Common use of NOTICE OF LABOR DISPUTES Clause in Contracts

NOTICE OF LABOR DISPUTES. (a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, to the Authority. (b) The Contractor agrees to insert the substance of this paragraph, including this subparagraph (b), in any Sub- contract under which a labor dispute may delay the timely performance of this Contract; except that each Subcontract shall provide that in the event its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor shall immediately notify the next higher tier Subcontractor or the Contractor, as the case may be, of all relevant information concerning the dispute.

NOTICE OF LABOR DISPUTES. (a) A. If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, information to the AuthorityOWNER. (b) B. The Contractor agrees to insert the substance of this paragraphArticle, including this subparagraph paragraph (bB), in any Sub- contract subcontract under which a labor dispute may delay the timely performance of this Contract; except that each Subcontract subcontract shall provide that in the event its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor subcontractor shall immediately notify the next higher tier Subcontractor subcontractor or the Contractor, as the case may be, of all relevant information concerning the dispute.

NOTICE OF LABOR DISPUTES. (a) If Whenever the Contractor SELLER has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor SELLER shall immediately shall give noticenotice thereof, including all relevant informationinformation with respect thereto, to the Authority.LOCKHEED XXXXXX (b) The Contractor SELLER agrees to insert the substance of this paragraphclause, including this subparagraph paragraph (b), in any Sub- contract under Subcontract hereunder as to which a labor dispute may delay the timely performance of this Contract; except that each such Subcontract shall provide that in the event its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor shall immediately notify the its next higher tier Subcontractor subcontractor or the Contractor, LOCKHEED XXXXXX as the case may be, of all relevant information concerning the such dispute.

NOTICE OF LABOR DISPUTES. (a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, to the Authority. (b) The Contractor agrees to insert the substance of this paragraph, including this subparagraph paragraph (b), in any Sub- contract Subcon- tract under which a labor dispute may delay the timely performance of this Contract; except that each Subcontract shall provide that in the event its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor shall immediately notify the next higher tier Subcontractor or the Contractor, as the case may be, of all relevant information concerning the dispute.

NOTICE OF LABOR DISPUTES. (a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this ContractContract Modification, the Contractor immediately shall give notice, including all relevant information, to the AuthorityContracting Officer. (b) The Contractor agrees to insert the substance of this paragraph, including this subparagraph paragraph (b), in any Sub- contract Subcontract under which a labor dispute may delay the timely performance of this ContractContract Modification; except that each Subcontract shall provide that in the event its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor shall immediately notify the next higher tier Subcontractor or the Contractor, as the case may be, of all relevant information concerning the dispute.

NOTICE OF LABOR DISPUTES. (a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, to the AuthorityContracting Officer. (b) The Contractor agrees to insert the substance of this paragraphsubparagraph, including this subparagraph (b), in any Sub- contract Subcontract under which a labor dispute may delay the timely performance of this Contract; except that each Subcontract shall provide that in the event its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor shall immediately notify the next higher tier Subcontractor or the Contractor, as the case may be, of all relevant information concerning the dispute.