Notice of Claim or Dispute Sample Clauses

Notice of Claim or Dispute. In the event of any dispute, controversy, or claim arising out of or relating to this Subcontract or the Subcontract Work (“Subcontractor Claim”), Subcontractor will provide written notice to TRC within seven (7) Days following the occurrence of the event on which such claim is based, or at least five (5) Days prior to the time required by the Prime Contract, whichever is earlier, and in any event will provide such notice before either performing any work which it may contend is beyond the scope of its obligations and in any event before allowing the conditions leading to the event to be covered or changed. The notice will describe in detail the nature of the claim or dispute. Any claim not timely presented as required in this Section is hereby expressly waived by Subcontractor. Upon request by TRC, Subcontractor will promptly provide detailed information to support any claim for additional time or compensation.
Sample 1
AutoNDA by SimpleDocs
Notice of Claim or Dispute. For each claim or dispute which the XXXX has against or with the City (except for any claim for an equitable adjustment under Section 3.02 which is subject to the 30-day limitation set forth therein), notice of the claim must be submitted in writing to the City's Representative within thirty (30) days after the claim or dispute arises. The purpose of written notification is to place the City on notice so that proper measures can be taken to properly consider the claim, and if necessary, defend against the claim or dispute, and the failure to give such notice shall preclude the XXXX from subsequently mediating that particular claim or dispute pursuant to Section 10.20C of this Agreement, and the XXXX shall have no further recourse against the City. Pending a final decision on the claim or dispute under Sections 10.208 or 10.20C, the XXXX shall proceed diligently with the performance of this Agreement.
Sample 1

Related to Notice of Claim or Dispute

  • Notice of Claim Promptly after receipt by an Investor Indemnitee or Company Indemnitee of notice of the commencement of any action or proceeding (including any governmental action or proceeding) involving an Indemnified Liability, such Investor Indemnitee or Company Indemnitee, as applicable, shall, if a claim for an Indemnified Liability in respect thereof is to be made against any indemnifying party under this Article V, deliver to the indemnifying party a written notice of the commencement thereof; but the failure to so notify the indemnifying party will not relieve it of liability under this Article V except to the extent the indemnifying party is prejudiced by such failure. The indemnifying party shall have the right to participate in, and, to the extent the indemnifying party so desires, jointly with any other indemnifying party similarly noticed, to assume control of the defense thereof with counsel mutually reasonably satisfactory to the indemnifying party and the Investor Indemnitee or Company Indemnitee, as the case may be; provided, however, that an Investor Indemnitee or Company Indemnitee shall have the right to retain its own counsel with the actual and reasonable third party fees and expenses of not more than one counsel for such Investor Indemnitee or Company Indemnitee to be paid by the indemnifying party, if, in the reasonable opinion of counsel retained by the indemnifying party, the representation by such counsel of the Investor Indemnitee or Company Indemnitee and the indemnifying party would be inappropriate due to actual or potential differing interests between such Investor Indemnitee or Company Indemnitee and any other party represented by such counsel in such proceeding. The Investor Indemnitee or Company Indemnitee shall cooperate fully with the indemnifying party in connection with any negotiation or defense of any such action or claim by the indemnifying party and shall furnish to the indemnifying party all information reasonably available to the Investor Indemnitee or Company Indemnitee which relates to such action or claim. The indemnifying party shall keep the Investor Indemnitee or Company Indemnitee reasonably apprised as to the status of the defense or any settlement negotiations with respect thereto. No indemnifying party shall be liable for any settlement of any action, claim or proceeding effected without its prior written consent, provided, however, that the indemnifying party shall not unreasonably withhold, delay or condition its consent. No indemnifying party shall, without the prior written consent of the Investor Indemnitee or Company Indemnitee, consent to entry of any judgment or enter into any settlement or other compromise which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Investor Indemnitee or Company Indemnitee of a release from all liability in respect to such claim or litigation. Following indemnification as provided for hereunder, the indemnifying party shall be subrogated to all rights of the Investor Indemnitee or Company Indemnitee with respect to all third parties, firms or corporations relating to the matter for which indemnification has been made. The indemnification required by this Article V shall be made by periodic payments of the amount thereof during the course of the investigation or defense, as and when bills are received and payment therefor is due.

  • Notice of Claims Within thirty (30) days after a Person seeking indemnification hereunder (hereinafter the “Indemnified Party”) has received notice of or has acquired knowledge of any claim by any Person not a Party to this Agreement of the commencement or threatened commencement of any action or proceeding by any Person not a Party to this Agreement (“third party claim”) or has acquired knowledge of any other claim hereunder against another Party hereto (“first party claim”) the Indemnified Party shall, if such claim is indemnifiable by the other Party pursuant hereto (hereinafter the “Indemnifying Party”), give the Indemnifying Party written notice of such claim and the commencement or threatened commencement of such action or proceeding, if any. Such notice shall state the nature and basis of such claim, and, if ascertainable, the amount thereof. Notwithstanding the foregoing, the failure of the Indemnified Party to give such notice shall not excuse the Indemnifying Party’s obligation to indemnify and, in the case of a third party claim, defend the Indemnified Party, except to the extent the Indemnifying Party has suffered damage or prejudice by reason of the Indemnified Party’s failure to give or delay in giving such notice. Within ten (10) business days of receipt of any notice issued by the Indemnified Party pursuant to this Section 12.3, the Indemnifying Party shall notify the Indemnified Party whether the Indemnifying Party acknowledges its indemnification obligation and, in the case of a third party claim, its defense obligation with respect to the claim which was the subject of the Indemnified Party’s notice or whether it disclaims such obligations. In the event the Indemnifying Party disclaims or fails to timely acknowledge its obligations with respect to any claim by the Indemnified Party relating to any third party claim, the Indemnified Party shall have the right to defend such claim, with counsel of its own selection, and compromise such claim without prejudice to its right to indemnification hereunder. In the event the Indemnifying Party timely acknowledges its obligations hereunder with respect to any third party claim, the Indemnifying Party shall defend the same with counsel in accordance with this Section. Where the Indemnifying Party shall have acknowledged in writing its obligations hereunder with respect to any third party claim, the Indemnified Party may, at its expense, participate in the defense of such third party claim and no such third party claim shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party which consent shall not be unreasonably withheld or delayed. At any time after the Indemnifying Party acknowledges its obligations hereunder with respect to any third party claim, the Indemnifying Party may request the Indemnified Party to agree in writing to the payment or compromise of such third party claim (provided such payment or compromise has been previously approved in writing by the third party claimant), and, in the event the Indemnifying Party does so, the Indemnified Party shall promptly agree in writing to such settlement, unless such settlement would involve a remedy or remedies, other than the payment of money damages by the Indemnifying Party, to which the Indemnified Party reasonably objects.

  • Notice of Claims, etc Promptly after receipt by an indemnified party of notice of the commencement of any action or proceeding involving a claim referred to in the preceding subdivisions of this Section 5, such indemnified party will, if a claim in respect thereof is to be made against an indemnifying party, give written notice to the latter of the commencement of such action, provided, however, that the failure of any indemnified party to give notice as provided herein shall not relieve the indemnifying party of its obligations under the preceding subdivisions of this Section 5. In case any such action is brought against an indemnified party, unless in such indemnified party's reasonable judgment a conflict of interest between such indemnified and indemnifying party may exist in respect of such claim, the indemnifying party shall be entitled to participate in, and to assume the defense thereof, jointly with any other indemnifying party similarly notified, to the extent that it may wish, with counsel reasonably satisfactory to such indemnified party, and after notice from the indemnifying party to such indemnified party of its election so to assume the defense thereof, the indemnifying party shall not be liable to such indemnified party for any legal or other expenses subsequently incurred by the latter in connection with the defense thereof other than reasonable costs of investigation. No indemnifying party shall, without the consent of the indemnified party, consent to entry of any judgment or enter into any settlement of such proceedings which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such indemnified party of a complete and unconditional release from all liability in respect to such claim or litigation.

  • Arbitration Notice BY INITIALING IN THE SPACE BELOW YOU ARE AGREEING TO HAVE ANY DISPUTE ARISING OUT OF THE MATTERS INCLUDED IN THE "ARBITRATION OF DISPUTES" PROVISION DECIDED BY NEUTRAL ARBITRATION AS PROVIDED BY CALIFORNIA LAW AND YOU ARE GIVING UP ANY RIGHTS YOU MIGHT POSSESS TO HAVE THE DISPUTE LITIGATED IN COURT OR JURY TRIAL. BY INITIALING IN THE SPACE BELOW YOU ARE GIVING UP YOUR JUDICIAL RIGHTS TO DISCOVERY AND APPEAL, UNLESS SUCH RIGHTS ARE SPECIFICALLY INCLUDED IN THE "ARBITRATION OF DISPUTES" PROVISION. IF YOU REFUSE TO SUBMIT TO ARBITRATION AFTER AGREEING TO THIS PROVISION, YOU MAY BE COMPELLED TO ARBITRATE UNDER THE AUTHORITY OF THE CALIFORNIA CODE OF CIVIL PROCEDURE. YOUR AGREEMENT TO THIS ARBITRATION PROVISION IS VOLUNTARY.

  • Claim Notice A Party that seeks indemnity under this Article X (an “Indemnified Party”) will give written notice (a “Claim Notice”) to the Party from whom indemnification is sought (an “Indemnifying Party”), whether the Damages sought arise from matters solely between the Parties or from Third Party Claims. The Claim Notice must contain (i) a description and, if known, estimated amount (the “Claimed Amount”) of any Damages incurred or reasonably expected to be incurred by the Indemnified Party, (ii) a reasonable explanation of the basis for the Claim Notice to the extent of facts then known by the Indemnified Party, and (iii) a demand for payment of those Damages. No delay or deficiency on the part of the Indemnified Party in so notifying the Indemnifying Party will relieve the Indemnifying Party of any liability for Damages or obligation hereunder except to the extent of any Damages caused by or arising out of such failure.

  • Notice of Dispute The party wishing to commence the dispute resolution process must give written notice (Notice of Dispute) to the other parties of: (a) The nature of the dispute, (b) The alleged basis of the dispute, and (c) The position which the party issuing the Notice of Dispute believes is correct.

  • Notice of Direct Claims Any claim for indemnification or contribution under this Agreement or any Ancillary Agreement that does not result from a Third-Party Claim shall be asserted by written notice given by the Indemnitee to the applicable Indemnifying Party; provided, that the failure by an Indemnitee to so assert any such claim shall not prejudice the ability of the Indemnitee to do so at a later time except to the extent (if any) that the Indemnifying Party is prejudiced thereby. Such Indemnifying Party shall have a period of thirty (30) days after the receipt of such notice within which to respond thereto. If such Indemnifying Party does not respond within such thirty (30)-day period, such specified claim shall be conclusively deemed a Liability of the Indemnifying Party under this Section 4.6(b) or, in the case of any written notice in which the amount of the claim (or any portion thereof) is estimated, on such later date when the amount of the claim (or such portion thereof) becomes finally determined. If such Indemnifying Party does not respond within such thirty (30)-day period or rejects such claim in whole or in part, such Indemnitee shall, subject to the provisions of Article VII, be free to pursue such remedies as may be available to such party as contemplated by this Agreement and the Ancillary Agreements, as applicable, without prejudice to its continuing rights to pursue indemnification or contribution hereunder.

  • Dispute Notice If there is a dispute between the parties, then either party may give a notice to the other succinctly setting out the details of the dispute and stating that it is a dispute notice given under this clause 17.1.

  • Notice and contest of claims In the event that either Party receives a claim or demand from a third party in respect of which it is entitled to the benefit of an indemnity under this Article 38 (the "Indemnified Party") it shall notify the other Party (the "Indemnifying Party") within 15 (fifteen) days of receipt of the claim or demand and shall not settle or pay the claim without the prior approval of the Indemnifying Party, which approval shall not be unreasonably withheld or delayed. In the event that the Indemnifying Party wishes to contest or dispute the claim or demand, it may conduct the proceedings in the name of the Indemnified Party, subject to the Indemnified Party being secured against any costs involved, to its reasonable satisfaction.

  • Audit Dispute In the event of a dispute with respect to any audit conducted under Section 6.10.1, Xxxxxxx and Forest shall work in good faith to resolve the disagreement. If the Parties are unable to reach a mutually acceptable resolution of any such dispute within [*] days, the dispute shall be submitted for resolution to a certified public accounting firm jointly selected by each Party’s certified public accountants or to such other Person as the Parties shall mutually agree (the “Accountant”). The decision of the Accountant shall be final and the costs of such arbitration as well as the initial audit shall be borne between the Parties in such manner as the Accountant shall determine. If the Accountant concludes that additional payments were owed, or that excess payments were made during such period, then the Party owing such additional payments shall pay such additional amounts, or the Party that received such excess payments shall reimburse such excess payments, as applicable, in either case, within [*] days after the date on which such decision is made by the Accountant.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!