Emergency Response Partners must develop, maintain, and carry out a response plan for public water system emergencies, including disease outbreaks, spills, operational failures, and water system contamination. Partners must notify DWS in a timely manner of emergencies that may affect drinking water supplies.
Agency Response a. OGS will consider all information relevant to the Formal Dispute, and may, in its discretion, suspend, modify, or cancel the disputed procurement/Contract action prior to issuance of a Formal Dispute decision.
b. OGS reserves the right to require the filer to meet or participate in a conference call with OGS to discuss the Formal Dispute when, in its sole judgment, circumstances so warrant.
c. OGS reserves the right to waive or extend the time requirements for decisions and final determinations on appeals herein prescribed when, in its sole judgment, circumstances so warrant.
d. OGS reserves the right to consider or reject the merits of any Formal Dispute.
Company’s Response Upon receipt by the Company of a copy of a Conversion Notice, the Company shall as soon as practicable, but in no event later than one (1) Business Day after receipt of such Conversion Notice, send, via email, facsimile or overnight courier, a confirmation of receipt of such Conversion Notice to such Holder indicating that the Company will process such Conversion Notice in accordance with the terms herein. Within two (2) Business Days after the date of the Conversion Confirmation, the Company shall have issued and electronically transferred the shares to the Broker indicated in the Conversion Notice; should the Company be unable to transfer the shares electronically, it shall, within two (2) Business Days after the date of the Conversion Confirmation, have surrendered to FedEx for delivery the next day to the address as specified in the Conversion Notice, a certificate, registered in the name of the Holder, for the number of shares of Common Stock to which the Holder shall be entitled.
Additional Responsibilities This paragraph applies to all phases of Architect's work.
(a) Architect shall be responsible for the professional quality, technical accuracy, timely completion and coordination of all of Architect's work, including that performed by Architect's consultants, and including designs, Drawings, Specifications, reports and other services, irrespective of Owner's approval or acquiescence in same. Architect shall, without additional compensation, correct or revise any errors, omissions or other deficiencies in his work.
(b) Architect shall be responsible, in accordance with applicable law, to Owner for all loss or damage to Owner caused by Architect's negligent act or omission; except that Architect hereby irrevocably waives and excuses Owner and its attorneys from compliance with any requirement to obtain a certificate of review as a condition precedent to commencement of an action, including any such requirements set forth in Section 00-00-000, C.R.S. or similar statute.
(c) Architect's professional responsibility shall comply with the standard of care applicable to the type of engineering and architectural services provided, commensurate with the size, scope and nature of the Project.
(d) Architect shall be completely responsible for the safety of Architect's employees in the execution of work under this Agreement, shall provide all necessary safety equipment for said employees, and shall hold harmless and indemnify and defend Owner from any and all claims, suits, loss or injury to Architect's employees.
(e) Architect acknowledges that, due to the nature of architectural and related professional services and the impact of same on the Project, the Owner has a substantial interest in the personnel and consultants to whom Architect assigns principal responsibility for services performed under this Agreement. Consequently, Architect represents that Architect has selected and intends to employ or assign the key personnel and consultants identified in Appendix C - "Identification of Personnel, Subcontractors and Task Responsibility", attached hereto for the Project assignments and areas of responsibility stated therein. Within 10 days of execution of this Agreement, Owner shall have the right to object in writing to employment on the Project of any such key person, consultant or assignment of principal responsibility, in which case Architect will employ alternate personnel for such function or reassign such responsibility to another to whom Owner has no reasonable objection. Thereafter, Architect shall not assign or reassign Project work to any person to whom Owner has reasonable objection. Within 5 days of execution of this Agreement, Architect shall designate in writing a Project representative who shall have complete authority to bind Architect, and to whom Owner should address communications.
(f) Promptly after execution of this Agreement and upon receipt of authorization from Owner to proceed, Architect shall submit to Owner for approval a schedule showing the order in which Architect proposes to accomplish his work, with dates on which he will commence and complete each major work item. The schedule shall provide for performance of the work in a timely manner so as to not delay Owner's time table for achievement of interim tasks and final completion of Project work, provided however, the Architect will not be responsible for delays beyond his control.
(g) Before undertaking any work which Architect considers beyond or in addition to the scope of work and services which Architect has contractually agreed to perform under the terms of this Agreement, Architect shall advise Owner in writing (i) that Architect considers the work beyond the scope of this Agreement, (ii) the reasons the Architect believes the out of scope or additional work should be performed, and (iii) a reasonable estimate of the cost of such work. Architect shall not proceed with such out of scope or additional work until authorized in writing by Owner. The compensation for such authorized work shall be negotiated, but in the event the parties fail to negotiate or are unable to agree as to compensation, then Architect shall be compensated for his direct costs and professional time at the rates set forth in Appendix B - "Fee Schedule".
General Responsibility The Consultant shall, at all times during the Agreement, remain responsible. The Consultant agrees, if requested by the Commissioner of NYSDOT or his or her designee, to present evidence of its continuing legal authority to do business in New York State, integrity, experience, ability, prior performance, and organizational and financial capacity.
General Responsibilities Issuer hereby engages Distributor to act as exclusive distributor of the shares of each class of the Funds. The Funds subject to this Agreement as of the date hereof are identified on SCHEDULE A, which may be amended from time to time in accordance with Section 11 below. Sales of a Fund's shares shall be made only to investors residing in those states in which such Fund is registered. After effectiveness of each Fund’s registration statement, Distributor will hold itself available to receive, as agent for the Fund, and will receive by mail, telex, telephone, or such other method as may be agreed upon between Distributor and Issuer, orders for the purchase of Fund shares, and will accept or reject such orders on behalf of the Fund in accordance with the provisions of the applicable Fund’s prospectus. Distributor will be available to transmit orders, as promptly as possible after it accepts such orders, to the Fund’s transfer agent for processing at the shares’ net asset value next determined in accordance with the prospectuses.
School Responsibilities Pursuant to §1002.33(8)(e), F.S., the School shall be dissolved under the provisions of law under which the School was organized. Student records and copies of all administrative, operational, and financial records of the School shall be provided to the Sponsor on the date the termination/non-renewal takes effect.
MUTUAL RESPONSIBILITY 6.2.1 The Contractor shall afford the State and separate contractors reasonable opportunity for the introduction and storage of their materials and equipment and the execution of their work, and shall connect and coordinate his / her Work with the work of the State and separate contractors as required by the Contract Documents.
6.2.2 If any part of the Contractor's Work depends for proper execution or results upon the work of the State or any separate contractor, the Contractor shall, prior to proceeding with the Work, promptly report to the Architect any apparent discrepancies or defects in such other work that render it unsuitable for such proper execution and results. Failure of the Contractor so to report shall constitute an acceptance of the State's or separate contractors work as fit and proper to receive
6.2.3 Any costs caused by defective or ill-timed work shall be borne by the party responsible therefor.
6.2.4 Should the Contractor wrongfully cause damage to the work or property of the State, or to other work on the site, the Contractor shall promptly remedy such damage as provided in Subparagraph 10.2.5 of these General Conditions.
Financial Responsibility You understand that you remain, solely and exclusively responsible for any and all financial risks, including, without limitation, insufficient funds associated with accessing the Service. The Credit Union shall not be liable in any manner for such risk unless Credit Union fails to follow the procedures described in materials for use of the service. You assume exclusive responsibility for the consequences of any instructions you give to the Credit Union, for your failures to access the Service properly in a manner prescribed by the Credit Union, and for your failure to supply accurate input information, including, without limitation, any information contained in an application.
Timely and Sustained Response Interconnection Customer shall ensure that the Small Generating Facility’s real power response to sustained frequency deviations outside of the deadband setting is automatically provided and shall begin immediately after frequency deviates outside of the deadband, and to the extent the Small Generating Facility has operating capability in the direction needed to correct the frequency deviation. Interconnection Customer shall not block or otherwise inhibit the ability of the governor or equivalent controls to respond and shall ensure that the response is not inhibited, except under certain operational constraints including, but not limited to, ambient temperature limitations, physical energy limitations, outages of mechanical equipment, or regulatory requirements. The Small Generating Facility shall sustain the real power response at least until system frequency returns to a value within the deadband setting of the governor or equivalent controls. An Applicable Reliability Standard with equivalent or more stringent requirements shall supersede the above requirements.
