Equipment List 1. All items of equipment to be purchased with funds under this Contract must be itemized in Grantee’s equipment list as finally approved by the System Agency in the executed Contract. The equipment list must include: i. Description of the property; ii. Serial number or other identification number; iii. Source of funding for the property (including the Federal Assistance Identification Number); iv. Who holds title, v. Acquisition date and cost of the property;
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Equipment Location The Company recognizes that it is important when designing, constructing, and maintaining physical plant components, to have regard for the specific placement of equipment, with a view to the elimination of hazardous work situations. Accordingly, wherever practical to do so, new installations, or the rebuild of existing installations, will be designed accordingly.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
All new supplies equipment and services shall include manufacturer's minimum standard warranty unless otherwise agreed to in writing. Vendor shall be legally permitted to sell all products offered for sale to TIPS Members. All goods proposed and sold shall be new unless clearly stated in writing. The Vendor shall provide timely and accurate customer support for orders to TIPS Members as agreed by the Parties. Vendors shall respond to such requests within a commercially reasonable time after receipt of the request. If support andƒor training is a line item sold or packaged with a sale, support shall be as agreed with the TIPS Member. Most TIPS Members are tax exempt and the related laws andƒor regulations of the controlling jurisdiction(s) of the TIPS Member shall apply. No assignment of Agreement may be made without the prior notification of TIPS. Written approval of TIPS shall not be unreasonably withheld. Payment for delivered goods and services can only be made to the awarded Vendor, Vendor designated reseller or vendor assigned company.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Changes in Equipment, Systems, Etc USBFS reserves the right to make changes from time to time, as it deems advisable, relating to its systems, programs, rules, operating schedules and equipment, so long as such changes do not adversely affect the services provided to the Trust under this Agreement.
Equipment Use Lessee agrees that the Equipment will be operated by competent, qualified personnel in connection with Lessee's business for the purpose for which the Equipment was designed and in accordance with applicable operating instructions, laws, and government regulations, and that Lessee shall use all reasonable precautions to prevent loss or damage to the Equipment from fire and other hazards. Lessee shall procure and maintain in effect all orders, licenses, certificates, permits, approvals, and consents required by federal, state, or local laws or by any governmental body, agency, or authority in connection with the delivery, installation, use, and operation of the Equipment.
As to Equipment and Inventory Grantor hereby agrees that it shall: (a) keep all the Equipment and Inventory (other than Inventory in transit and Inventory sold in the ordinary course of business) at the places therefor specified in Section 3.1.1 or, upon 30 days' prior written notice to Agent, at such other places in a jurisdiction where all representations and warranties set forth in Article III (including Section 3.1.6) shall be true and correct, and all action required pursuant to the first sentence of Section 4.1.7 shall have been taken with respect to the Equipment and Inventory; (b) with respect to any Equipment or Inventory in the possession or control of any Third Party or any of Grantor's agents, notify such Third Party or agent of Agent's security interest in such Equipment or Inventory and, upon Agent's request following the occurrence and during the continuance of an Event of Default, direct such Third Party or agent to hold all such Equipment or Inventory for Agent's account and subject to Agent's instructions; (c) cause the Equipment to be maintained and preserved in the same condition, repair and working order as when new, ordinary wear and tear excepted, and in accordance with any manufacturer's manual; and forthwith, or in the case of any material loss or damage to any of the Equipment, as quickly as practicable after the occurrence thereof, make or cause to be made all repairs, replacements, and other improvements in connection therewith which are necessary or desirable to such end; and promptly furnish to Agent a statement respecting any loss or damage to any of the Equipment within ten (10) business days after Grantor obtains knowledge of any such loss or damage; and (d) pay promptly when due all property and other taxes, assessments and governmental charges or levies imposed upon, and all claims (including claims for labor, materials and supplies) against, the Equipment and Inventory, except to the extent the validity thereof is being contested in good faith by appropriate proceedings and for which adequate reserves in accordance with Generally Accepted Accounting Principles have been set aside.
