Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Consequences of non-compliance If a beneficiary breaches any of its obligations under this Article, the grant may be reduced (see Article 43). Such breaches may also lead to any of the other measures described in Chapter 6.
Certification of Funds; Budget and Fiscal Provisions; Termination in the Event of Non-Appropriation This Agreement is subject to the budget and fiscal provisions of the City’s Charter. Charges will accrue only after prior written authorization certified by the Controller, and the amount of City’s obligation hereunder shall not at any time exceed the amount certified for the purpose and period stated in such advance authorization. This Agreement will terminate without penalty, liability or expense of any kind to City at the end of any fiscal year if funds are not appropriated for the next succeeding fiscal year. If funds are appropriated for a portion of the fiscal year, this Agreement will terminate, without penalty, liability or expense of any kind at the end of the term for which funds are appropriated. City has no obligation to make appropriations for this Agreement in lieu of appropriations for new or other agreements. City budget decisions are subject to the discretion of the Mayor and the Board of Supervisors. Contractor’s assumption of risk of possible non-appropriation is part of the consideration for this Agreement. THIS SECTION CONTROLS AGAINST ANY AND ALL OTHER PROVISIONS OF THIS AGREEMENT.
Notification of Breach / Compliance Reports The Adviser shall notify the Trust immediately upon detection of (i) any material failure to manage any Fund in accordance with its investment objectives and policies or any applicable law; or (ii) any material breach of any of the Funds’ or the Adviser’s policies, guidelines or procedures. In addition, the Adviser shall provide a quarterly report regarding each Fund’s compliance with its investment objectives and policies, applicable law, including, but not limited to the 1940 Act and Subchapter M of the Code, as applicable, and the Fund’s policies, guidelines or procedures as applicable to the Adviser’s obligations under this Agreement. The Adviser agrees to correct any such failure promptly and to take any action that the Board may reasonably request in connection with any such breach. Upon request, the Adviser shall also provide the officers of the Trust with supporting certifications in connection with such certifications of Fund financial statements and disclosure controls pursuant to the Xxxxxxxx-Xxxxx Act. The Adviser will promptly notify the Trust in the event (i) the Adviser is served or otherwise receives notice of any action, suit, proceeding, inquiry or investigation, at law or in equity, before or by any court, public board, or body, involving the affairs of the Trust (excluding class action suits in which a Fund is a member of the plaintiff class by reason of the Fund’s ownership of shares in the defendant) or the compliance by the Adviser with the federal or state securities laws or (ii) an actual change in control of the Adviser resulting in an “assignment” (as defined in the 0000 Xxx) has occurred or is otherwise proposed to occur.
Environmental Compliance and Reports Borrower shall comply in all respects with any and all Environmental Laws; not cause or permit to exist, as a result of an intentional or unintentional action or omission on Borrower’s part or on the part of any third party, on property owned and/or occupied by Borrower, any environmental activity where damage may result to the environment, unless such environmental activity is pursuant to and in compliance with the conditions of a permit issued by the appropriate federal, state or local governmental authorities; shall furnish to Lender promptly and in any event within thirty (30) days after receipt thereof a copy of any notice, summons, lien, citation, directive, letter or other communication from any governmental agency or instrumentality concerning any intentional or unintentional action or omission on Borrower’s part in connection with any environmental activity whether or not there is damage to the environment and/or other natural resources. Additional Assurances. Make, execute and deliver to Lender such promissory notes, mortgages, deeds of trust, security agreements, assignments, financing statements, instruments, documents and other agreements as Lender or its attorneys may reasonably request to evidence and secure the Loans and to perfect all Security Interests.
Confirmation of no default The Borrower will, within 2 Business Days after service by the Lender of a written request, serve on the Lender a notice which is signed by 2 directors of the Borrower and which:
(a) states that no Event of Default or Potential Event of Default has occurred; or
(b) states that no Event of Default or Potential Event of Default has occurred, except for a specified event or matter, of which all material details are given.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Consequences of Determination; Remedies of Indemnitee The Company shall be bound by and shall have no right to challenge a Favorable Determination. If an Adverse Determination is made, or if for any other reason the Company does not make timely indemnification payments or advances of Expenses, Indemnitee shall have the right to commence a Proceeding before a court of competent jurisdiction to challenge such Adverse Determination and/or to require the Company to make such payments or advances (and the Company shall have the right to defend its position in such Proceeding and to appeal any adverse judgment in such Proceeding). Indemnitee shall be entitled to be indemnified for all Expenses incurred in connection with such a Proceeding and to have such Expenses advanced by the Company in accordance with Section 8 of this Agreement. If Indemnitee fails to challenge an Adverse Determination within fifteen (15) business days, or if Indemnitee challenges an Adverse Determination and such Adverse Determination has been upheld by a final judgment of a court of competent jurisdiction from which no appeal can be taken, then, to the extent and only to the extent required by such Adverse Determination or final judgment, the Company shall not be obligated to indemnify or advance Expenses to Indemnitee under this Agreement.
Required Confidentiality Claim Form This is a requirement of the TIPS Contract and is non-negotiable. TIPS provides the required TIPS Confidentiality Claim Form in the "Attachments" section of this solicitation. Vendor must execute this form by either signing and waiving any confidentiality claim, or designating portions of Vendor's proposal confidential. If Vendor considers any portion of Vendor's proposal to be confidential and not subject to public disclosure pursuant to Chapter 552 Texas Gov’t Code or other law(s) and orders, Vendor must have identified the claimed confidential materials through proper execution of the Confidentiality Claim Form. If TIPS receives a public information act or similar request, any responsive documentation not deemed confidential by you in this manner will be automatically released. For Vendor documents deemed confidential by you in this manner, TIPS will follow procedures of controlling statute(s) regarding any claim of confidentiality and shall not be liable for any release of information required by law, including Attorney General determination and opinion. Notwithstanding any other Vendor designation of Vendor's proposal as confidential or proprietary, Vendor’s submission of this proposal constitutes Vendor’s agreement that proper execution of the required TIPS Confidentiality Claim Form is the only way to assert any portion of Vendor's proposal as confidential.
EVENTS CONSTITUTING MATERIAL BREACH OF AGREEMENT The Applicant shall be in Material Breach of this Agreement if it commits one or more of the following acts or omissions (each a “Material Breach”):
A. The Application, any Application Supplement, or any Application Amendment on which this Agreement is approved is determined to be inaccurate as to any material representation, information, or fact or is not complete as to any material fact or representation or such application;
B. The Applicant failed to complete Qualified Investment as required by Section 2.5.A. of this Agreement during the Qualifying Time Period;
C. The Applicant failed to create and maintain the number of New Qualifying Jobs required by the Act;
D. The Applicant failed to create and maintain the number of New Qualifying Jobs specified in Schedule C of the Application;
E. The Applicant failed to pay at least the average weekly wage of all jobs in the county in which the jobs are located for all New Non-Qualifying Jobs created by the Applicant;
F. The Applicant failed to provide payments to the District sufficient to protect future District revenues through payment of revenue offsets and other mechanisms as more fully described in Article IV of this Agreement;
G. The Applicant failed to provide the payments to the District that protect the District from the payment of extraordinary education-related expenses related to the project to the extent and in the amounts that the Applicant agreed to provide such payments in Article V of this Agreement;
H. The Applicant failed to provide the Supplemental Payments to the extent and in the amounts that the Applicant agreed to provide such Supplemental Payments in Article VI of this Agreement;
I. The Applicant failed to create and Maintain Viable Presence on or with the Qualified Property as more fully specified in Article VIII of this Agreement;
J. The Applicant failed to submit the reports required to be submitted by Section 8.2 to the satisfaction of the Comptroller;
K. The Applicant failed to provide the District or the Comptroller with all information reasonably necessary for the District or the Comptroller to determine whether the Applicant is in compliance with its obligations, including, but not limited to, any employment obligations which may arise under this Agreement;
L. The Applicant failed to allow authorized employees of the District, the Comptroller, the Appraisal District, or the State Auditor’s Office to have access to the Applicant’s Qualified Property or business records in order to inspect the project to determine compliance with the terms hereof or as necessary to properly appraise the Taxable Value of the Applicant’s Qualified Property under Sections 8.5 and 8.6;
M. The Applicant failed to comply with a request by the State Auditor’s office to review and audit the Applicant’s compliance with this Agreement;
N. The Applicant has made any payments to the District or to any other person or persons in any form for the payment or transfer of money or any other thing of value in recognition of, anticipation of, or consideration for this Agreement for limitation on Appraised Value made pursuant to Chapter 313 of the TEXAS TAX CODE, in excess of the amounts set forth in Articles IV, V and VI of this Agreement;
O. The Applicant failed to comply with the conditions included in the certificate for limitation issued by the Comptroller.