Time Extensions 2.03.1 If Contractor requests an extension of time to complete its performance, then the Director, in consultation with the CPO, may, in his or her sole discretion, extend the time so long as the extension does not exceed 90 days. The extension must be in writing but does not require amendment of this Agreement. Contractor is not entitled to damages for delay(s) regardless of the cause of the delay(s).
Time Extension CONTRACTOR shall provide a time extension request on completion of Task Order for delays caused by others (Permitting Agencies, COUNTY or Contract Cities, or unforeseen conditions such as inclement weather, etc.) and at no fault by CONTRACTOR, subject to approval by COUNTY. COUNTY will review the request and determine in its sole discretion whether the situation warrant a time extension at no-cost or with costs. If CONTRACTOR completes the Task Order beyond the stipulated completion date without COUNTY’s specific written approval for time extension, CONTRACTOR will be subject to liquidated damages and may be construed as non-responsive, which may affect CONTRACTOR for considerations for future Task Orders or projects.
Contract Extensions This Contract may be extended on an annual basis beyond the Initial Term if the Local Board successfully meets the terms of the Contract for at least three or more years as determined by the State Board.
Complete Work without Extra Cost Except to the extent otherwise specifically stated in this contract, the Contractor shall obtain and provide, without additional cost to the City, all labor, materials, equipment, transportation, facilities, services, permits, and licenses necessary to perform the Work.
CAISO Monthly Billed Fuel Cost [for Geysers Main only] The CAISO Monthly Billed Fuel Cost is given by Equation C2-1. CAISO Monthly Billed Fuel Cost Equation C2-1 = Billable MWh ◆ Steam Price ($/MWh) Where: • Steam Price is $16.34/MWh. • For purposes of Equation C2-1, Billable MWh is all Billable MWh Delivered after cumulative Hourly Metered Total Net Generation during the Contract Year from all Units exceeds the Minimum Annual Generation given by Equation C2-2. Equation C2-2 Minimum Annual Generation = (Annual Average Field Capacity ◆ 8760 hours ◆ 0.4) - (A+B+C) Where: • Annual Average Field Capacity is the arithmetic average of the two Field Capacities in MW for each Contract Year, determined as described below. Field Capacity shall be determined for each six-month period from July 1 through December 31 of the preceding calendar year and January 1 through June 30 of the Contract Year. Field Capacity shall be the average of the five highest amounts of net generation (in MWh) simultaneously achieved by all Units during eight-hour periods within the six-month period. The capacity simultaneously achieved by all Units during each eight-hour period shall be the sum of Hourly Metered Total Net Generation for all Units during such eight-hour period, divided by eight hours. Such eight-hour periods shall not overlap or be counted more than once but may be consecutive. Within 30 days after the end of each six-month period, Owner shall provide CAISO and the Responsible Utility with its determination of Field Capacity, including all information necessary to validate that determination. • A is the amount of Energy that cannot be produced (as defined below) due to the curtailment of a Unit during a test of the Facility, a Unit or the steam field agreed to by CAISO and Owner. • B is the amount of Energy that cannot be produced (as defined below) due to the retirement of a Unit or due to a Unit’s Availability remaining at zero after a period of ten Months during which the Unit’s Availability has been zero. • C is the amount of Energy that cannot be produced (as defined below) because a Force Majeure Event reduces a Unit’s Availability to zero for at least thirty (30) days or because a Force Majeure Event reduces a Unit’s Availability for at least one hundred eighty (180) days to a level below the Unit Availability Limit immediately prior to the Force Majeure Event. • The amount of Energy that cannot be produced is the sum, for each Settlement Period during which the condition applicable to A, B or C above exists, of the difference between the Unit Availability Limit immediately prior to the condition and the Unit Availability Limit during the condition.
Preliminary Cost Estimate Consulting Engineer/Architect shall furnish City an estimate of probable Construction Cost based on the preliminary design. Consulting Engineer/Architect's estimate of probable Construction Cost is to be made on the basis of Consulting Engineer/Architect's experience and qualifications and represent Consulting Engineer/Architect's best judgment as an experienced and qualified design professional, familiar with the construction industry.
Labor Costs 6.2.1 Wages of construction workers directly employed by the Construction Manager to perform the construction of the Work at the site or, with the Owner’s prior approval, at off-site workshops.
GMP Cost Limitation The Guaranteed Maximum Price shall not be in excess of the GMP Cost Limitation.
Contract Extension The City may, in its sole discretion, unilaterally exercise an option to extend the Contract as described in the Contract Documents. In addition, the City may, in its sole discretion, unilaterally extend the Contract on a month-to-month basis following contract expiration if authorized under Charter section 99 and the Contract Documents. Contractor shall not increase its pricing in excess of the percentage increase described in the Contract.
Development Costs With respect to activities prior to the Amendment Effective Date, each Party was to pay [*] of the total Direct Development Costs of a Product incurred in accordance with the Development Budget (as defined in the Original Agreement). Notwithstanding anything in this Article 6 of this Agreement or in any other provision of this Agreement to the contrary, with respect to activities on and after the Amendment Effective Date, subject to Sections 3.1.2, Alimera will be solely responsible for, and shall pay one hundred percent (100%) of, all development costs of a Product, including Direct Development Costs. Notwithstanding anything in this Article 6 of this Agreement or in any other provision of this Agreement to the contrary, (i) all payments owing by CDS hereunder with respect to development activities prior to the Amendment Effective Date are hereby deemed fully paid by CDS (or waived, to the extent such waiver may be required), including any Development Payments, Compounded Development Payments, Determined Disputed Costs and Compounded Disputed Costs (as all defined in the Original Agreement), further including any penalties and interest which might have accrued with respect thereto, and further including all CDS payments deferred pursuant to that February 11, 2008 letter agreement sent by CDS and executed by CDS and Alimera regarding deferral of payments under the Original Agreement as of such date; (ii) all payments owing by Alimera hereunder with respect to development activities prior to the Amendment Effective Date are hereby deemed fully paid by Alimera (or waived, to the extent such waiver may be required), including any Development Payments, Compounded Development Payments, Determined Disputed Costs and Compounded Disputed Costs (as all defined in the Original Agreement), and further including any penalties and interest which might have accrued with respect thereto; and (iii) subject to Sections 3.1.1 and 3.1.2, from and after the Amendment Effective Date, CDS will have no liability whatsoever hereunder for any past, present or future development costs, including Direct Development Costs (which includes those incurred before, on and after the Amendment Effective Date), and instead Alimera shall have sole liability therefor.
