Improvement Allowance The Lessor is contributing to Lessee an improvement allowance (the “Initial Improvement Allowance”) of $70.000. Lessor must spend the Initial Improvement Allowance on costs related to the construction of the Improvements (as defined in Article 40 of the Lease). As part of the Improvements, Lessor shall provide new carpet for the office area and rear section of the Leased Premises as noted on the attached plan. In addition, the Lessor will paint the walls in the Leased Premises, and provide selective demolition (to be mutually agreed upon). The Lessor will add wall between the R&D lab space and the administrative cubicle area, as noted on the attached plan. The Initial Improvement Allowance will be used to fund Lessor’s activities related to the Improvements under this Exhibit X. Xxxxxx shall not charge Lessee any administration and supervision fee in connection with Xxxxxx’s work on the Improvements. The Leased Premises will be available on or about March 1, 2020 for work to commence work on the Improvements and Lessee to inspect the Building and the Leased Premises. Promptly following mutual execution of the Lease but prior to Lessor commencing any work under this Exhibit D, Lessor shall submit to Lessee, for its consent, a detailed construction plan, specifying materials to be used, renderings and schematics for the initial Improvements described above (the “Initial Improvement Plan”). Following Xxxxxx’s consent to the Initial Improvement Plan, Lessor shall exercise all reasonable efforts to have their general contractor bid and substantially complete the work for the Initial Improvements by April 1, 2020. Lessee shall have the right to inspect the Initial Improvements as they are being made. Lessor shall proceed with and complete the construction of the Improvements described above. As soon as such improvements have been Substantially Completed, Lessor shall notify Lessee in writing of the date that the Improvements were Substantially Completed. The Improvements shall be deemed substantially completed (“Substantially Completed”) when only punch list items remain which do not prevent in any material way the use of the Improvements for the purposes for which they were intended. If the Initial Improvement Allowance exceeds $70,000, then Xxxxxx will reimburse Lessor within thirty (30) days of the Improvements being substantially completed. 3706364.3/MTBA-JRP
TI Allowance Landlord shall provide to Tenant a tenant improvement allowance (collectively, the “TI Allowance”) as follows:
Tenant Improvement Allowance Items Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord only for the following items and costs (collectively the “Tenant Improvement Allowance Items”):
Construction Allowance Landlord shall provide to Tenant a construction allowance not to exceed $45.00 per rentable square foot in the Premises (the “Construction Allowance”) to be applied toward the Total Construction Costs, as adjusted for any changes to the Tenant’s Work. No advance of the Construction Allowance shall be made by Landlord until Tenant has first paid to the contractor from its own funds (and provided reasonable evidence thereof to Landlord) the anticipated Excess Amount. Thereafter, Landlord shall pay to Tenant the Construction Allowance, to be applied solely toward the remaining Total Construction Costs and not in reimbursement of the Excess Amount paid by Tenant, in multiple disbursements (but not more than once in any calendar month) following the receipt by Landlord of the following items: (i) a request for payment, (ii) final, unconditional or partial lien waivers, as the case may be, from all persons performing work or supplying or fabricating materials for the Tenant’s Work, fully executed, acknowledged and in recordable form, (iii) copies of all invoices and proof of payment of same, and (iv) the Architect’s certification that the Tenant’s Work for which reimbursement has been requested has been finally completed, including (with respect to the last application for payment only) any punch-list items, on the appropriate AIA form or another form approved by Landlord, and, with respect to the disbursement of the last 10% of the Construction Allowance: (1) the permanent certificate of occupancy issued for the Premises, (2) Tenant’s occupancy of the Premises, (3) delivery of the “as-built” plans for the Tenant’s Work as constructed (and as set forth above) to Landlord’s construction representative (set forth below), and (4) an estoppel certificate confirming such factual matters as Landlord or Landlord’s Mortgagee may reasonably request (collectively, a “Completed Application for Payment”). Landlord shall pay the amount requested in the applicable Completed Application for Payment to Tenant within 30 days following Tenant’s submission of the Completed Application for Payment. If, however, the Completed Application for Payment is incomplete or incorrect, Landlord’s payment of such request shall be deferred until 30 days following Landlord’s receipt of the corrected Completed Application for Payment. Notwithstanding anything to the contrary contained in this Exhibit, Landlord shall not be obligated to make any disbursement of the Construction Allowance during the pendency of any of the following: (A) Landlord has received written notice of any unpaid claims relating to any portion of the Tenant’s Work or materials in connection therewith, other than claims which will be paid in full from such disbursement, (B) there is an unbonded lien outstanding against the Project or the Premises or Tenant’s interest therein by reason of work done, or claimed to have been done, or materials supplied or specifically fabricated, claimed to have been supplied or specifically fabricated, to or for Tenant or the Premises, (C) the conditions to the advance of the Construction Allowance are not satisfied, or (D) an Event of Default by Tenant exists. If the Total Construction Costs for the Premises are less than the Construction Allowance, then Tenant shall not be entitled to receive payment or credit for such difference and Landlord shall retain the same. The Construction Allowance must be used (that is, the Tenant’s Work must be fully complete and the Construction Allowance disbursed) within twenty-four (24) months following the Commencement Date or shall be deemed forfeited with no further obligation by Landlord with respect thereto, time being of the essence with respect thereto. The Construction Allowance may be used in Tenant’s discretion for Tenant’s Work with no stipulation from Landlord as to how much of the Construction Allowance is allocated within the various spaces in the Premises.
Intent to Limit Charges to Maximum Lawful Rate In no event shall the interest rate or rates payable under this Agreement, plus any other amounts paid in connection herewith, exceed the highest rate permissible under any law that a court of competent jurisdiction shall, in a final determination, deem applicable. Borrower and the Lender Group, in executing and delivering this Agreement, intend legally to agree upon the rate or rates of interest and manner of payment stated within it; provided, however, that, anything contained herein to the contrary notwithstanding, if said rate or rates of interest or manner of payment exceeds the maximum allowable under applicable law, then, ipso facto, as of the date of this Agreement, Borrower is and shall be liable only for the payment of such maximum as allowed by law, and payment received from Borrower in excess of such legal maximum, whenever received, shall be applied to reduce the principal balance of the Obligations to the extent of such excess.
Construction Costs Tenant shall pay for all construction costs, including, but not limited to permits, costs of materials and labor, sales tax, construction management fees and the like except to the extent of the Tenant Improvement Allowance which shall be paid by Landlord. The term “Tenant Improvement Allowance” shall mean the sum of $316,020.00 (or $15.00 per square foot of rentable area times 21,068 square feet of rentable area) which Landlord agrees to pay towards the construction costs. Landlord agrees to pay architectural fees and design services up to $1.25 per rentable square foot. Any services performed by the architect above the $1.25 per rentable square foot shall be the responsibility of the Tenant and may be paid out of the Tenant Improvement Allowance to the extent funds are available. Notwithstanding anything to the contrary, provided there is any unused portion of the Tenant Improvement Allowance, up to 20% of the allowance can be used by the Tenant as a moving allowance or for communications costs for cabling and data. Tenant must submit invoices for such allowances for Landlord to pay. Xxxxxx Development will act as General Contractor for the construction of tenant improvements, competitively bidding each trade to at least three subcontractors, the typical five percent (5%) construction management fee will not be charged to Tenant or deducted from the Tenant Improvement Allowance. Landlord shall obtain bids based on the Approved Pricing Plans and construct the Work as described in the Approved Pricing Plans. If after finalizing the Approved Working Drawings, it is determined that the construction costs will exceed the amount of the Tenant Improvement Allowance (an “Excess”), then Tenant shall pay to Landlord the amount of such Excess within ten (10) days of written request from Landlord. Notwithstanding anything to the contrary, if Tenant fails to pay any Excess timely, Landlord shall not be obligated to commence construction of the Work and such delay shall constitute a Tenant Delay for each day beyond the ten (10) day period until the Excess is paid to Landlord. If Tenant elects not to use Xxxxxx Development as the General Contractor, Tenant understands that Landlord, or its designated agent, shall serve as construction manager for all of Tenant’s refurbishment and renovations in the refurbishment and renovations in the Premises and the fee for such service is 5% of the total cost of all work performed in connection with such refurbishment and renovations. Tenant agrees to cooperate with Landlord in completing any such improvements on a timely basis and Tenant has approved the preliminary space plan and pricing documentation. Additional space on the 3rd floor which Tenant elects to lease pursuant [****] = CERTAIN CONFIDENTIAL INFORMATION CONTAINED IN THIS DOCUMENT, MARKED BY BRACKETS, HAS BEEN OMITTED AND FILED SEPARATELY WITH THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO RULE 406 OF THE SECURITIES ACT OF 1933, AS AMENDED. to a right hereunder shall be finished out by Landlord pursuant to mutually agreed upon plans and Tenant shall receive an allowance of $15.00 per square foot of rentable area provided, however, Tenant acknowledges that Landlord is improving the entire third (3rd) floor prior to commencement of the Lease and Tenant shall not be entitled to any additional tenant finish when Tenant leases the remainder of the third floor.
Excess TI Costs Landlord shall have no obligation to bear any portion of the cost of any of the Tenant Improvements except to the extent of the TI Allowance. If at any time the remaining TI Costs under the Budget exceed the remaining unexpended TI Allowance, Tenant shall deposit with Landlord, as a condition precedent to Landlord’s obligation to complete the Tenant Improvements, 100% of the then current TI Cost in excess of the remaining TI Allowance (“Excess TI Costs”). If Tenant fails to deposit any Excess TI Costs with Landlord, Landlord shall have all of the rights and remedies set forth in the Lease for nonpayment of Rent (including, but not limited to, the right to interest at the Default Rate and the right to assess a late charge). For purposes of any litigation instituted with regard to such amounts, those amounts will be deemed Rent under the Lease. The TI Allowance and Excess TI Costs are herein referred to as the “TI Fund.” Funds deposited by Tenant shall be the first disbursed to pay TI Costs. Notwithstanding anything to the contrary set forth in this Section 5(d), Tenant shall be fully and solely liable for TI Costs and the cost of Minor Variations in excess of the TI Allowance. If upon completion of the Tenant Improvements and the payment of all sums due in connection therewith there remains any undisbursed portion of the TI Fund, Tenant shall be entitled to such undisbursed TI Fund solely to the extent of any Excess TI Costs deposit Tenant has actually made with Landlord.
Termination Costs Concurrently with the exchange of final reports pursuant to Articles 4.2 and 5.2, PHS shall submit to the Collaborator for payment a statement of all costs incurred prior to the date of termination and for all reasonable termination costs including the cost of returning Collaborator property or removal of abandoned property, for which Collaborator shall be responsible.
Tenant Allowance Landlord shall provide Tenant an allowance for each Building in an amount not to exceed the sum set forth in the Basic Lease Information for the Tenant Allowance for the applicable Building (collectively, the “Tenant Allowance”), to be applied toward the cost of the following items in respect of the Tenant Improvements in the applicable Building: Architectural and engineering fees, space planning, building permits or other governmental fees, and the cost of labor, materials, contractors fees and overhead, and other charges included in the construction contract for construction of Tenant Improvements, including the contractor’s fee, overhead and general conditions, sales and use taxes, the cost of the builder’s risk insurance during construction and all testing and inspection costs. If Landlord elects to itself construct the Restroom Improvements, Landlord shall make payments to its contractor for the Restroom Improvements as and when such costs are incurred and deduct the amount of such payments from the Tenant Allowance for Building 2 up to the maximum amount stated in Paragraph I of this Work Letter. Landlord shall not be obligated to disburse any remaining portion of the Tenant Allowance attributable to a Building until such time as (i) the Commencement Date for the applicable Building has occurred and Tenant has accepted delivery of the Building and made the initial prepayment of Rent with respect to the applicable portion of the Premises; and (ii) Tenant has delivered to Landlord and Landlord has approved, in Landlord’s reasonable discretion, all of the following: (A) invoices, paid receipts and/or related evidence reasonably acceptable to Landlord establishing that Tenant has paid an amount equal to that portion of the Tenant Allowance requested by Tenant to third parties in connection with the Tenant Improvements in the applicable Building; (B) executed unconditional final mechanics’ lien releases, in statutory form, from Tenant’s contractor and all subcontractors, laborers, materialmen and suppliers used by Tenant with respect to all work in and to the Premises located in the applicable Building; (C) a certificate from Tenant’s architect or space planner, in a form reasonably acceptable to Landlord, certifying that the construction of the Tenant Improvements in the applicable Building has been substantially completed and meets all applicable building codes; (D) a copy of the certificate of occupancy (or similar governmental authorization) for the applicable Building; (E) “as-built” drawings for the Tenant Improvements in the applicable Building, signed by either Tenant’s architect, space planner or contractor, and electronic CAD files from Tenant’s Contractor and all subcontractors; and (F) a final punch list signed off by both Tenant and Landlord and/or their architects. Thereafter, Landlord shall deliver, within fifteen (15) days following Tenant’s delivery of the materials and information required for disbursement thereof in the preceding sentence, a check payable to Tenant in the amount of that portion of the Tenant Allowance requested by Tenant and paid to third parties in connection with the Tenant Improvements for the applicable Building (which amount shall not exceed the portion of the Tenant Allowance provided for such Building as specified in the Basic Lease Information). Landlord’s payment of any portion of the Tenant Allowance shall not be deemed Landlord’s approval any of the Tenant Improvements absent Landlord’s prior approval pursuant to this Work Letter. Landlord’s obligation to disburse the Tenant Allowance for each Building under this Paragraph 9(b) shall expire six (6) months after the Delivery Date for the applicable Building, subject to extension due to Force Majeure, such that Landlord shall not be obligated to provide to Tenant any undisbursed portion of the Tenant Allowance for a Building unless Tenant has delivered to Landlord all documents required above within nine (9) months after the Delivery Date of such Building.
Landlord’s Contribution Landlord shall, in the manner hereinafter set forth, contribute the lesser of (i) the actual cost of Tenant’s Work or (ii) $1,698,800.00 (calculated on the basis of $40.00 per rentable square foot of the Relocation Premises) (“Landlord’s Contribution”) towards the costs of designing and constructing Tenant’s Work. Tenant shall be entitled to use up to $424,700.00 (i.e., $10.00 per rentable square foot of the Relocation Premises) of Landlord’s Contribution towards the cost of architectural and engineering drawings, furniture, fixtures and equipment, permitting costs, cabling, wiring and moving costs, signage, third-party legal fees and consulting costs incurred by Tenant in the performance of Tenant’s Work. Provided no Default of Tenant exists at the time that Tenant submits any Requisition (as hereinafter defined) on account of Landlord’s Contribution, Landlord shall pay the cost of the work shown on each Requisition submitted by Tenant to Landlord within twenty-five (25) days of Landlord’s receipt thereof. For the purposes hereof, a “Requisition” shall mean written documentation showing in reasonable detail the costs of the Tenant’s Work then installed by Tenant in the Premises. Each Requisition shall be accompanied by evidence reasonably satisfactory to Landlord that all work covered by previous Requisitions has been fully paid. Landlord shall have the right, upon reasonable advance notice to Tenant, to inspect Tenant’s books and records relating to each Requisition in order to verify the amount thereof. Tenant shall submit Requisition(s) no more often than monthly. Landlord’s Contribution, less a 10% retainage (which retainage shall be payable as part of the final draw), shall be paid to the general contractor that performs Tenant’s Work, in periodic disbursements within twenty-five (25) days after receipt of the following documentation: (i) an application for payment and sworn statement of contractor substantially in the form of AIA Document G-702 covering all work for which disbursement is to be made to a date specified therein; (ii) a certification from an AIA architect substantially in the form of the Architect’s Certificate for Payment found in AIA Document G702, Application and Certificate of Payment; (iii) Contractor’s, subcontractor’s and material supplier’s waivers of liens which shall cover all Tenant’s Work for which disbursement is being requested and all other statements and forms required for compliance with the mechanics’ lien laws of the state in which the Relocation Premises is located, together with all such invoices, contracts, or other supporting data as Landlord or Landlord’s Mortgagee may reasonably require; (iv) a cost breakdown for each trade or subcontractor performing Tenant’s Work; (v) plans and specifications for Tenant’s Work, together with a certificate from an AIA architect that such plans and specifications comply in all material respects with all laws affecting the Building, Property and Relocation Premises; (vi) copies of all construction contracts for Tenant’s Work, together with copies of all change orders, if any; and (vii) a request to disburse from Tenant containing an approval by Tenant of the work done and a good faith estimate of the cost to complete Tenant’s Work. Upon completion of Tenant’s Work, and prior to final disbursement of Landlord’s Contribution, Tenant shall furnish Landlord with: (I) general contractor and architect’s completion affidavits, (2) full and final waivers of lien, (3) receipted bills covering all labor and materials expended and used, (4) as-built plans of the Tenant’s Work, and (5) the certification of Tenant’s architect that Tenant’s Work has been installed in a good and workmanlike manner in accordance with the Tenant’s Plans, and in accordance with applicable laws, codes and ordinances. In no event shall Landlord be required to disburse Landlord’s Contribution more than one (1) time per month. Notwithstanding anything herein to the contrary, Landlord shall not be obligated to disburse any portion of Landlord’s Contribution during the continuance of an uncured Default by Tenant under the Lease, and Landlord’s obligation to disburse shall only resume when and if such Default is cured. If Tenant does not submit a request for payment of the entire Landlord’s Contribution to Landlord in accordance with the provisions contained in this Section II (D) on or before the date that is twelve (12) months after the Relocation Date, any unused amount shall accrue to the sole benefit of Landlord, it being understood that Tenant shall not be entitled to any credit, abatement or other concession in connection therewith. Tenant shall be responsible for all applicable state sales or use taxes, if any, payable in connection with Tenant’s Work and Landlord’s Contribution.
