Common use of Notice of Delay Clause in Contracts

Notice of Delay. The Contractor shall notify the Government if the contractor receives a notice of any change in the work, or if any other conditions arise that may cause or are actually causing delays and the Contractor believes may result in completion of the project after the completion date. The notification shall state the effect, if any, of such change or other conditions upon the approved schedule, and shall state in what respects, if any, the relevant schedule or the completion date should be revised. The Contractor shall give such notice promptly, not more than ten (10) days following the first occurrence of event giving rise to the delay or prospective delay. The Contractor shall obtain the approval of the Contracting Officer for any revisions to the approved time schedule.

Notice of Delay. The In the event the Contractor shall notify the Government if the contractor receives a notice of any change in the work, or if any other conditions arise that may which are likely to cause or are actually causing delays and which the Contractor believes may result in completion of the project after the completion date. The notification , the Contractor shall state notify the Contracting Officer of the effect, if any, of such change or other conditions upon the approved schedule, and shall state in what respects, if any, the relevant schedule or the completion date should be revised. The Contractor Such notice shall give such notice be given promptly, and not more than ten (10) days following the first occurrence of event giving rise to the delay or prospective delay. The Contractor Revisions to the approved time schedule shall obtain only be made with the approval of the Contracting Officer for any revisions to the approved time scheduleOfficer.

Notice of Delay. The If the Contractor shall notify the Government if the contractor receives a notice of any change in the work, or if any other conditions arise that may which are likely to cause or are actually causing delays and which the Contractor believes may result in late completion of the project after project, the completion dateContractor shall notify the Contracting Officer. The notification Contractor’s notice shall state the effect, if any, of such change or other conditions upon the approved schedule, and shall state in what respects, if any, the relevant schedule or the completion date should be revised. The Contractor shall give such this notice promptly, not more than ten (10) days following after the first occurrence of event event-giving rise to the delay or prospective delay. The Contractor shall obtain the approval of Only the Contracting Officer for any may make revisions to the approved time schedule.

Notice of Delay. The Contractor contractor shall notify the Government if the contractor receives a notice of any change in the work, or if any other conditions arise that may cause or are actually causing delays and the Contractor contractor believes may result in completion of the project after the completion date. The notification shall state the effect, if any, of such change or other conditions upon the approved schedule, and shall state in what respects, if any, the relevant schedule or the completion date should be revised. The Contractor contractor shall give such notice promptly, not more than ten (10) days following the first occurrence of event giving rise to the delay or prospective delay. The Contractor contractor shall obtain the approval of the Contracting Officer for any revisions to the approved time schedule.

Notice of Delay. The In the event the Contractor shall notify the Government if the contractor receives a notice of any change in the work, or if any other conditions arise that may which are likely to cause or are actually causing delays and which the Contractor believes may result in completion of the project after the completion date. The notification , the Contractor shall state notify the Contracting Officer of the effect, if any, of such change or other conditions upon the approved schedule, and shall state in what respects, if any, the relevant schedule or the completion date should be revised. The Contractor Such notice shall give such notice be given promptly, and not more than ten (10) days following the first occurrence of event giving rise to the delay or prospective delay. The Contractor shall obtain the approval of the Contracting Officer for any revisions to the approved time schedule.ten