Preliminaries Where prices are submitted by the contractor or nominated/selected sub contractor during the progress of the works in respect of contract instructions or in regard to a claim under the terms of the contract and notwithstanding the fact that such prices may be used in an interim payment certificate, there is to be no presumption of acceptance. Should the principal agent wish to accept any such prices prior to the issue of the final certificate, it will be in writing. Clause 31.9 is amended as follows: Payment shall be subject to the Employer giving the Contractor a Tax Invoice for the amount due. The Employer undertakes to ensure compliance with the administrative requirements of Sections 20 (2) and 21 (4) of the Value Added Tax Act (Act 89 of 1991). The Contractor agrees to the adoption of the self invoicing procedures and undertakes not to issue any tax invoices, debit or credit notes in respect of any transaction included in the Tax Invoices issued by the Employer. The above clauses shall constitute a written agreement between the parties as required in terms of the Value Added Tax Act (Act 89 of 1991).' 30 F: ……….… V: ….……… T: ….……... Item Adjustment to the contract value (Clause 32). 31 F: ……….… V: ….……… T: ….……... Item Recovery of expense and loss (Clause 33). 32 F: ……….… V: ….……… T: ….……... Item Final account and final payment (Clause 34). 33 F: ……….… V: ….……… T: ….……... Item Payment to other parties (Clause 35). 34 F: ……….… V: ….……… T: ….……... Item Carried to Collection R Section 1 Bill No. 1 Preliminaries R CANCELLATION Cancellation by Employer - Contractor's default (Clause 36). 35 F: ……….… V: ….……… T: ….……... Item Cancellation by Employer - Loss and damage (Clause 37). 36 F: ……….… V: ….……… T: ….……... Item Cancellation by Contractor - Employer's default (Clause 38). 37 F: ……….… V: ….……… T: ….……... Item Cancellation - Cessation of the works (Clause 39). 38 F: ……….… V: ….……… T: ….……... Item DISPUTE Dispute Settlement (Clause 40) 39 F: ……….… V: ….……… T: ….……... Item SUBSTITUTE PROVISIONS State Clauses (Clause 41) 40 F: ……….… V: ….……… T: ….……... Item CONTRACT VARIABLES The Schedule: Pre-Tender information (Clause 42). 41 F: ……….… V: ….……… T: ….……... Item Carried to Collection Section 1 Bill No. 1 Preliminaries
Specific Preliminaries C1. Proprietary branded products The contractor shall take delivery of, handle, store, use, apply and/or fix all proprietary branded products in strict accordance with the manufacturer's instructions after consultation with the manufacturer's authorised representative. 95 F: ……….… V: ….……… T: ….……... Item C2. Trade Names, etc. All materials, fittings, finishings, etc., specified hereinafter under a trade name, catalogue number or reference, must be exactly as described. The Architect's approval in writing must be obtained for the use of any alternative to the specification before the submission of tenders otherwise the specified materials, fittings, finishings, etc., will be assumed to have been allowed for in the tender. The Contractor must take delivery of, handle, store, use, apply and/or fix all proprietary branded products in strict accordance with the manufacturer's instructions after consultation with the manufacturer's authorised representative. 96 F: ……….… V: ….……… T: ….……... Item C3. Contractors responsibility The Employer, the Principal Agent and the other professional consultants shall not be responsible for any act or omission on the part of the Contractor which may result in any patent or latent defects, in materials or workmanship, breach or neglect of any local regulations. The Contractor shall at all times be responsible for any such neglect, deviation or wrong act, whether the same is discovered before or after the final certificate, or any other Certificate, has been approved. 97 F: ……….… V: ….……… T: ….……... Item Carried to Collection R Section 1 Bill No. 1 Preliminaries C4. Overtime Should overtime be required to be worked for any reason whatsoever, the costs of such overtime are to be borne by the contractor unless the principal agent has specifically authorised in writing, prior to the execution thereof, that costs for such overtime are to be borne by the employer. 98 F: ……….… V: ….……… T: ….……... Item
Preliminary Schedule A preliminary schedule of construction indicating the starting and completion dates of the various stages of the Work, including any information and following any form as may be specified in the Specifications. Once approved by District, this shall become the Construction Schedule. This schedule shall include and identify all tasks that are on the Project’s critical path with a specific determination of the start and completion of each critical path task as well as all Contract milestones and each milestone’s completion date(s) as may be required by the District.
Class Specifications The Human Resources Division shall determine:
Alternate Work Schedules Workweeks and work shifts of different numbers of hours may be established for overtime-eligible employees by the Employer in order to meet business and customer service needs, as long as the alternate work schedules meet federal and state law. When there is a holiday, employees may be required to switch from their alternate work schedules to regular work schedules.
Preliminary Cost Estimates The Engineer shall develop a preliminary cost estimate using the Average Low Bid Unit Price. The Engineer shall estimate the total project cost including preliminary engineering, final engineering, right-of-way (ROW) acquisition, environmental compliance and mitigation, construction, utility relocation, and construction engineering inspection (CEI).
Preliminary Evaluation Site evaluation and planning functions should proceed concurrently with the accomplishment of Schematic Design, Design Development, and Construction Documents. The Design Professional shall conduct a preliminary review of the site based on information furnished by the Owner. The Design Professional will advise the Owner of potential site-related problems that the Design Professional notes from such review.
Preliminary Cost Estimate Consulting Engineer/Architect shall furnish City an estimate of probable Construction Cost based on the preliminary design. Consulting Engineer/Architect's estimate of probable Construction Cost is to be made on the basis of Consulting Engineer/Architect's experience and qualifications and represent Consulting Engineer/Architect's best judgment as an experienced and qualified design professional, familiar with the construction industry.
Alternate Work Schedule An alternate work schedule is any work schedule where an employee is regularly scheduled to work five (5) days per week, but the employee’s regularly scheduled two (2) days off are NOT Saturday and Sunday.
Statistical Sampling Documentation a. A copy of the printout of the random numbers generated by the “Random Numbers” function of the statistical sampling software used by the IRO.