Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Prevention of or Delay in Performance by the Depositary, the Depositary’s Agents, the Registrar or the Company. Neither the Depositary nor any Depositary’s Agent nor the Registrar nor the Company shall incur any liability to any holder of any Receipt if by reason of any provision of any present or future law, or regulation thereunder, of the United States of America or of any other governmental authority or, in the case of the Depositary, the Depositary’s Agent or the Registrar, by reason of any provision, present or future, of the Company’s Articles of Incorporation or by reason of any act of God or war or other circumstance beyond the control of the relevant party, the Depositary, the Depositary’s Agent, the Registrar or the Company shall be prevented, delayed or forbidden from, or subjected to any penalty on account of, doing or performing any act or thing which the terms of this Deposit Agreement provide shall be done or performed; nor shall the Depositary, any Depositary’s Agent, the Registrar or the Company incur liability to any holder of a Receipt (i) by reason of any nonperformance or delay, caused as aforesaid, in the performance of any act or thing which the terms of this Deposit Agreement shall provide shall or may be done or performed, or (ii) by reason of any exercise of, or failure to exercise, any discretion provided for in this Deposit Agreement except, in the case of any such exercise or failure to exercise discretion not caused as aforesaid, if caused by the gross negligence, willful misconduct or bad faith of the party charged with such exercise or failure to exercise.
ADDITIONAL ACTIVITIES I agree that during the period of my employment by the Company I will not, without the Company's express written consent, engage in any employment or business activity which is competitive with, or would otherwise conflict with, my employment by the Company. I agree further that for the period of my employment by the Company and for one (l) year after the date of termination of my employment by the Company I will not induce any employee of the Company to leave the employ of the Company.
Compliance with Occupational Laws The Company and each of its subsidiaries (A) is in compliance, in all material respects, with any and all applicable foreign, federal, state and local laws, rules, regulations, treaties, statutes and codes promulgated by any and all Governmental Authorities (including pursuant to the Occupational Health and Safety Act) relating to the protection of human health and safety in the workplace (“Occupational Laws”); (B) has received all material permits, licenses or other approvals required of it under applicable Occupational Laws to conduct its business as currently conducted; and (C) is in compliance, in all material respects, with all terms and conditions of such permit, license or approval. No action, proceeding, revocation proceeding, writ, injunction or claim is pending or, to the Company’s knowledge, threatened against the Company or any of its subsidiaries relating to Occupational Laws, and the Company does not have knowledge of any facts, circumstances or developments relating to its operations or cost accounting practices that could reasonably be expected to form the basis for or give rise to such actions, suits, investigations or proceedings.
Devotion of Time; Additional Activities (a) The Manager will provide a dedicated management team, including a President, a Chief Financial Officer and a Chief Operating Officer of the Company, to provide the management services to be provided by the Manager to the Company hereunder, the members of which team shall have as their primary responsibility the management of the Company and shall devote such of their time to the management of the Company as the Board of Directors reasonably deems necessary and appropriate, commensurate with the level of activity of the Company from time to time.
Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.
Remedial Actions Relating to Hazardous Materials Activities Borrower shall, in compliance with all applicable Environmental Laws, promptly undertake, and shall cause each of its Subsidiaries promptly to undertake, any and all investigations, studies, sampling, testing, abatement, cleanup, removal, remediation or other response actions necessary to remove, remediate, clean up or xxxxx any Hazardous Materials Activity on, under or about any Facility that is in violation of any Environmental Laws or that presents a material risk of giving rise to an Environmental Claim. If Borrower or any of its Subsidiaries undertakes any such action with respect to any Hazardous Materials, Borrower or such Subsidiary shall conduct and complete such action in compliance with all applicable Environmental Laws and in accordance with the policies, orders and directives of all federal, state and local Government Authorities except when, and only to the extent that, Borrower’s or such Subsidiary’s liability with respect to such Hazardous Materials Activity is being diligently contested in good faith and by appropriate proceedings by Borrower or such Subsidiary.
Delays If no event of Force Majeure shall have occurred and be continuing and in the event that a delay shall have been caused by the negligence or willful misconduct of the Custodian in carrying out an Instruction to credit or transfer cash, the Custodian shall be liable to the Fund: (a) with respect to Principal Accounts, for interest to be calculated at the rate customarily paid on such deposit and currency by the Custodian on overnight deposits at the time the delay occurs for the period from the day when the transfer should have been effected until the day it is in fact effected; and, (b) with respect to Agency Accounts, for interest to be calculated at the rate customarily paid on such deposit and currency by the Subcustodian on overnight deposits at the time the delay occurs for the period from the day when the transfer should have been effected until the day it is in fact effected. The Custodian shall not be liable for delays in carrying out Instructions to transfer cash which are not due to the Custodian's own negligence or willful misconduct.
Ready for Occupancy For purposes of Section 1.3.2 of this Agreement, the Premises shall be deemed “Ready for Occupancy” upon the substantial completion of the Tenant Improvement Work. Subject to Section 4.2 below, the Tenant Improvement Work shall be deemed to be “substantially complete” upon the completion of the Tenant Improvement Work pursuant to the Approved Construction Drawings (as reasonably determined by Landlord), with the exception of any details of construction, mechanical adjustment or any other similar matter the non-completion of which does not materially interfere with Tenant’s use of the Premises.
Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.
