OWNER'S RIGHT AND NOTICE Sample Clauses

OWNER'S RIGHT AND NOTICE. A. The parties agree that:
Sample 1Sample 2Sample 3See All (13)
AutoNDA by SimpleDocs
OWNER'S RIGHT AND NOTICE. A. The parties agree that: 1. If the CMR fails to begin the Work when required to do so; or 2. If, at any time during the progress of the Work, the Owner determines that the CMR is not prosecuting the Work with reasonable speed and diligence, or is delaying the Work unreasonably or unnecessarily; or 3. If the force of workmen or the quality or quantity of services or product furnished is not sufficient to ensure completion of the Work within the specified time and in accordance with the Contract Documents; or 4. If the CMR fails to make prompt payments to suppliers or to Subcontractors for Work performed in connection with the Contract; or 5. If the CMR fails in any manner of substance to observe the provisions of this Contract; or 6. If any of the Work is defective and is not replaced as herein provided; then the Owner’s Representative shall certify such fact or condition to the Owner without prejudice to any other rights or remedies Owner may have hereunder, and the Owner shall have the right to declare the CMR in default in whole or in part. In the event the Owner elects to declare the CMR in default, the Owner shall notify the CMR by written Notice describing the nature of the default and providing the CMR a right to cure such default within three (3) calendar days after the date of the Notice, or within such longer period as the Owner, in its sole and absolute discretion, may prescribe. In the event the default is not cured within the time period specified by the Owner, the Owner shall have the right to take any actions necessary to correct or complete the Work, including but not limited to those as set forth in Paragraph 14.3 of these Terms and Conditions. B. The parties further agree that: 1. If legal proceedings have been instituted by others than the Owner in such manner as to interfere with the progress of the Work and to potentially subject the Owner to the peril of litigation or outside claims; or 2. If the CMR is adjudicated bankrupt or makes an assignment for the benefit of creditors; or 3. If in any proceeding instituted by or against the CMR, an order is made or entered granting an extension of the time of payment, composition, adjustment, modification, settlement or satisfaction of its debts or liabilities; or 4. If a receiver or trustee is appointed for the CMR or the CMR's property; or 5. If the Contract or any part hereof is sublet without the prior written consent of the Owner; or 6. If the Contract or any rights, moneys, or claims her...
Sample 1

Related to OWNER'S RIGHT AND NOTICE

  • OWNER’S RIGHTS B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT.

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • Owner’s Right to Suspend Work The Owner reserves the right, with or without the concurrence of the Design Professional, to suspend the Work at any time or from time to time at the Owner's sole discretion, upon giving Contractor five days advanced written notice thereof. If the Owner exercises this right and then resumes the Work covered hereby, Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the suspension and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's suspension, to include compensation based upon the rate for Time Dependent Overhead Costs. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • OWNER’S RIGHT TO STOP THE WORK If the Contractor fails to correct Work that is not in accordance with the requirements of the Contract Documents as required by Section 12.2 or repeatedly fails to carry out Work in accordance with the Contract Documents, the Owner may issue a written order to the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, the right of the Owner to stop the Work shall not give rise to a duty on the part of the Owner to exercise this right for the benefit of the Contractor or any other person or entity.

  • STATE's Right to Suspend the Operations The STATE and/or the STATE's Authorized Representative has the authority to suspend portions or all of the operations due to causes including, but not limited to:

  • OWNER’S RIGHT TO PERFORM CONSTRUCTION AND TO AWARD SEPARATE CONTRACTS 6.1.1 The Owner reserves the right to perform construction or operations related to the Project with the Owner’s own forces, and to award separate contracts in connection with other portions of the Project or other construction or operations on the site under Conditions of the Contract identical or substantially similar to these including those portions related to insurance and waiver of subrogation. If the Contractor claims that delay or additional cost is involved because of such action by the Owner, the Contractor shall make such Claim as provided in Article 15.

  • OWNER’S RIGHT TO CLEAN UP If a dispute arises among the Contractor, separate contractors and the Owner as to the responsibility under their respective contracts for maintaining the premises and surrounding area free from waste materials and rubbish, the Owner may clean up and allocate the cost among those responsible.

  • TEACHERS’ RIGHTS A. Pursuant to the Public Employment Relations Act, the Board hereby agrees that every teacher as defined in Article I, Section A of this Agreement, shall have the right freely to organize, join and support the Association for the purpose of engaging in collective bargaining or negotiation and other concerted activities for mutual aid and protection, or choose not to join and support the association. As a duly elected body exercising governmental power under color of law of the State of Michigan, the Board undertakes and agrees that it will not directly or indirectly discourage any teacher in the employment of any rights conferred by the Public Employment Relations Act or other laws of Michigan and the United States; that it will not discriminate against any teacher with respect to hours, wages, or any terms or conditions of employment by reason of membership in the Association or collective professional negotiations with the Board or institution of any grievance, complaint or proceeding under this Agreement, or otherwise with respect to any terms or conditions of employment.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!