Necessity of Repaving Sample Clauses

Necessity of Repaving. If two (2) or more Owners dispute the necessity of repaving the Access Driveways, the Repaving Owner may either (i) submit the matter of whether such repaving is necessary to arbitration, or (ii) repave the Access Driveways and then submit the matter of whether the repaving was necessary to arbitration. If the Repaving Owner elects to repave the Access Driveways, and then submits the matter to arbitration and the arbitrator finds that the repaving was necessary, the other Owners shall reimburse the Repaving Owner pursuant to Section 3.5 of this Declaration, together with a reimbursement of the costs for the arbitration; however, if the arbitrator finds that the repaving was not necessary, the Repaving Owner shall bear the full cost of the Repaving Expenses. Arbitration proceedings initiated pursuant to this Section 3.4 shall be held in California, in a venue to be mutually agreed upon by the Owners, within thirty (30) days after the election to arbitrate is made pursuant to the then applicable Commercial Arbitration Rules of the American Arbitration Association; provided, however, that (i) the decision of any such arbitration shall be expressly limited to the issue of the necessity for repaving the Access Driveways, (ii) there shall be no right of discovery, and each party shall submit supporting material for its position regarding the repaving issue to the arbitrator as the sole admittable evidence.
AutoNDA by SimpleDocs

Related to Necessity of Repaving

  • Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.

  • Cost of Repairs 54.1 Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and the end of the Defects Correction periods shall be remedied by the Contractor at the Contractor's cost if the loss or damage arises from the Contractor's acts or omissions.

  • REMOVAL OF RECORDS FROM PREMISES Where performance of the Contract involves use by the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) of Authorized User owned or licensed papers, files, computer disks or other electronic storage devices, data or records at Authorized User facilities or offices, or via remote access, the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) shall not remotely access, modify, delete, copy or remove such Records without the prior written approval of the Authorized User. In no case, with or without the written approval of the Authorized User, can the Authorized User data be accessed, moved or sent outside the continental United States.

  • Removal of Improvements Grantor shall not demolish or remove any Improvements from the Real Property without Lender's prior written consent. As a condition to the removal of any Improvements, Lender may require Grantor to make arrangements satisfactory to Lender to replace such Improvements with Improvements of at least equal value.

  • Performance of Replacements (a) Borrower shall make Replacements when required in order to keep the Property in condition and repair consistent with other similar properties in the same market segment in the metropolitan area in which the Property is located, and to keep the Property or any portion thereof from deteriorating. Borrower shall complete all Replacements in a good and workmanlike manner as soon as practicable following the commencement of making each such Replacement. (b) Lender reserves the right, at its option, to approve all contracts or work orders with materialmen, mechanics, suppliers, subcontractors, contractors or other parties providing labor or materials under contracts for an amount in excess of $100,000 in connection with the Replacements performed by Borrower. Upon Lender's request, Borrower shall assign any contract or subcontract to Lender. (c) In the event Lender determines in its reasonable discretion that any Replacement is not being performed in a workmanlike or timely manner or that any Replacement has not been completed in a workmanlike or timely manner, and such failure continues to exist for more than thirty (30) days after notice from Lender to Borrower, Lender shall have the option, upon ten (10) days notice to Borrower (except in the case of an emergency), to withhold disbursement for such unsatisfactory Replacement and to proceed under existing contracts or to contract with third parties to complete such Replacement and to apply the Replacement Reserve Fund toward the labor and materials necessary to complete such Replacement, and to exercise any and all other remedies available to Lender upon an Event of Default hereunder. (d) In order to facilitate Lender's completion or making of the Replacements pursuant to Section 7.3.3

  • Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.

  • Effect of Replacement In the event of the substitution of an Airframe or of a Replacement Engine pursuant to Section 10 of the Lease, all provisions of this Trust Indenture relating to the Airframe or Engine or Engines being replaced shall be applicable to such Replacement Airframe or Replacement Engine or Engines with the same force and effect as if such Replacement Airframe or Replacement Engine or Engines were the same airframe or engine or engines, as the case may be, as the Airframe or Engine or Engines being replaced but for the Event of Loss with respect to the Airframe or Engine or Engines being replaced.

  • Surrender of Premises Ownership and Removal of Trade Fixtures 23.1 No act or thing done by Landlord or any agent or employee of Landlord during the Lease Term shall be deemed to constitute an acceptance by Landlord of a surrender of the Premises unless such intent is specifically acknowledged in writing by Landlord. The delivery of keys to the Premises to Landlord or any agent or employee of Landlord shall not constitute a surrender of the Premises or effect a termination of this Lease, whether or not the keys are thereafter retained by Landlord, and notwithstanding such delivery Tenant shall be entitled to the return of such keys at any reasonable time upon request until this Lease shall have been properly terminated. The voluntary or other surrender of this Lease by Xxxxxx, whether accepted by Landlord or not, or a mutual termination hereof, shall not work a merger, and at the option of Landlord shall operate as an assignment to Landlord of all subleases or subtenancies affecting the Premises or terminate any or all such subtenants or subtenancies. 23.2 Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 23 and section 8.2 above, quit and surrender possession of the Premises to Landlord in as good order and condition as when Xxxxxx took possession, ordinary wear and tear and damage thereto by fire or other casualty excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions, voice and data cabling and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed; provided, however, that in lieu of removing certain cabling, Tenant shall, at Landlord's request, abandon and leave in place, without additional payment to Tenant or credit against rent, any cabling (including conduit) designated by Landlord and installed in the Premises or elsewhere in the Building by or on behalf of Tenant (including all connections for such cabling), in a neat and safe condition in accordance with the requirements of all applicable Legal Requirements, including the National Electric Code or any successor statute, and terminated at both ends of a connector, properly labeled at each end and in each electrical closet and junction box. Any such property not so removed by Tenant shall be deemed to be abandoned and at the option of Landlord shall either (a) become Landlord's property without any payment to Tenant or (b) remain Tenant's property, but Landlord shall have the right to sell or otherwise dispose of such personal property in any commercially reasonable manner, provided that any proceeds realized from the sale of Tenant's property shall be applied first to offset all expenses of storage and sale, then credited against Tenant's outstanding obligations under this Lease (including, without limitation, past due rent amounts and any termination damages owing by Tenant to Landlord pursuant to Article 19 hereof), and any remaining balance shall be returned to Tenant.

  • Maintenance, Alteration and Repair (a) Resident is responsible for and agrees to take good care of the premises, fixtures and all common areas. Resident may not remove any of Owner’s property and will not perform any repairs, upgrades, painting, wallpapering, electric changes or other alterations of the premises without prior written consent from Owner. Resident will be responsible for damage from waste stoppages caused by foreign or improper objects or improper use in lines serving bathrooms, damage to fixtures, appliances, doors, windows, screens, damage from water faucets left on or from doors left open, and repairs or replacements to alarm devices necessitated by misuse or damage by Resident and/or guests. Extraordinary appliances or furnishings such as satellite dishes, hot tubs, pool tables, water beds or high utility-consuming devices may not be installed or placed on the premises or anywhere at the Property without Owner’s prior written consent, in its sole discretion. SAMPLE (b) In the case of a malfunction of any utilities or damage by fire, water or similar cause, or any water leak, suspected mold or microbial growth, electrical problem, broken glass, broken lock or any other condition that Resident reasonably believes poses a hazard to health and safety, Resident must promptly notify Owner in writing. Owner will act with reasonable time and diligence in making repairs and reconnections; Resident may not withhold or reduce payment of rent or other charges during such time. Maintenance and repair requested by Resident will generally be performed between 8am and 8pm, unless the work is considered an emergency, in which case work may take place at any time. Owner may temporarily disconnect equipment or utilities to avoid property damage and/or to perform repairs requiring such interruption, in Owner’s sole discretion. Owner will not be liable for any inconvenience, discomfort, disruption or interference with Resident use of the premises because of ongoing repairs, alterations or improvements to the Property or any apartment. (c) Following move-in, Resident is responsible for providing and changing all light bulbs and batteries (for smoke detectors and remote controls) in the assigned apartment. A written maintenance report requesting assistance in changing these items may be submitted for maintenance staff assistance, with extra charges payable by Resident as applicable per Owner’s published rates. From time to time, maintenance staff may enter the assigned apartment with or without notice to inspect and change furnace filters and to provide pest control.

  • Condition of Improvements The risk of destruction or substantial damage by fire or Act of God prior to delivery of deed is assumed by Seller. Xxxxxx agrees that on possession, the Real Estate shall be in the same condition as it is on the date of this contract, except for ordinary wear and tear. If the Real Estate should be damaged or destroyed by fire or other casualty and if, prior to Closing, the real Estate shall not be repaired or restored by and at the Sellers expense, to a condition as good as it was prior to the damage or destruction, then Purchaser, at his option, may terminate this contract by written notice to Seller and the Down Payment Shall be returned to Purchaser. While this contract is pending, Sellers shall not change any existing lease or enter into any new lease, nor make any substantial alterations or repairs without the consent of the Purchaser. In addition, the Purchaser also has an insurable interest in the property from date of this contract. Purchaser is hereby notified that insurance should be placed upon the property immediately to protect Purchasers’ interest.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!