Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.
Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT.
B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate.
B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner.
B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment.
B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.
Our Right to Make Payments and Recover Overpayments If payments which should have been made by us according to this provision have actually been made by another organization, we have the right to pay those organizations the amounts we decide are necessary to satisfy the rules of this provision. These amounts are considered benefits provided under this plan and we will not have to pay those amounts again. If we make payments for allowable expenses, which are more than the maximum amount needed to satisfy the conditions of this provision, we have the right to recover the excess amounts from: • the person to or for whom the payments were made; • any other insurers; and/or • any other organizations (as we decide). As the subscriber, you agree to pay back any excess amount paid, provide information and assistance, or do whatever is necessary to aid in the recovery of this excess amount. The amount of payments made includes the reasonable cash value of any
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
Right to Make Agreement Each party warrants, with respect to itself, that neither the execution of this Agreement, nor the consummation of any transaction contemplated hereby, shall violate any provision of any law, or any judgment, writ, injunction, order or decree of any court or governmental authority having jurisdiction over it; nor result in or constitute a breach or default under any indenture, contract, other commitment or restriction to which it is a party or by which it is bound; nor require any consent, vote or approval which has not been given or taken, or at the time of the transaction involved shall not have been given or taken. Each party covenants that it has and will continue to have throughout the term of this Agreement and any extensions thereof, the full right to enter into this Agreement and perform its obligations hereunder.
MANAGEMENT'S RIGHTS Section 1. Except to the extent expressly modified by a specific provision of this agreement, the City of Xxxxxxxx reserves and retains solely and exclusively all of its statutory and common law rights to manage the operation of the Xxxxxxxx Fire Division of the City of Mitchell, South Dakota, as such rights existed prior to the execution of this agreement with the Union including, but not limited to:
A. The right to operate and manage all manpower, facilities and equipment;
B. The right to adopt, modify, change, enforce, or discontinue any existing rules, regulations, procedures and policies that are not in direct conflict with any provision of the agreement;
C. The right to formulate, implement, modify, or discontinue standard operating procedures for the governing of the operation of the division. Standard operating procedures will be distributed to the union and shall be posted by the City on station bulletin boards and/or published in the form of a manual;
D. To determine work assignments or eliminate work schedules, locations or functions in accordance with municipal and divisional needs and to contract or subcontract all or any of the functions of the Fire Division that does not take work away from the bargaining unit;
E. To transfer, promote or demote employees, or to lay-off, terminate or otherwise relieve employees from duty for just cause;
F. To recruit, select and determine the number and types of employees required;
G. To establish recognized fire service in-service training programs and requirements for upgrading employees;
H. To establish fire functions and programs, including the setting and amending of budgets;
I. To determine the utilization of technology and manpower and to modify organizational structures. To select, direct and determine the number of personnel engaged in total functions or any particular part thereof;
X. Xx perform any inherent managerial functions not specifically limited by this agreement and to take such other measures as the City or Xxxxxxxx Fire Division administration may deem necessary for the orderly and efficient operation of the Xxxxxxxx Fire Division so long as it does not conflict with this agreement.
Section 2. To the extent that the above rights are specifically limited, in whole or in part, by the provisions of this agreement, alleged violations are subject to the grievance procedure in accordance with Article 19, except regarding those issues identified in this agreement as being subject to the City Council appeal process only.
RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES The Allottee hereby agrees to purchase the [Apartment/Plot] on the specific understanding that is/her right to the use of Common Areas shall be subject to timely payment of total maintenance charges, as determined and thereafter billed by the maintenance agency appointed or the association of allottees (or the maintenance agency appointed by it) and performance by the Allottee of all his/her obligations in respect of the terms and conditions specified by the maintenance agency or the association of allottees from time to time.
No Obligation to Mitigate Damages; No Effect on Other Contractual Rights (a) All compensation and benefits provided to the Executive under this Agreement are in consideration of the Executive’s services rendered to the Company and of the Executive’s adhering to the terms set forth in Section 5 hereof and the Executive shall not be required to mitigate damages or the amount of any payment provided for under this Agreement by seeking other employment or otherwise, nor shall the amount of any payment provided for under this Agreement be reduced by any compensation earned by the Executive as the result of employment by another employer after the Date of Termination, or otherwise.
(b) The provisions of this Agreement, and any payment provided for hereunder, shall not reduce any amounts otherwise payable, or in any way diminish the Executive’s existing rights, or rights which would accrue solely as a result of the passage of time, under any Benefit Plan, Incentive Plan or Securities Plan, employment agreement or other contract, plan or arrangement.
BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.