Modification or Suspension by State or Federal Law Sample Clauses

Modification or Suspension by State or Federal Law. In the event that State, County or Federal laws or regulations, enacted after the Effective Date of this Agreement, prevent or preclude compliance with one or more of the provisions of this Agreement, such provisions of this Agreement shall be modified or suspended as may be necessary to comply with such State or Federal laws or regulations; provided, however, that this Agreement shall remain in full force and effect to the extent it is not inconsistent with such laws or regulations and to the extent such laws or regulations do not render such remaining provisions impractical to enforce.
Sample 1Sample 2Sample 3See All (20)
AutoNDA by SimpleDocs
Modification or Suspension by State or Federal Law. In the event that State or Federal laws or regulations, enacted after the Effective Date of this Agreement, prevent or preclude compliance with one or more of the provisions of this Agreement, such provisions of this Agreement shall be modified or suspended as may be necessary to comply with such State or Federal laws or regulations, provided, however, that this Agreement shall remain in full force and effect to the extent it is not inconsistent with such laws or regulations and to the extent such laws or regulations do not render such remaining provisions impractical to enforce. In the event OWNER alleges that such State or Federal laws or regulations preclude or prevent compliance with one or more provisions of this Agreement, and the CITY does not agree, the OWNER may, at its sole cost and expense, seek declaratory relief (or other similar non-monetary remedies); provided however, that nothing contained in this Section 3.6.3 shall impose on CITY any monetary liability for contesting such declaratory relief (or other similar non-monetary relief).
Sample 1Sample 2Sample 3See All (5)
Modification or Suspension by State or Federal Law. In the event that state or federal laws or regulations, or those of any regional authority having jurisdiction over the Project or Property, enacted after the Approval Date of this Agreement, prevent or preclude compliance with one or more of the provisions of this Agreement or the Project conditions, such provisions of this Agreement shall be modified or suspended as may be necessary to comply with such state, federal, or regional authority laws or regulations and to effectuate to the extent possible the terms of this Agreement.
Sample 1
Modification or Suspension by State or Federal Law. In the event that state or federal laws or regulations enacted after the Approval Date prevent or preclude compliance with one or more of the provisions of this Agreement, such provisions of this Agreement shall be modified or suspended as may be necessary to comply with such state or federal laws or regulations. If such state or federal laws or regulations prevent or materially frustrate Seaview Palms’ exercise of its rights under this Agreement to construct and operate the Permitted Sign, and if the applicable provisions of this Agreement cannot be modified in such a manner as to permit Seaview Palms to exercise its rights under this Agreement to construct and operate the Permitted Sign, then Seaview Palms shall have the right to terminate this Agreement by written notice to the City and replace the Permitted Sign with the Existing Sign.
Sample 1
Modification or Suspension by State or Federal Law. In the event that State, County or Federal laws or regulations, enacted after the Effective Date of this Agreement, prevent or preclude compliance with one or more of the provisions of this Agreement, such provisions of this Agreement shall be modified or suspended as may be necessary to comply with such State or Federal laws or regulations; provided, however, that this Agreement shall remain in full force and effect to the extent it is not inconsistent with such laws or regulations and to the extent such laws or regulations do not render such remaining provisions impractical to enforce. Notwithstanding the foregoing, if Owner’s obligations or costs are materially increased, or if Owner’s rights and benefits hereunder are materially adversely affected, Owner may terminate this Agreement in Owner’s discretion and shall not have any liability for doing so or be considered in breach or default.
Sample 1
Modification or Suspension by State or Federal Law. In the event the County, in good faith, reasonably determines that State or Federal laws or regulations enacted or adopted after the date hereof prevent or preclude compliance with one or more of the provisions of this Agreement, the Parties shall meet and confer in good faith in order to modify or otherwise amend this Agreement or the Development Approvals, consistent with Section 2.6.1, above, as may be necessary to comply with such state or federal laws or regulations; provided, however, that this Agreement and the Development Approvals shall remain in full force and effect to the extent they are not inconsistent with such laws or regulations, as determined by the County. In making determinations under this Section 2.7.3, the County shall consult with Developer. Nothing in this Agreement shall preclude Developer from contesting by any available means (including administrative or judicial proceedings) the County's determination of the applicability to the Project any such State or Federal laws or regulations.
Sample 1
Modification or Suspension by State or Federal Law. In the event that state or federal laws or regulations, or those of any regional authority having jurisdiction over the Permitted Sign or Property, enacted after the Approval Date of this Agreement, prevent or preclude compliance with one or more of the provisions of this Agreement, such provisions of this Agreement shall be modified or suspended as may be necessary to comply with such state, federal, or regional authority laws or regulations. If such state or federal laws or regulations prevent or materially frustrate Owner’s exercise of its rights under this Agreement to construct and operate the Permitted Sign, and if the applicable provisions of this Agreement cannot be modified in such a manner as to permit Owner to exercise its rights under this Agreement to construct and operate the Permitted Sign, then Owner shall have the right to terminate this Agreement by written notice to the City.
Sample 1
AutoNDA by SimpleDocs

Related to Modification or Suspension by State or Federal Law

  • Termination or Suspension Under Federal Law (i) If the Employee is removed and/or permanently prohibited from participating in the conduct of the Company’s affairs by an order issued under Sections 8(e)(iv) or 8(g)(i) of the Federal Deposit Insurance Act (“FDIA”) (12 U.S.C. 1818(e)(4) and (g)(1)), all obligations of the Company under this Agreement shall terminate, as of the effective date of the order, but vested rights of the Employee shall not be affected. (ii) If the Bank is in default (as defined in Section 3(x)(1) of the FDIA), all obligations under this Agreement shall terminate as of the date of default; but the vested rights of the Employee shall not be affected. (iii) All obligations under this Agreement shall terminate, except to the extent it is determined that the continuation of this Agreement is necessary for the continued operation of the Bank; (A) by the OCC or its designee, at the time that the Federal Deposit Insurance Corporation (“FDIC”) enters into an agreement to provide assistance to or on behalf of the Bank under the authority contained in Section 13(c) of FDIA; or (B) by the OCC, or its designee, at the time that the OCC or its designee approves a supervisory merger to resolve problems related to operation of the Bank or when the Bank is determined by the OCC to be in an unsafe or unsound condition. Such action shall not affect any vested rights of the Employee. (iv) If a notice served under Section 8(e)(3) or (g)(1) of the FDIA suspends and/or temporarily prohibits the Employee from participating in the conduct of the Bank’s affairs, the Bank’s obligations under this Agreement shall be suspended as of the date of such service, unless stayed by appropriate proceedings. However, the vested rights of the Employee as of the date of suspension will not be affected. If the charges in the notice are dismissed, the Bank may in its discretion (A) pay the Employee all or part of the compensation withheld while its contract obligations were suspended, and (B) reinstate (in whole or in part) any of its obligations which were suspended.

  • Termination by Operation of Law This Agreement may be terminated by any Party hereto if there shall be any statute, rule or regulation that renders consummation of the transactions contemplated by this Agreement (the “Contemplated Transactions) illegal or otherwise prohibited, or a court of competent jurisdiction or any government (or governmental authority) shall have issued an order, decree or ruling, or has taken any other action restraining, enjoining or otherwise prohibiting the consummation of such transactions and such order, decree, ruling or other action shall have become final and nonappealable.

  • No Waiver of Governmental Immunity Nothing in this Agreement shall be construed to waive, limit, or otherwise modify any governmental immunity that may be available by law to the Town, its officials, employees, contractors, or agents, or any other person acting on behalf of the Town and, in particular, governmental immunity afforded or available pursuant to the Colorado Governmental Immunity Act, Title 24, Article 10 of the Colorado Revised Statutes.

  • TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Architect’s option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, the Architect shall give seven days’ written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.2 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days’ written notice. § 9.4 Either party may terminate this Agreement upon not less than seven days’ written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination. § 9.5 The Owner may terminate this Agreement upon not less than seven days’ written notice to the Architect for the Owner’s convenience and without cause. § 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall compensate the Architect for services performed prior to termination, Reimbursable Expenses incurred, and costs attributable to termination, including the costs attributable to the Architect’s termination of consultant agreements. § 9.7 In addition to any amounts paid under Section 9.6, if the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall pay to the Architect the following fees:

  • Succession by Xxxxxx, Etc Any corporation or other entity into which the Trustee may be merged or converted or with which it may be consolidated, or any corporation or other entity resulting from any merger, conversion or consolidation to which the Trustee shall be a party, or any corporation or other entity succeeding to all or substantially all of the corporate trust business of the Trustee (including the administration of this Indenture), shall be the successor to the Trustee hereunder without the execution or filing of any paper or any further act on the part of any of the parties hereto; provided that in the case of any corporation or other entity succeeding to all or substantially all of the corporate trust business of the Trustee such corporation or other entity shall be eligible under the provisions of Section 7.08. In case at the time such successor to the Trustee shall succeed to the trusts created by this Indenture, any of the Notes shall have been authenticated but not delivered, any such successor to the Trustee may adopt the certificate of authentication of any predecessor trustee or authenticating agent appointed by such predecessor trustee, and deliver such Notes so authenticated; and in case at that time any of the Notes shall not have been authenticated, any successor to the Trustee or an authenticating agent appointed by such successor trustee may authenticate such Notes either in the name of any predecessor trustee hereunder or in the name of the successor trustee; and in all such cases such certificates shall have the full force which it is anywhere in the Notes or in this Indenture provided that the certificate of the Trustee shall have; provided, however, that the right to adopt the certificate of authentication of any predecessor trustee or to authenticate Notes in the name of any predecessor trustee shall apply only to its successor or successors by merger, conversion or consolidation.

  • Amendment, Suspension or Termination of the Plan By accepting this Award, Participant expressly warrants that he or she has received an Award of Restricted Stock Units under the Plan, and has received, read and understood a description of the Plan. Participant understands that the Plan is discretionary in nature and may be amended, suspended or terminated by the Company at any time.

  • Limitation on the Exercise of Certain Rights Related to Affiliate Insolvency Proceedings (a) Notwithstanding anything to the contrary in this Agreement or any other agreement, but subject to the requirements of Section 19, no party to this Agreement shall be permitted to exercise any Default Right against a Covered Party with respect to this Agreement that is related, directly or indirectly, to a BHC Affiliate of such party becoming subject to a receivership, insolvency, liquidation, resolution, or similar proceeding (each an “Insolvency Proceeding”), except to the extent the exercise of such Default Right would be permitted under the creditor protection provisions of 12 C.F.R. § 252.84, 12 C.F.R. § 47.5, or 12 C.F.R. § 382.4, as applicable. (b) After a BHC Affiliate of a Covered Party has become subject to Insolvency Proceedings, if any party to this Agreement seeks to exercise any Default Right against such Covered Party with respect to this Agreement, the party seeking to exercise a Default Right shall have the burden of proof, by clear and convincing evidence, that the exercise of such Default Right is permitted hereunder.

  • TEN TERMINATION OR SUSPENSION CONTRACTOR shall be considered in material default of this Agreement and such default will be considered cause for OWNER to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) failure to begin work under the Agreement within the times specified under the Notice(s) to Proceed, or (b) failure to properly and timely perform the services to be provided hereunder or as directed by OWNER, or (c) the bankruptcy or insolvency or a general assignment for the benefit of creditors by CONTRACTOR or by any of CONTRACTOR's principals, officers or directors, or (d) failure to obey laws, ordinances, regulations or other codes of conduct, or (e) failure to perform or abide by the terms or spirit of this Agreement, or (f) for any other just cause. The OWNER may so terminate this Agreement, in whole or in part, by giving the CONTRACTOR seven (7) calendar day’s written notice.

  • Notice of Governing Law This award of Restricted Stock Units shall be governed by, and construed in accordance with, the laws of the State of California, without regard to principles of conflict of laws.

  • No Termination or Abatement Lessee shall remain obligated under this Lease in accordance with its terms and shall not take any action to terminate, rescind or avoid this Lease, notwithstanding any action for bankruptcy, insolvency, reorganization, liquidation, dissolution, or other proceeding affecting any Person or any Governmental Authority, or any action with respect to this Lease or any Operative Agreement which may be taken by any trustee, receiver or liquidator of any Person or any Governmental Authority or by any court with respect to any Person, or any Governmental Authority. Lessee hereby waives all right (a) to terminate or surrender this Lease (except as permitted under the terms of the Operative Agreements) or (b) to avail itself of any abatement, suspension, deferment, reduction, setoff, counterclaim or defense with respect to any Rent. Lessee shall remain obligated under this Lease in accordance with its terms and Lessee hereby waives any and all rights now or hereafter conferred by statute or otherwise to modify or to avoid strict compliance with its obligations under this Lease. Notwithstanding any such statute or otherwise, Lessee shall be bound by all of the terms and conditions contained in this Lease.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!