintain the Premises in good order, condition and repair as required under this Lease, Landlord shall give Tenant prior written notice to do such acts as are required to so maintain the Premises. In the event that Tenant fails to commence such work within 30 days after written demand by Landlord, and diligently prosecute it to completion, then Landlord shall have the right, but shall not be obligated, to do such acts and expend such funds at the expense of Tenant as are reasonably required to perform such work. Landlord shall have no liability to Tenant for any reasonable damage, inconvenience or interference with Tenant's use of the Premises as a result of performing any such work.
(3) Landlord will maintain, repair and replace all structural components of the Premises and the roof of the Building, and if a repair, replacement or alteration or other change would be considered a capital improvement or replacement to the Premises under generally accepted accounting principles, then it shall be Landlord's responsibility to promptly make and pay for such repair, replacement, alteration or other change. The cost of any such capital improvement shall be amortized over the useful life of such item and Tenant agrees to pay its percentage share (which shall be determined by dividing the square footage of the Building by the square footage of all buildings benefitted by such improvement, including the Building) of the annual amortized amount. Such payment will be made by Tenant as set forth in Paragraph 4 above. Landlord shall do all acts required to comply with all applicable laws, ordinances, regulations and rules of any public authority relating to the Premises, except to the extent that the foregoing are solely a result of Tenant's use of the Premises. Tenant shall do all acts required to comply with all applicable laws, ordinances, regulations and rules of any public authority relating solely to Tenant's use of the Premises. If a repair is required as a result of Tenant's negligence and such repair cost is not covered by insurance proceeds, Tenant will pay for the cost of such repair. Notwithstanding anything in this Lease to the contrary, in the event that the need for repairs or the making of repairs (or both) which Landlord is obligated to effect at Landlord's expense renders a material portion of the Premises unusable for more than three consecutive business days, then Tenant shall be entitled to an abatement of rent commencing with the fourth business day that the same are unusable; provided, however, that Tenant shall not be entitled to a pro rata abatement of rent under the foregoing due to unusability (i) caused directly or indirectly by any act or omission of Tenant or any of Tenant's servants, employees, agents, contractors, visitors or licensees, (ii) where Tenant makes a decoration, alteration, improvement or addition which directly causes such unusability, or (iii) where the repair in question is one which Tenant is obligated to furnish under the provisions of this Lease.
MAINTENANCE AND REPAIR; RULES Tenant will, at its sole expense, keep and maintain the Premises and appurtenances in good and sanitary condition and repair during the term of this Agreement and any renewal thereof. Without limiting the generality of the foregoing, Tenant shall:
(a) Not obstruct the driveways, sidewalks, courts, entry ways, stairs and/or halls, which shall be used for the purposes of ingress and egress only;
(b) Keep all windows, glass, window coverings, doors, locks and hardware in good, clean order and repair;
(c) Not obstruct or cover the windows or doors;
(d) Not leave windows or doors in an open position during any inclement weather;
(e) Not hang any laundry, clothing, sheets, etc. from any window, rail, porch or balcony nor air or dry any of same within any yard area or space;
(f) Not cause or permit any locks or hooks to be placed upon any door or window without the prior written consent of Landlord;
(g) Keep all air conditioning filters clean and free from dirt;
(h) Keep all lavatories, sinks, toilets, and all other water and plumbing apparatus in good order and repair and shall use same only for the purposes for which they were constructed. Tenant shall not allow any sweepings, rubbish, sand, rags, ashes or other substances to be thrown or deposited therein. Any damage to any such apparatus and the cost of clearing stopped plumbing resulting from misuse shall be borne by Tenant;
(i) And Tenant's family and guests shall at all times maintain order in the Premises and at all places on the Premises, and shall not make or permit any loud or improper noises, or otherwise disturb other residents;
(j) Keep all radios, television sets, stereos, phonographs, etc., turned down to a level of sound that does not annoy or interfere with other residents;
(k) Deposit all trash, garbage, rubbish or refuse in the locations provided therefor and shall not allow any trash, garbage, rubbish or refuse to be deposited or permitted to stand on the exterior of any building or within the common elements;
(l) Abide by and be bound by any and all rules and regulations affecting the Premises or the common area appurtenant thereto which may be adopted or promulgated by the Condominium or Homeowners' Association having control over them.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Installation and Maintenance Except for the bi‐directional and production metering equipment owned by the City, all equipment on Customer’s side of the delivery point, including the required disconnect device, shall be provided and maintained in satisfactory operating condition by Customer and shall remain the property and responsibility of the Customer. The City will bear no responsibility for the installation or maintenance of Customer’s equipment or for any damage to property as a result of any failure or malfunction thereof. The City shall not be liable, directly or indirectly for permitting or continuing to allow the interconnection of the Facility or for the acts or omissions of Customer or the failure or malfunction of any equipment of Customer that causes loss or injury, including death, to any party.
Aircraft Maintenance Operator shall, at its own expense, cause the Aircraft to be inspected, maintained, serviced, repaired, overhauled, and tested in accordance with FAR Part 91 so that the Aircraft will remain in good operating condition and in a condition consistent with its airworthiness certification and shall take such requirements into account in scheduling the Aircraft hereunder, including but not limited compliance with applicable airworthiness directives and service bulletins. Performance of maintenance, preventive maintenance or inspection shall not be delayed or postponed for the purpose of scheduling the Aircraft unless such maintenance or inspection can safely be conducted at a later time in compliance with applicable laws, regulations and requirements, and such delay or postponement is consistent with the sound discretion of the pilot-in-command. In the event that any non-standard maintenance is required during the term and will interfere with User’s requested or scheduled flights, Operator, or Operator’s pilot-in-command, shall notify User of the maintenance required, the effect on the ability to comply with User’s requested or scheduled flights and the manner in which the parties will proceed with the performance of such maintenance and conduct of such flight(s). In no event shall Operator be liable to User or any other person for loss, injury or damage occasioned by the delay or failure to furnish the Aircraft under this Agreement, whether or not maintenance-related.
Maintenance and Support NCR Voyix is solely responsible for providing any maintenance and support services with respect to the Software as specified in the Agreement, or as required under applicable law. The parties acknowledge that Apple has no obligation whatsoever to furnish any maintenance and support services with respect to the Software.
Maintenance Requirements The Contractor shall ensure and procure that at all times during the Maintenance Period, the Project Highway conforms to the maintenance requirements set forth in Schedule-E (the “Maintenance Requirements”).
Maintenance and Repair (a) Subject to Landlord’s limited obligations under subparagraph 6(a), by taking possession of the Premises, Tenant shall be deemed to have accepted the Premises as being in good order, condition and repair. Tenant shall, at Tenant’s sole cost and expense, keep the Premises and every part thereof in good condition and repair, including without limitation, the maintenance, repair and replacement of any storefront, doors, window casements, glazing, plumbing, pipes, electrical wiring and conduits, and the heating and air conditioning (“HVAC”) system. Tenant shall obtain a service contract for repairs and maintenance of the HVAC system and shall provide to Landlord a copy of the service contract along with written details of any and all scheduled and other repairs and maintenance performed on the HVAC system within ten (10) days of the date of such performance. Tenant shall, upon the expiration or sooner termination of this Lease, surrender the Premises to Landlord in good condition, broom clean, ordinary wear and tear and damage subject to Paragraph 24 excepted. Except for damage subject to Paragraph 24, any damage caused by Tenant’s use of the Premises shall be repaired at the sole cost and expense of Tenant.
(b) Except as specifically provided in subparagraph 6(a) above, Tenant shall repair and maintain the structural portions of the Building, including the exterior walls and roof. Landlord shall not be liable for Tenant’s failure to make such repairs or to perform any maintenance. There shall be no abatement of Rent and no liability of Landlord by reason of any injury to or interference with Tenant’s business arising from the making of any repairs, alterations or improvements in or to any portion of the Building or the Premises or in or to fixtures, appurtenances and equipment therein. Tenant waives any right to make repairs at Landlord’s expense under any law, statute or ordinance now or hereafter in effect.
(c) If Tenant refuses or neglects to repair or maintain the Premises, as required herein, to the reasonable satisfaction of Landlord, Landlord shall provide Tenant with written notice of any such refusal or neglect and Tenant shall repair any item mentioned in said notice within thirty (30) days thereafter. If Tenant has not made such repairs within the 30-day period, Landlord may make such repairs without liability to the Tenant for any loss or damage it may accrue to Tenant’s merchandise, fixtures or other property or to Tenant’s business by reason thereof and, upon completion thereof, Tenant shall pay Landlord’s costs for making such repairs upon presentation of a xxxx thereof. In the event Tenant does not pay such xxxx within ten (10) days of its receipt, such failure shall be an event of default hereunder, Landlord shall be entitled to utilize all of its remedies herein and such amount shall bear interest at the rate of eighteen percent (18%) per annum from the date of the notice. Notwithstanding the foregoing, in the event that Tenant in good faith disputes Landlord’s claim that Tenant has failed to repair or maintain any aspect of the Premises, then if Landlord makes any repairs, Tenant shall not be obligated to pay for the repairs or any interest thereon until the dispute is finally determined; provided, that Tenant shall deposit the disputed amount with the Landlord until the dispute is resolved.
Maintenance and Insurance (a) The Company shall maintain or cause to be maintained, at its own expense, all of its assets and properties in good working order and condition, making all necessary repairs thereto and renewals and replacements thereof.
(b) The Company shall maintain or cause to be maintained, at its own expense, insurance in form, substance and amounts (including deductibles), which the Company deems reasonably necessary to the Company's business, (i) adequate to insure all assets and properties of the Company, which assets and properties are of a character usually insured by persons engaged in the same or similar business against loss or damage resulting from fire or other risks included in an extended coverage policy; (ii) against public liability and other tort claims that may be incurred by the Company; (iii) as may be required by the Transaction Documents and/or applicable law and (iv) as may be reasonably requested by Secured Party, all with adequate, financially sound and reputable insurers.
