Material Project Documents (a) The Company shall at all times (i) perform and observe all of the covenants under the Material Project Documents to which it is a party and take reasonable actions to enforce all of its rights thereunder, other than to the extent the same could not reasonably be expected to have a Material Adverse Effect, (ii) subject to the provisions of clause (b) of this Section 9.8, maintain the System Leases (other than Leases constituting System Leases only pursuant to clause (5) of the definition thereof) in full force and effect, and (iii) maintain the Leases (other than the System Leases referred to in the foregoing clause (ii) of this Section 9.8(a)) to which it or any of its Subsidiaries is a party in full force and effect, except to the extent the same could not reasonably be expected to have a Material Adverse Effect.
(b) If the term of a Lease with the Company or one of its Subsidiaries expires and the Qualified Lessee under such Lease has either ceased operating the related assets or has ceased paying rent as required under the applicable Lease, the Company shall, or shall cause a Subsidiary, as applicable, to enter into a supplement or a new Lease with respect to the related leasehold assets with a Qualified Lessee that provides for rent that, when combined with all other expected revenue, will, in the reasonable judgment of the Company, as of the commencement date of such supplement or new Lease, generate sufficient revenue to satisfy the requirements of Section 9.9 and will not otherwise result in a materially worse position for the Company as compared to the terms of the applicable expired Lease. Each such new Lease shall have a term of at least five years. Notwithstanding the foregoing, if (i) such expired Lease relates to transmission and/or distribution assets that are not generating significant revenue, (ii) the failure to renew such Lease would not constitute a Material Adverse Effect and (iii) the Company reasonably believes it will generate sufficient revenue and hold sufficient assets (without giving effect to the leasehold assets with respect to such Lease) to satisfy the requirements of Section 9.9, then this Section 9.8(b) will not require a supplement or new lease with respect to such leasehold assets.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.
190 Contract Complete This contract is the final expression of the Parties' agreement. There are no understandings, agreements, or representations, expressed or implied, which are not specified in this contract.
Copies of Contract Documents to Contractor Without charge to the Contractor the Design Professional shall furnish to the Contractor up to five sets of completed Contract Documents in hardcopy, one set of reproducible and electronic background floor and reflected ceiling plan drawings and, if requested, one copy in read-only electronic format. The Contractor may obtain such additional sets of Contract Documents, as the Contractor deems necessary and shall pay the cost of reproduction of such additional sets to the Design Professional.
Complete Contract This Contract contains all the terms agreed upon by the Parties with respect to the subject matter of this Contract and supersedes all prior agreements, arrangements, and communications between the Parties concerning such subject matter, whether oral or written.
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
REPORT OF CONTRACT USAGE All fields of information shall be accurate and complete. The report is to be submitted electronically via electronic mail utilizing the template provided in Microsoft Excel 2003, or newer (or as otherwise directed by OGS), to the attention of the individual shown on the front page of the Contract Award Notification and shall reference the Group Number, Award Number, Contract Number, Sales Period, and Contractor's (or other authorized agent) Name, and all other fields required. OGS reserves the right to amend the report template without acquiring the approval of the Office of the State Comptroller or the Attorney General.
Material Safety Data Sheet Seller shall provide to Buyer with each delivery any Material Safety Data Sheet applicable to the work in conformance with and containing such information as required by the Occupational Safety and Health Act of 1970 and regulations promulgated thereunder or its State approved counterpart.
Tax Service Contract; Flood Certification Contract Each Mortgage Loan is covered by a paid in full, life of loan, tax service contract and a paid in full, life of loan, flood certification contract and each of these contracts is assignable to the Purchaser;
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
