Engineers Responsibility The Engineer shall be responsible for the accuracy of its work and shall promptly make necessary revisions or corrections resulting from its errors, omissions, or negligent acts without compensation. The Engineer will not be relieved of the responsibility for subsequent correction of any such errors or omissions or for clarification of any ambiguities until after the construction phase of the project has been completed.
Seller’s Responsibility If the Seller determines that the Interface Problem is primarily attributable to the design of a Warranted Part, the Seller shall, if so requested by the Buyer and pursuant to the terms and conditions of Clause 12.1, correct the design of such Warranted Part to the extent of the Seller’s obligation as defined in Clause 12.1.
CONTRACTOR'S RESPONSIBILITY 1.1. The Basic Services to be performed by CONTRACTOR hereunder is the Citywide Landscape Maintenance. 1.2. The CONTRACTOR agrees to obtain and maintain throughout the period of this Agreement all such licenses as are required to do business in the State of Florida, the City of Naples, and in Xxxxxxx County, Florida, including, but not limited to, all licenses required by the respective state boards and other governmental agencies responsible for regulating and licensing the professional services to be provided and performed by the CONTRACTOR pursuant to this Agreement. 1.3. The CONTRACTOR agrees that, when the services to be provided hereunder relate to a professional service which, under Florida Statutes, requires a license, certificate of authorization or other form of legal entitlement to practice such services, it shall employ and/or retain only qualified personnel to provide such services. 1.4. CONTRACTOR agrees to employ and designate, in writing, within five (5) calendar days after receiving its Notice to Proceed, a qualified licensed professional to serve as the CONTRACTOR's project manager (hereinafter referred to as the "Project Manager"). The Project Manager shall be authorized and responsible to act on behalf of the CONTRACTOR with respect to directing, coordinating and administering all aspects of the services to be provided and performed under this Agreement. 1.5. The CONTRACTOR has represented to the OWNER that it has expertise in the type of professional services that will be required for the Project. The CONTRACTOR agrees that all services to be provided by CONTRACTOR pursuant to this Agreement shall be subject to the OWNER's review and approval and shall be in accordance with the generally accepted standards of professional practice in the State of Florida, as well as in accordance with all published laws, statutes, ordinances, codes, rules, regulations and requirements of any governmental agencies which regulate or have jurisdiction over the Project or the services to be provided and performed by CONTRACTOR hereunder. In the event of any conflicts in these requirements, the CONTRACTOR shall notify the OWNER of such conflict and utilize its best professional judgment to advise OWNER regarding resolution of the conflict. 1.6. CONTRACTOR agrees not to divulge, furnish or make available to any third person, firm or organization, without OWNER's prior written consent, or unless incident to the proper performance of the CONTRACTOR's obligations hereunder, or in the course of judicial or legislative proceedings where such information has been properly subpoenaed, any non-public information concerning the services to be rendered by CONTRACTOR hereunder, and CONTRACTOR shall require all of its employees, agents, subconsultants and subcontractors to comply with the provisions of this paragraph.
Buyer’s Responsibility Buyer shall obtain and maintain all distribution, transmission and interconnection rights and agreements (including all Governmental Authority approvals) required to enable transmission and delivery of electric energy at and after the Delivery Point.
The Publisher’s Responsibilities Subject always to the other provisions of this Clause below, the Publisher will undertake the production, publication and distribution of the Contribution and the Work in print and/or electronic form at its own expense and risk within a reasonable time after acceptance of the Work unless the Publisher is prevented from or delayed in doing so due to any circumstances beyond its reasonable control. The Publisher shall have the entire control of such production, publication and distribution determined in its sole discretion in relation to any and all editions and versions of the Contribution and the Work, including in respect of all the following matters: (a) distribution channels, including determination of markets; (b) determination of the range and functions of electronic formats and/or the number of print copies produced; (c) publication and distribution of the Contribution, the Work, or parts thereof as individual content elements, in accordance with market demand or other factors; (d) determination of layout and style as well as the standards for production; (e) setting or altering the list price, and allowing for deviations from the list price (if permitted under applicable jurisdiction); (f) promotion and marketing as the Publisher considers most appropriate. All rights, title and interest, including all intellectual property or related rights in the typography, design and/or look-and-feel of the Contribution shall remain the exclusive property of and are reserved to the Publisher. All illustrations and any other material or tangible or intangible property prepared at the expense of the Publisher including any marketing materials remain, as between the Parties, the exclusive property of the Publisher. The provisions of this subclause shall continue to apply notwithstanding any termination of, and/or any reversion of rights in the Contribution to the Author, under this Agreement. Without prejudice to the Publisher's termination and other rights hereunder including under the Clause "The Author's Responsibilities", it is agreed and acknowledged by the Parties that nothing in this Agreement shall constitute an undertaking on the part of the Publisher to publish the Contribution unless and until: (i) any and all issues in relation to the Work (including all necessary revisions, consents and permissions) raised by the Publisher have been resolved to the Publisher’s satisfaction, and (ii) the Publisher has given written notice of acceptance in writing of the final manuscript of the entire Work to the Editor. If following (i) and (ii) above the Publisher has not published the Contribution in any form within a reasonable period and the Author has given written notice to the Publisher requiring it to publish within a further reasonable period and the Publisher has failed to publish in any form, then the Author may terminate this Agreement by one month's written notice to the Publisher and all rights granted by the Author to the Publisher under this Agreement shall revert to the Author (subject to the provisions regarding any third party rights under any subsisting licence or sub-licence in accordance with the Clause "Termination"). The Author may also give such written notice requiring publication on the same terms as above if the Publisher has published the Contribution but subsequently ceases publishing the Contribution in all forms so that it is no longer available. This shall be the Author's sole right and remedy in relation to such non-publication and is subject always to the Author's continuing obligations hereunder including the Clause "Warranty".
Customer’s Responsibility The policies in this document apply to the use of Data by Customers, Redistributors and their End Customers. Customers are responsible for compliance with this policy by all members of the Customer’s Group and by all persons to whom they distribute Data where authorised to do so. Turquoise recommends that Customers make this Schedule available to all Subscribers to their services having access to Data which is subject to Charges, reporting requirements or usage restrictions.
Filing Responsibility PARTICIPANT ACKNOWLEDGES THAT IT IS PARTICIPANT’S SOLE RESPONSIBILITY, AND NOT THE CORPORATION’S, TO FILE A TIMELY ELECTION UNDER CODE SECTION 83(b), EVEN IF PARTICIPANT REQUESTS THE CORPORATION OR ITS REPRESENTATIVES TO MAKE THIS FILING ON HIS OR HER BEHALF.
SELLER’S RESPONSIBILITIES (a) Seller shall act in performance of this Agreement as an independent contractor and not as an agent for Company or the Government in performing this Agreement, maintaining complete control over its employees and all lower-tier subcontractors. Nothing contained in this Agreement or any lower-tier subcontract shall create any contractual relationship between any such lower-tier subcontractor and the Government or Company. Seller is solely responsible for the actions of itself and its lower-tier subcontractors, agents or employees. (b) Seller shall be responsible for all liability and related expenses resulting from (1) injury, death, damage to or loss of property or (2) violation of Part 1.12a Compliance with Laws, which is in any way connected with its performance of work under this Agreement. Seller's responsibility shall apply to activities of Seller, its agents, lower-tier subcontractors, or employees and such responsibility includes the obligation to indemnify, defend, and hold harmless the Government and the Company for Seller's conduct. However, such liability and indemnity does not apply to injury, death, or damage to property to the extent it arises from the negligent or willful misconduct of Company. (c) If Company’s costs are determined to be unallowable, its fee reduced, or it incurs any cost or damages as a result of Seller’s violation of applicable laws, orders, rules, regulations, or ordinances, or the submission of defective cost or pricing data, Company may make an equivalent reduction in amounts due Seller. (d) If Seller is a State agency, such as an Educational Institution, all liabilities and remedies shall be determined in accordance with the laws applicable to this Agreement under Part 1.2.
Owner’s Responsibility Proper preventative maintenance of the exterior and interior of the vehicle is the responsibility of the owner. See the owner’s manual(s) for proper care instructions. Defects or damage as a result of improper care or maintenance are not covered by this warranty agreement.
Contractor’s Responsibilities Unless stated specifically to the contrary in the tender with full supporting explanations, the contractor will be deemed to have concurred as a practical manufacturer with the design and layout of the works as being sufficient to ensure reliability and safety in operation, freedom from undue stresses and satisfactory performance in all other essentials as a working material.
