Notice Regarding Delays Sample Clauses

Notice Regarding Delays. It shall be Contractor's responsibility to anticipate, wherever reasonably possible, all potential sources of delays to the completion of the Work and to advise Owner's Representative in respect thereto and to take appropriate action to limit the delay, where possible. Contractor shall, in consultation with Owner, schedule other or alternate Work to be performed during anticipated delays; provided that Contractor shall not perform any Work that is outside the scope of the Preliminary Activities Development Schedule or the applicable Mine Production Schedule without Owner's prior written consent. Contractor shall give Owner reasonable prior notification of anticipated delays and the alternate Work Contractor shall perform during the anticipated delay. Contractor shall notify Owner's Representative of the occurrence of unanticipated delays orally as soon as reasonably practical after and in writing within 24 hours of the start of the delay. Contractor shall not receive any payment for alternate Work performed during anticipated delays where notification, reasonable for the particular circumstances, is not received by Owner's Representative. Owner's Representative's receipt of such notice shall not constitute an acceptance of the fact that any delay in fact occurred or was justified and Owner shall be free to dispute the validity of any delay claimed in Contractor's notices to Owner's Representative or the actual effect of such delay on the Work.
Sample 1
AutoNDA by SimpleDocs

Related to Notice Regarding Delays

  • Certain Notice Requirements From and after the consummation of the IPO, an Investor Group (for purposes of this Section 4.3, a “Notifying Investor Group”) shall provide the other applicable Investor Group with written notice prior to the time that such Notifying Investor Group acquires, during any twelve (12) month period following the consummation of the IPO, Beneficial Ownership of an aggregate amount of Shares in excess of nine-tenths of a percent (0.90%) of the aggregate amount of issued and outstanding Shares.

  • Covenants Regarding Information (a) From the date hereof through the earlier of the Closing Date and the termination of this Agreement pursuant to Section 9, Seller shall afford Purchaser and its Representatives reasonable access (subject to any applicable privileges (including attorney-client privilege), trade secrets, contractual confidentiality obligations and applicable Law) during reasonable business hours to the Purchased Assets and Seller’s Representatives, and books and records relating to the Specified Business and the Purchased Assets (excluding any information regarding Seller or its Affiliates’ employees), and shall furnish Purchaser with such operating and other data and information in connection with the Specified Business and the Purchased Assets as Purchaser may reasonably request; provided, however, that the auditors and independent accountants of Seller shall not be obligated to make any work papers available to any Person unless and until such Person has signed a customary confidentiality and hold harmless agreement relating to such access to work papers in form and substance reasonable acceptable to such auditors or independent accountants; provided, further, that Purchaser and Seller shall cooperate in good faith to develop substitute arrangements, to the extent reasonably possible, that do not result in the loss of such privilege or violation of such applicable Law; provided, further, that except as provided in Section 5.14, Purchaser will not (without Seller’s express written approval) contact or otherwise communicate with any of the Specified Business Employees; and provided further that any such access shall be conducted at Purchaser’s expense, under the supervision of appropriate personnel of Seller and its Affiliates and in such a manner as to maintain the confidentiality of this Agreement and the transactions contemplated hereby in accordance with the terms hereof and not to interfere with the normal operation of the business of Seller and its Affiliates. For so long as any applicable COVID-19 Measures are in effect, Seller and its Affiliates shall be permitted to provide access through virtual or other remote means.

  • Notice Regarding Material Contracts Promptly, and in any event within ten Business Days (i) after any Material Contract of Company or any of its Subsidiaries is terminated or amended in a manner that is materially adverse to Company or such Subsidiary, as the case may be, or (ii) any new Material Contract is entered into, a written statement describing such event, with copies of such material amendments or new contracts, delivered to Administrative Agent (to the extent such delivery is permitted by the terms of the applicable Material Contract, provided, no such prohibition on delivery shall be effective if it were bargained for by Company or its applicable Subsidiary with the intent of avoiding compliance with this Section 5.1(l)), and an explanation of any actions being taken with respect thereto;

  • Waiver or Delay The failure or delay on the part of the Corporation or Executive to exercise any right or remedy, power or privilege hereunder shall not operate as a waiver thereof. A waiver, to be effective, must be in writing and signed by the party making the waiver. A written waiver of default shall not operate as a waiver of any other default or of the same type of default on a future occasion.

  • Effect of Failure or Delay in Requesting Compensation Failure or delay on the part of any Lender or the Issuing Bank to demand compensation pursuant to this Section 5.01 shall not constitute a waiver of such Lender’s or the Issuing Bank’s right to demand such compensation; provided that the Borrower shall not be required to compensate a Lender or the Issuing Bank pursuant to this Section 5.01 for any increased costs or reductions incurred more than 180 days prior to the date that such Lender or the Issuing Bank, as the case may be, notifies the Borrower of the Change in Law giving rise to such increased costs or reductions and of such Lender’s or the Issuing Bank’s intention to claim compensation therefor; provided further that, if the Change in Law giving rise to such increased costs or reductions is retroactive, then the 180-day period referred to above shall be extended to include the period of retroactive effect thereof.

  • Additional Conditions For each mediation or arbitration:

  • Excusable Delays Neither Party shall be held liable for any delay or failure in performance of any part of this Services Agreement by reason of any cause beyond its reasonable control, including, but not limited to, acts of God, acts of civil or military authority, government regulations, embargoes, epidemics, war, terrorist acts, riots, fires, explosions, earthquakes, nuclear accidents, floods, strikes, power blackouts affecting facilities, inability to secure products or services of other persons or transportation facilities, or acts or omissions of transportation common carriers, provided that the Party so affected shall use reasonable commercial efforts to remove such causes of non-performance. Upon the occurrence of any event of force majeure, the Party whose performance is prevented shall promptly give written notice to the other Party and the Parties shall promptly confer in good faith to agree upon reasonable action to minimize the impact of such event on the Parties.

  • Announcement Regarding Lock-ups The Company agrees to announce the Underwriters’ intention to release any director or “officer” (within the meaning of Rule 16a-1(f) under the Exchange Act) of the Company from any of the restrictions imposed by any Lock-Up Agreement, by issuing, through a major news service, a press release in form and substance satisfactory to the Representatives promptly following the Company’s receipt of any notification from the Representatives in which such intention is indicated, but in any case not later than the close of the third business day prior to the date on which such release or waiver is to become effective; provided, however, that nothing shall prevent the Representatives, on behalf of the Underwriters, from announcing the same through a major news service, irrespective of whether the Company has made the required announcement; and provided, further, that no such announcement shall be made of any release or waiver granted solely to permit a transfer of securities that is not for consideration and where the transferee has agreed in writing to be bound by the terms of a Lock-Up Agreement in the form set forth as Exhibit A hereto. The Representatives, on behalf of the several Underwriters, may, in their sole discretion, waive in writing the performance by the Company of any one or more of the foregoing covenants or extend the time for their performance.

  • Notice of Certain Releases, Remedial Actions, Etc Promptly upon the occurrence thereof, written notice describing in reasonable detail (a) any Release required to be reported to any federal, state or local governmental or regulatory agency under any applicable Environmental Laws, (b) any remedial action taken by Company or any other Person in response to (1) any Hazardous Materials Activities the existence of which could reasonably be expected to result in one or more Environmental Claims having, individually or in the aggregate, a Material Adverse Effect, or (2) any Environmental Claims that, individually or in the aggregate, could reasonably be expected to result in a Material Adverse Effect, and (c) Company’s discovery of any occurrence or condition on any real property adjoining or in the vicinity of any Facility that could cause such Facility or any part thereof to be subject to any material restrictions on the ownership, occupancy, transferability or use thereof under any Environmental Laws.

  • Extension of Time Periods The parties may extend any period of time provided in this Article 7 by mutual agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.