N o Litigation Sample Clauses

N o Litigation. To the knowledge of the Developer, there is no litigation or proceeding pending or threatened against or affecting the Developer respectively that would adversely affect the construction of the Project, or the priority or enforceability of this Agreement, the ability of the Developer to complete the Project or the ability of the Developer to perform their obligations under this Agreement. The City represents and warrants to the Developer that to the knowledge of the City, there is no litigation or proceeding pending or threatened against or affecting the City that would adversely affect the priority or enforceability of this Agreement or the ability of the City to perform its obligations under this Agreement or the Bond.
Sample 1
AutoNDA by SimpleDocs
N o Litigation. There are no legal, governmental or regulatory actions, suits or proceedings pending, nor, to the Company’s knowledge, any legal, governmental or regulatory investigations, including any proceeding before the United States Food and Drug Administration of the U.S. Department of Health and Human Services (the “FDA”) or comparable federal, state, local or foreign governmental authorities (it being understood that the interaction between the Company and the FDA and such comparable governmental authorities relating to the clinical development and product approval process shall not be deemed proceedings for purposes of this representation), to which the Company or a Subsidiary is a party or to which any property of the Company or any Subsidiary is the subject that, individually or in the aggregate, if determined adversely to the Company or any Subsidiary, would have a Material Adverse Effect or materially and adversely affect the ability of the Company to perform its obligations under this Agreement; to the Company’s knowledge, no such actions, suits or proceedings are threatened or contemplated in writing by any governmental or regulatory authority or threatened in writing by others that, individually or in the aggregate, if determined adversely to the Company or any Subsidiary, would have a Material Adverse Effect; and there are no current or pending legal, governmental or regulatory actions, suits, proceedings or, to the Company’s knowledge, investigations that are required under the Securities Act to be described in the Prospectus that are not described in the Prospectus (including any Incorporated Document). The Company is in compliance with all applicable federal, state, local and foreign laws, regulations, orders and decrees governing its business as enforced by the FDA, or any other federal, state or foreign agencies or bodies engaged in the regulation of medical devices, except where noncompliance would not, singularly or in the aggregate, reasonably be expected to have a Material Adverse Effect. All preclinical and clinical studies conducted by or on behalf of the Company to support clearance for commercialization of the Company’s products have been conducted by the Company, or to the Company’s knowledge by third parties, in compliance with all applicable federal, state or foreign laws, rules, orders and regulations, except for such failure or failures to be in compliance as would not reasonably be expected to have, singularly or in the aggregate, a Ma...
Sample 1
N o Litigation. Except as previously disclosed in writing to the Bureau, there is not now pending nor, to the knowledge of CONTRACTOR, threatened, any action, suit, or proceeding to which CONTRACTOR is a party, before or by any court or governmental agency or body, which might result in any material adverse change in CONTRACTOR ability to perform its obligations under this Contract, or any such action, suit, or proceeding related to environmental or civil rights matters: and no labor disturbance by the employees of CONTRACTOR exists or is imminent which might be expected to materially and adversely affect CONTRACTOR this Contract.
Sample 1

Related to N o Litigation

  • Alternative to Litigation 13.2.1 The Parties desire to resolve disputes arising out of this Agreement without litigation. Accordingly, the Parties agree to use the following Dispute Resolution procedures with respect to any controversy or claim arising out of or relating to this Agreement or its breach.

  • No Litigation No suit, action, arbitration, or legal, administrative, or other proceeding or governmental investigation is pending or, to Contractor’s knowledge, threatened against or affecting Contractor or Contractor’s business, financial condition, or ability to perform this Agreement, except any suit, action, arbitration, proceeding, or investigation that individually or in the aggregate with others will not or would not have a material adverse affect on Contractor’s business, the validity or enforceability of this Agreement, or Contractor’s ability to perform this Agreement.

  • No Litigation Pending There is no action, suit, proceeding or investigation pending or threatened against the Servicer which, either in any one instance or in the aggregate, may result in any material adverse change in the business, operations, financial condition, properties or assets of the Servicer, or in any material impairment of the right or ability of the Servicer to carry on its business substantially as now conducted, or in any material liability on the part of the Servicer, or which would draw into question the validity of this Agreement or of any action taken or to be taken in connection with the obligations of the Servicer contemplated herein, or which would be likely to impair materially the ability of the Servicer to perform under the terms of this Agreement;

  • No Litigation, Etc No suit, action or other proceeding, investigation, or injunction or final judgment relating thereto, shall be pending or threatened before any court or governmental agency in which it is sought to restrain or prohibit or to obtain damages or other relief in connection with any of the Transaction Documents or the consummation of the Transaction.

  • No Litigation Threatened No action or proceedings shall have been instituted or threatened before a court or other government body or by any public authority to restrain or prohibit any of the transactions contemplated hereby.

  • Pending Litigation Financial position and prospective long-term profitability of the Single Tenderer, and in the case the Tenderer is a JV, of each member of the JV, shall remain sound according to criteria established with respect to Financial Capability under paragraph I (i) above assuming that all pending litigation will be resolved against the Tenderer. Tenderer shall provide information on pending litigations as per Form CON-2.

  • Investigations; Litigation There is no investigation or review pending (or, to the knowledge of Parent, threatened) by any Governmental Entity with respect to Parent or any of its Subsidiaries which would have, individually or in the aggregate, a Parent Material Adverse Effect, and there are no actions, suits, inquiries, investigations or proceedings pending (or, to Parent’s knowledge, threatened) against or affecting Parent or its Subsidiaries, or any of their respective properties at law or in equity before, and there are no orders, judgments or decrees of, or before, any Governmental Entity, in each case which would have, individually or in the aggregate, a Parent Material Adverse Effect.

  • Related Litigation The party that delivers the Arbitration Notice to the other party shall have the option to also commence concurrent legal proceedings with any state or federal court sitting in Salt Lake County, Utah (“Litigation Proceedings”), subject to the following: (a) the complaint in the Litigation Proceedings is to be substantially similar to the claims set forth in the Arbitration Notice, provided that an additional cause of action to compel arbitration will also be included therein, (b) so long as the other party files an answer to the complaint in the Litigation Proceedings and an answer to the Arbitration Notice, the Litigation Proceedings will be stayed pending an Arbitration Award (or Appeal Panel Award (defined below), as applicable) hereunder, (c) if the other party fails to file an answer in the Litigation Proceedings or an answer in the Arbitration proceedings, then the party initiating Arbitration shall be entitled to a default judgment consistent with the relief requested, to be entered in the Litigation Proceedings, and (d) any legal or procedural issue arising under the Arbitration Act that requires a decision of a court of competent jurisdiction may be determined in the Litigation Proceedings. Any award of the arbitrator (or of the Appeal Panel (defined below)) may be entered in such Litigation Proceedings pursuant to the Arbitration Act.

  • No Proceeding or Litigation No suit, action, investigation, inquiry or other proceeding by any Authority or other person or entity will have been instituted or threatened which delays or questions the validity or legality of the transactions contemplated hereby or which, if successfully asserted, would, in the reasonable judgment of the Company, individually or in the aggregate, otherwise have a Material Adverse Effect on Parent's business, financial condition, prospects, assets or operations or prevent or delay the consummation of the transactions contemplated by this Agreement.

  • Third Party Litigation In the event that a Third Party institutes a patent or other infringement suit against any of NovaDel, PAR or HANA or any of its respective Affiliates during the Term, alleging manufacture, use or sale of a Licensed Product in the Territory, infringes one or more patent or other intellectual property rights held by such Third Party (an “Infringement Suit”), the Parties shall cooperate with one another in defending such suit. PAR, as the NDA holder, shall have the first right to direct and control, at its expense, any Infringement Suit (including settlement negotiations, settlement or compromise thereof) to the extent that it relates to the manufacture, use or sale of a Licensed Product but does not implicate the Licensed Technology or Licensed Process. In the event that the Infringement Suit relates to the use of the Licensed Technology or Licensed Process, NovaDel shall have the first right to direct and control, at its expense, any such Infringement Suit (including settlement negotiations, settlement or compromise thereof). To the extent that any amounts become payable to any Third Party as a result of such action, whether through judgment or settlement, then PAR shall, unless HANA is jointly promoting and commercializing the Licensed Product pursuant to Section 2.4 and subject to Section 12.2, bear [***] percent ([***]%) of such amounts with respect to the Exploitation of the Licensed Product; provided, however, that PAR shall have the right to credit [***] percent ([***]%) of any amounts paid by PAR through judgment or settlement with respect to such country against the royalty payments to be paid by PAR to HANA with respect to the sale of the Licensed Product under Section 6.3; provided further, however, that no royalty payment when due, regardless of the amount or number of credits available to PAR shall be reduced by more than [***] percent ([***]%) of the amounts otherwise owed pursuant to Section 6.3 in any calendar quarter. Credits not exhausted in any calendar quarter may be carried into future calendar quarters. Notwithstanding the foregoing, in the event that no payments are due or owing, or contemplated to be due or owing, by PAR to HANA under Article 6 with respect to the sale of the Licensed Product, then NovaDel shall pay to PAR such amount owed to a Third Party up to a cap of [***]% of such amount owed to such Third Party, less any amount already credited to PAR under this Section 10.3. Notwithstanding the foregoing, NovaDel shall have no obligation under this Section 10.3 for any costs, expenses or damages that are paid or payable to a Third Party as a result of an actual or alleged infringement by PAR or HANA to the extent such costs, expenses or damages result from the use of a Product Trademark.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!