NOTICE OF OVERRUNS AND DELAYS Sample Clauses

NOTICE OF OVERRUNS AND DELAYS. The Contractor shall promptly give written notice to the Trust representative of the occurrence of an event or action, the discovery of a condition or the failure of an event or action to occur or a condition to exist as anticipated, that may result in an increase in (a) the compensation due Contractor; (b) reimbursable expenses and/or; (c) the number of hours necessary to perform the work or which may delay completion of the work (or extend the completion date). For purposes of this provision, “promptly” shall mean as soon as possible but in no event more than (3) business days after Contractor’s discovery of the occurrence, condition or failure which gives rise to the subject increase and/or delay.
Sample 1Sample 2Sample 3See All (4)
AutoNDA by SimpleDocs
NOTICE OF OVERRUNS AND DELAYS. The Contractor shall promptly give written notice to the Corporation’s Representative of the occurrence of an event or action, the discovery of a condition or the failure of an event or action to occur or a condition to exist as anticipated, which may result in an increase in: (a) the compensation due Contractor; (b) reimbursable expenses; (c) the number of hours necessary to perform the work; and/or (d) which may delay completion of the work or extend the Completion Date.
Sample 1Sample 2Sample 3
NOTICE OF OVERRUNS AND DELAYS. Consultant shall promptly give written notice to the LMDC ’s Representative and Chief Financial Officer of the occurrence of an event or action, the discovery of a condition or the failure of an event or action to occur or a condition to exist as anticipated, which may result in an increase in (a) the compensation due Consultant; (b) reimbursable expenses , and/or (c) the number of hours necessa ry to perform the work. Consultant shall give prompt written notice to the LMDC Representative of the occurrence of an event or action, discovery of a condition, or failure of an event or action to occur or a condition to exist as anticipated that may del ay the agreed on date of completion of the work (“Completion Date”) or extend the Completion Date.
Sample 1Sample 2
NOTICE OF OVERRUNS AND DELAYS. The Consultant shall promptly give written notice to the Trust representative of the occurrence of an event or action, the discovery of a condition or the failure of an event or action to occur or a condition to exist as anticipated, that may result in an increase in (a) the compensation due to the Consultant; (b) reimbursable expenses and/or; (c) the number of hours necessary to perform the work or which may delay completion of the work (or extend the completion date). For purposes of this provision, “promptly” shall mean as soon as possible but in no event more than (3) business days after Consultant’s discovery of the occurrence, condition or failure which gives rise to the subject increase and/or delay.
Sample 1
NOTICE OF OVERRUNS AND DELAYS. Consultant shall promptly give written notice to the LMDC’s Representative and Chief Financial Officer of any circumstance that may (a) increase Consultant’s fees or reimbursable expenses, or the number of hours necessary to perform the work, or (b) delay the agreed on date of completion of the work (“Completion Date”), or any milestone, or extend the Completion Date.
Sample 1

Related to NOTICE OF OVERRUNS AND DELAYS

  • Notice of Overtime The Agency shall give as much notice as possible of overtime to be worked.

  • Notice of Overpayment If the Contractor receives a vendor overpayment notice or a letter communicating the existence of an overpayment from DSHS, the Contractor may protest the overpayment determination by requesting an adjudicative proceeding. The Contractor’s request for an adjudicative proceeding must:

  • NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.

  • Completion of Concrete Pours and Emergency Work 24.14.1 Except as provided in this sub-clause an employee shall not work or be required to work in the rain.

  • Substantial Completion “Substantial Completion” means the stage in the progress of the Work when the Work, or designated portions thereof, may still require minor modifications or adjustments but, in the Owner’s opinion, the Work has progressed to the point such that all parts of the Work under consideration are fully operational and usable for intended purposes, as evidenced by a Certificate of Substantial Completion approved by the Owner. If a Certificate of Occupancy is required by public authorities having jurisdiction over the Work, said certificate shall be issued before the Work or any portion thereof is considered substantially complete. When the Contractor considers that the Work, or a portion thereof which the Owner agrees to accept separately, is substantially complete, the Contractor shall notify Owner’s Designated Representative (sometimes referred to as the “ODR”) and request a determination as to whether the Work or designated portion thereof is substantially complete. If the ODR does not consider the Work substantially complete, the ODR will notify the Contractor giving reasons therefore. Failure on the Owner’s part to list a reason does not alter the responsibility of the Contractor to complete all Work in accordance with the terms of this Agreement. After satisfactorily completing items identified by Owner’s Designated Representative, the Contractor shall then submit another request for the ODR to determine Substantial Completion. If The ODR considers the Work substantially complete, The ODR will prepare and deliver a certificate of Substantial Completion which shall establish the date of Substantial Completion, shall include a punch list of items to be completed or corrected before final completion and final payment, shall establish the time within which the Contractor shall finish the punch list, and shall establish responsibilities of the Owner and the Contractor for security, maintenance, heat, utilities, damage to the Work, warranty and insurance. Failure to include an item on the punch list does not alter the responsibility of the Contractor to complete all Work in accordance with the terms and conditions of this Agreement. The certificate of Substantial Completion shall be signed by the Owner and the Contractor to evidence acceptance of the responsibilities assigned to them in such certificate. Substantial Completion (as defined in this agreement) for all stages of the Work shall be achieved on or before the following Substantial Completion date: DATE FOR SUBSTANTIAL COMPLETION: TBD Under no circumstances will the time for Substantial Completion exceed this date without a written amendment to this Agreement. THE TIMES SET FORTH IN THE CONSTRUCTION DOCUMENTS ARE AN ESSENTIAL ELEMENT OF THE AGREEMENT. TIME LIMITS STATED IN THE CONTRACT DOCUMENTS ARE OF THE ESSENCE OF THIS AGREEMENT.

  • Commencement and Completion of Construction The Company shall begin Construction Activities no later than January 1, 2014 (“Commencement Date”) and secure a final Certificate of Compliance by June 30, 2015 (hereinafter, “Completion Date”).

  • Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.

  • TIME OF COMMENCEMENT AND SUBSTANTIAL COMPLETION (i) The work under this Contract shall commence within seven (7) calendar days of receipt of Notice to Proceed and will be substantially complete within thirty (80) calendar days after the date when the Contract Time commences to run as provided in paragraph 2.03 of the General Conditions and completed and ready for final payment within ninety (90) calendar days after the date when the Contract Time commences to run.

  • Construction Budget The total amount indicated by the District for the Project plus all other costs, including design, construction, administration, financing, and all other costs.

  • Construction Phase Part 1 –

Time is Money Join Law Insider Premium to draft better contracts faster.