Quality Assurance/Quality Control Contractor shall establish and maintain a quality assurance/quality control program which shall include procedures for continuous control of all construction and comprehensive inspection and testing of all items of Work, including any Work performed by Subcontractors, so as to ensure complete conformance to the Contract with respect to materials, workmanship, construction, finish, functional performance, and identification. The program established by Contractor shall comply with any quality assurance/quality control requirements incorporated in the Contract.
How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000-000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent flooring inspector to verify the Warranty Holder’s warranty claims. The determination of the flooring inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/geowood-flooring-warranty/. This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s GeoWood flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and (ii) maintained in accordance with Cali Bamboo’s GeoWood flooring care and maintenance guidelines found online at xxxxx://xxx.xxxxxxxxxx.xxx/floor-care-and-maintenance/ (the “Maintenance Guide”). Cali Bamboo will provide copies of these guides upon request by the Warranty Holder. This limited warranty only applies when the Flooring is used under normal traffic and other usage conditions. The limited warranty for Manufacturing Defects does not apply after the Warranty Holder has installed the Flooring, and product variation or error that does not exceed the 5% industry standard is not considered a Manufacturing Defect for purposes of this limited warranty. This limited warranty does not extend to or cover:
Billing and Payment Procedure for Forest Products Delivered The State will compute and forward to Purchaser a billing statement of charges for forest products delivered during the billing period at the delivered rate shown in P- 028.2 clause. After receipt of the billing statement, Purchaser’s payment must be received by the Department of Natural Resources on or before the due date shown on the billing statement. Purchaser agrees to make payment, payable to the Department of Natural Resources. Failure to pay on time for forest products delivered is considered a breach of contract. Included with the billing statement will be a summary report for the billing period compiled by the State or their log and load reporting service. The State will adjust final xxxxxxxx to account for any State approved payment reductions. Advance payments made under P-045 or P-045.2 remaining on account above the value for the charges shall be returned to Purchaser within 30 days following the final report of charges. Refunds not made within the 30 day period will accrue interest at the interest rate, as established by WAC 000-000-000, computed on a daily basis until paid.
Required Procurement Procedures for Obtaining Goods and Services The Grantee shall provide maximum open competition when procuring goods and services related to the grant- assisted project in accordance with Section 287.057, Florida Statutes.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded vendor under this Agreement when the TIPS Member has services that need to be undertaken. Notification may occur via phone, the web, email, fax, or in person. Upon notification of a pending request, the awarded vendor shall make contact with the TIPS Member as soon as possible, but must make contact with the TIPS Member within two working days. Scheduling of projects (if applicable) may be accomplished when the TIPS Member issues a Purchase Order and/or an Agreement or Contract that will serve as “the notice to proceed” as agreed by the Vendor and the TIPS Member. The period for the delivery order will include the mobilization, materials purchase, installation and delivery, design, weather, and site cleanup and inspection. No additional claims may be made for delays as a result of these items. When the tasks have been completed the awarded vendor shall notify the client and have the TIPS Member or a designated representative of the TIPS Member inspect the work for acceptance under the scope and terms in the Purchase Order and/or Agreement or Contract. The TIPS Member will issue in writing any corrective actions that are required. Upon completion of these items, the TIPS Member will issue a completion notice and final payment will be issued per the contractual requirements of the project with the TIPS Member. Any Construction contract prepared by the TIPS Member’s Legal Counsel may alter the terms of this subsection, “Scheduling of Projects”.
Important Information About Procedures for Opening a New Account To help the government fight the funding of terrorism and money laundering activities, Federal law requires all financial organizations to obtain, verify, and record information that identifies each person who opens an account. What this means for you: When you open an account, you are required to provide your name, residential address, date of birth, and identification number. We may require other information that will allow us to identify you.
Customer Service, Dispute Resolution If you have a question about your XOOM charges or service you may contact XOOM directly by calling 0-000-000-0000 Monday – Friday 8 (eight) a.m. to 11 (eleven)p.m.
Contractor Certification for Contractor Employees Introduction Texas Education Code Chapter 22 requires entities that contract with school districts to provide services to obtain criminal history record information regarding covered employees. Contractors must certify to the district that they have complied. Covered employees with disqualifying criminal histories are prohibited from serving at a school district. Definitions: Covered employees: Employees of a contractor or subcontractor who have or will have continuing duties related to the service to be performed at the District and have or will have direct contact with students. The District will be the final arbiter of what constitutes direct contact with students. Disqualifying criminal history: Any conviction or other criminal history information designated by the District, or one of the following offenses, if at the time of the offense, the victim was under 18 or enrolled in a public school: (a) a felony offense under Title 5, Texas Penal Code; (b) an offense for which a defendant is required to register as a sex offender under Chapter 62, Texas Code of Criminal Procedure; or (c) an equivalent offense under federal law or the laws of another state. I certify that: NONE (Section A) of the employees of Contractor and any subcontractors are covered employees, as defined above. If this box is checked, I further certify that Contractor has taken precautions or imposed conditions to ensure that the employees of Contractor and any subcontractor will not become covered employees. Contractor will maintain these precautions or conditions throughout the time the contracted services are provided. OR SOME (Section B) or all of the employees of Contractor and any subcontractor are covered employees. If this box is checked, I further certify that: (1) Contractor has obtained all required criminal history record information regarding its covered employees. None of the covered employees has a disqualifying criminal history.
Quality Control Program Engineer shall have a quality control program in place that ensures that all deliverable work is of high quality. Engineer shall submit a plan detailing its program to the Inspection Branch of the TxDOT Bridge Division for review and approval prior to beginning work. State may review or audit the programs.