Overriding powers of the Authority (i) If in the reasonable opinion of the Authority, the Contractor is in material breach of its obligations under this Agreement and, in particular, the Maintenance Requirements, and such breach is causing or likely to cause material hardship or danger to the Users and pedestrians, the Authority may, without prejudice to any of its rights under this Agreement including Termination thereof, by notice require the Contractor to take reasonable measures immediately for rectifying or removing such hardship or danger, as the case may be.
(ii) In the event that the Contractor, upon notice under Clause 14.9 (i), fails to rectify or remove any hardship or danger within a reasonable period, the Authority may exercise overriding powers under this Clause 14.9 (ii) and take over the performance of any or all the obligations of the Contractor to the extent deemed necessary by it for rectifying or removing such hardship or danger; provided that the exercise of such overriding powers by the Authority shall be of no greater scope and of no longer duration than is reasonably required hereunder; provided further that any costs and expenses incurred by the Authority in discharge of its obligations hereunder shall be recovered by the Authority from the Contractor, and the Authority shall be entitled to deduct any such costs and expenses incurred from the payments due to the Contractor under Clause 19.7 for the performance of its Maintenance obligations.
(iii) In the event of a national emergency, civil commotion or any other circumstances specified in Clause 21.3, the Authority may take over the performance of any or all the obligations of the Contractor to the extent deemed necessary by it, and exercise such control over the Project Highway or give such directions to the Contractor as may be deemed necessary; provided that the exercise of such overriding powers by the Authority shall be of no greater scope and of no longer duration than is reasonably required in the circumstances which caused the exercise of such overriding power by the Authority. For the avoidance of doubt, it is agreed that the consequences of such action shall be dealt in accordance with the provisions of Article 21. It is also agreed that the Contractor shall comply with such instructions as the Authority may issue in pursuance of the provisions of this Clause 14.9 (iii), and shall provide assistance and cooperation to the Authority, on a best effort basis, for performance of its obligations hereunder.
Powers of the Arbitrator It shall be the function of the arbitrator, and he/she shall be empowered, except as his/her powers are limited below, after due investigation, to make a decision in cases of alleged violation of the specific articles and sections of this Agreement.
a. The arbitrator shall have no power to add to, subtract from, disregard, alter, or modify any of the terms of this Agreement.
b. The arbitrator shall have no power to establish salary scales or change any salary.
c. The arbitrator shall have no power to rule on any of the following:
1. The termination of services of or failure to re-employ any probationary teacher.
2. The failure to reemploy any teacher to a position on the extra-curricular schedule.
3. Any claim or complaint for which there is another remedial procedure or forum established by law or by regulation having the force of law, including any matter subject to the procedures specified in the Teacher Tenure Act (Act IV of Public Acts, extra session, of 1937 of Michigan, as amended).
4. Any matter involving the evaluation of a non-classroom professional, unless it is a claim of failure to follow contractually agreed upon procedures.
d. He/she shall have no power to change any practice, policy, or rule of the District nor to substitute his/her judgment for that of the District as to the reasonableness of any such practice, policy, rule or any action taken by the District. His/her power shall be limited to deciding whether the District has violated the expressed articles or sections of this Agreement; and he/she shall not imply obligations and conditions binding upon the District from this Agreement, it being understood that any matter not specifically set forth herein remains within the reserved rights of the District.
e. He/she shall have no power to decide any questions which, under this Agreement, is within the responsibility of management to decide. In rendering a decision, an arbitrator shall give due regard to the responsibility of management and shall so construe the Agreement that there will be no interference with such responsibilities, except as they may be specifically conditioned by this Agreement.
f. If either party disputes the arbitrability of any grievance under the terms of this Agreement, the arbitrator shall determine the arbitrability of said dispute, except that either party reserves the right to seek resolution of any dispute of arbitrability in a court of competent jurisdiction before or after arbitration.
g. There shall be no appeal from an arbitrator’s decision if within the scope of his/her authority as set forth above. It shall be final and binding on the Association, its members, the employee or employees involved and the District.
h. The fees and expenses of the arbitrator shall be shared equally by the Association and the District.
Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works.
(iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor:
(a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre.
(b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7
(c) all environmental clearances as required under Clause 4.3.8
(iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
Powers of the Advisor Subject to the express limitations set forth in this Agreement and the continuing and exclusive authority of the Board over the management of the Company, the power to direct the management, operation and policies of the Company, including making, financing and disposing of investments, shall be vested in the Advisor, which shall have the power by itself and shall be authorized and empowered on behalf and in the name of the Company to carry out any and all of the objectives and purposes of the Company and to perform all acts and enter into and perform all contracts and other undertakings that it may in its sole discretion deem necessary, advisable or incidental thereto to perform its obligations under this Agreement.
Powers of the Company The Company shall have the power and authority to take any and all actions necessary, appropriate or advisable to or for the furtherance of the purposes set forth in Section 2.05.
AMOUNTS AND TERMS OF THE ADVANCES AND THE LETTERS OF CREDIT SECTION 2.01. The Advances and the Letters of Credit.
The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).
Purpose and Powers of the Company The Company is organized for the purpose of carrying on any lawful activity for which limited liability companies may be formed under the Act. The Company shall possess and may exercise all of the powers and privileges granted by the Act or by any other law or by this Agreement, together with any powers incidental thereto, so far as such powers and privileges are necessary or convenient to the conduct, promotion or attainment of the business purposes or activities of the Company contemplated by this Agreement.
Powers of the Member Pursuant to Section 00-00-000 of the Act, the Member is authorized:
(a) to make all decisions regarding the Company’s operations and legal affairs, including but not limited to:
i. the sale, development, lease, or other disposition of the Company's assets;
ii. the purchase or acquisition of other assets;
iii. the management of all or any part of the Company's assets;
iv. the borrowing of money and granting of security interests in the Company's assets;
v. the pre-payment, refinancing, or extension of any loan affecting the Company's assets;
vi. the compromise or release of any of the Company's claims or debts; and
vii. the employment of persons, firms, or corporations for the operation and management of the Company's business; and
(b) to execute and deliver:
i. all contracts, conveyances, assignments, leases, sub-leases, franchise agreements, licensing agreements, management contracts, and maintenance contracts covering or affecting the Company's assets;
ii. all checks, drafts, and other orders for the payment of the Company's funds;
iii. all promissory notes, loans, security agreements and other similar documents; and
iv. all other instruments of any kind relating to the Company's business and affairs.
Powers of the Board The Board shall have the power to do any and all acts necessary, convenient or incidental to or for the furtherance of the purposes described herein, including all powers, statutory or otherwise. Subject to the other provisions of this Agreement, the Board shall have the authority, on behalf of the Company, to do all things necessary or appropriate for the accomplishment of the purposes of the Company. Subject to the other provisions of this Agreement, the Board shall have full power to act for and to bind the Company to the extent provided by Delaware law.
