Binding Dispute Resolution For any Claim subject to, but not resolved by, mediation pursuant to Article 15 of AIA Document A232–2019, the method of binding dispute resolution shall be as follows: [ ] Arbitration pursuant to Article 15 of AIA Document A232–2019. [ X ] Litigation in a court of competent jurisdiction. [ ] Other: (Specify) If the Owner and Contractor do not select a method of binding dispute resolution, or do not subsequently agree in writing to a binding dispute resolution method other than litigation, Claims will be resolved by litigation in a court of competent jurisdiction.
Consultation and Dispute Resolution 1. The Parties shall promptly consult, at the request of either of them, on any question arising out of the interpretation or application of this Agreement. Any disputes concerning the interpretation or application of this agreement shall be settled by friendly consultations between the Parties. 2. Paragraph 1 shall not prevent the Parties from having recourse to dispute settlement procedures under the Partnership and Cooperation Agreement establishing partnership between the European Communities and their Member States, and Ukraine.
Dispute Resolution and Governing Law The Parties agree that all disputes arising pursuant to this Agreement shall be resolved by way of negotiations and discussions and with a view to an amicable settlement and mutual benefit of both Parties. Any negotiation for the settlement of dispute shall be governed by the laws of the country where such dispute arises.
Governing Law; Dispute Resolution (a) This Limited Guarantee shall be interpreted, construed and governed by and in accordance with the Laws of the State of New York without regard to the conflicts of law principles thereof that would subject such matter to the Laws of another jurisdiction other than the State of New York. (b) Any disputes, actions and proceedings against any party or arising out of or in any way relating to this Limited Guarantee shall be submitted to the Hong Kong International Arbitration Centre (the “HKIAC”) and resolved in accordance with the Arbitration Rules of HKIAC in force at the relevant time (the “Rules”) and as may be amended by this Section 10(b). The place of arbitration shall be Hong Kong. The official language of the arbitration shall be English and the arbitration tribunal shall consist of three arbitrators (each, an “Arbitrator”). The claimant(s), irrespective of number, shall nominate jointly one Arbitrator; the respondent(s), irrespective of number, shall nominate jointly one Arbitrator; and a third Arbitrator will be nominated jointly by the first two Arbitrators and shall serve as chairman of the arbitration tribunal. In the event the claimant(s) or respondent(s) or the first two Arbitrators shall fail to nominate or agree on the joint nomination of an Arbitrator or the third Arbitrator within the time limits specified by the Rules, such Arbitrator shall be appointed promptly by the HKIAC. The arbitration tribunal shall have no authority to award punitive or other punitive-type damages. The award of the arbitration tribunal shall be final and binding upon the disputing parties. Any party to an award may apply to any court of competent jurisdiction for enforcement of such award and, for purposes of the enforcement of such award, the parties irrevocably and unconditionally submit to the jurisdiction of any court of competent jurisdiction and waive any defenses to such enforcement based on lack of personal jurisdiction or inconvenient forum. (c) Notwithstanding the foregoing, the parties hereto consent to and agree that in addition to any recourse to arbitration as set out in Section 10(b), any party may, to the extent permitted under the Laws of the jurisdiction where application is made, seek an interim injunction from a court or other authority with competent jurisdiction and, notwithstanding that this Agreement is governed by the Laws of the State of New York, a court or authority hearing an application for injunctive relief may apply the procedural Law of the jurisdiction where the court or other authority is located in determining whether to grant the interim injunction. For the avoidance of doubt, this Section 10(c) is only applicable to the seeking of interim injunctions and does not restrict the application of Section 10(b) in any way.
Complaints and Dispute Resolution 16.1 Where a dispute arises in connection with any aspect of this Agreement, the parties acting with good faith, will use all reasonable endeavours to bring any such issue to the attention of the other party in a timely fashion and in any event within 60 days of any such dispute coming to their attention. 16.2 Notification by one party to the other must be in writing and include the nature of the dispute and the desired resolution. 16.3 If a Supplier wishes to notify ACM of a dispute in connection with this Agreement, any such notification should be made by email to xxxxxxxxxx@xxxxxx.xxx.xx. 16.4 Within seven days of receipt of a notification in accordance with clause 16.2, a party will provide a response in writing including setting out steps it intends to take to resolve the dispute. 16.5 If, after attempting to resolve the dispute for a period of at least 60 days, the parties are not reconciled, they agree to then participate in a mediation to be conducted in accordance with the Code. 16.6 If, after undertaking mediation in accordance with the Code, the parties are still not reconciled, they may then submit to an arbitration to be conducted in accordance with the Code. 16.7 Unless otherwise agreed in writing, the parties shall each bear their own legal costs associated with any mediation and/or arbitration pursuant to this Agreement. 16.8 Nothing in this clause will prevent a party from seeking an injunction.
Governing Law and Dispute Resolution Procedure 25.1 This Agreement and any dispute or claim (including any non-contractual dispute or claim) arising out of or in connection with it or its subject matter, shall be governed by, and construed in accordance with, the laws of England and Wales. 25.2 Subject to the remainder of this clause 25, the parties irrevocably agree that the courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim (including any non-contractual dispute or claim) that arises out of or in connection with this Agreement or its subject matter. 25.3 In the event that any claim or dispute arises out of or in connection with this Agreement, the parties shall, following service of written notice by one party on the other, attempt to resolve amicably by way of good faith negotiations and discussions any such dispute or claim as soon as reasonably practicable (and in any event within 14 calendar days after such notice or by such later date as the parties may otherwise agree in writing). If the parties are unable to resolve the dispute or claim in accordance with this clause 25.3, either party may commence proceedings in accordance with clause 25.2. 25.4 Nothing in this clause 25 shall prevent either party from applying at any time to the court for injunctive relief on the grounds of infringement, or threatened infringement, of the other party's obligations of confidentiality contained in this Agreement or infringement, or threatened infringement, of the applicant's Intellectual Property Rights.
Governing Law and Dispute Resolution 11.1 This Agreement and any non-contractual obligations arising out of, or in connection with, it shall be governed by, and interpreted in accordance with, English law. 11.2 Any Dispute arising out of or in connection with this Agreement or any related agreement (s), including any question regarding its or their existence, validity, breach, termination or enforceability, shall be referred to and finally resolved by arbitration administered by the Hong Kong International Arbitration Centre (the “HKIAC”) under the HKIAC Administered Arbitration Rules in force when the notice of arbitration is submitted (the “HKIAC Rules”) which are deemed to be incorporated by reference into this Clause 11.2, except as they may be modified herein or by mutual agreement of the Parties. 11.3 The tribunal shall consist of three (3) arbitrators. The parties to the Dispute shall each nominate one arbitrator, provided that where there are multiple claimants or multiple respondents, the multiple claimants jointly and the multiple respondents jointly shall nominate an arbitrator. The third arbitrator, who will be the chairman of the tribunal, shall be nominated by the two party-nominated arbitrators. The chairman of the tribunal must be a solicitor or barrister qualified in England and Wales, with at least ten (10) years of experience. Notwithstanding anything to the contrary in the HKIAC Rules, in agreeing upon a third arbitrator, the two party-nominated arbitrators may communicate directly with each other and their respective nominating parties. If no agreement is reached upon the third arbitrator within ten (10) Business Days of the appointment of the second arbitrator, HKIAC shall expeditiously nominate and appoint a third arbitrator to act as chairman of the arbitral tribunal (as applicable). If the claimant or claimant parties and/or the respondent or respondent parties fail to nominate an arbitrator in accordance with this Clause 11.3 within twenty (20) Business Days after the deadline to submit the answer to the notice of arbitration, an arbitrator shall be appointed on their behalf in accordance with the HKIAC Rules. In such circumstances, any existing nomination or confirmation of an arbitrator shall be unaffected, and the remaining arbitrator(s) shall be appointed in accordance with this Clause 11.3. Each party expressly agrees and consents to this process for nominating and appointing the arbitrators. 11.4 The seat, or legal place, of arbitration shall be Hong Kong. 11.5 The language to be used in the arbitral proceedings shall be English. 11.6 The governing law of this arbitration agreement shall be English law. 11.7 The arbitration award shall be final and binding on the parties, and the parties undertake to carry out any award without delay. Except as provided in Clause 11.8, judgment upon the award may be entered by any court having jurisdiction over the award or over the relevant party or its assets. 11.8 Each Party hereby acknowledges and agrees that it shall not, and it shall procure that its Affiliates shall not, bring any action, claim or proceedings in any court in Russia (including pursuant to Articles 248.1 and 248.2 of the Arbitrazh Procedure Code of the Russian Federation) or in any other jurisdiction or dispute resolution forum other than (i) as set out in Clause 11.2 in relation to this Agreement or the transactions contemplated therein or (ii) any enforcement proceeding in relation to an arbitral award obtained in accordance with Clause 11.2 (each such restricted action, claim or proceeding, a “Restricted Party Claim”). 11.9 Each Party hereby covenants with each other Party to hold such Party and its Affiliates harmless and on such Party’s demand to indemnify such Party and its Affiliates for and against (and hereby covenants on such Party’s demand to pay such Party and its Affiliates an amount equal to) all documented losses, liabilities, claims, actions, demands, damages or costs and expenses (including documented fees of external legal advisers) incurred by such Party or any of its Affiliates resulting from or arising out of or in connection with a Restricted Party Claim of the Party giving the covenant hereunder (or a Restricted Party Claim of an Affiliate of such Party). 11.10 Any Party to this Agreement serving a notice of arbitration shall send a copy of that notice to every other Party. Any respondent to a claim may join any other Party as a party to the arbitration, to afford that party an opportunity to defend against the claim or to assert against that party a substantially related claim. Any Party that is not already a party to the arbitration may intervene as a party to the arbitration to defend against a claim or to assert against any other Party a substantially related claim. Any joined or intervening Party shall be bound by any award rendered by the arbitration tribunal even if such Party chooses not to participate in the arbitration proceedings. Any joinder or intervention pursuant to this Clause shall be made by serving written notice on all Parties within thirty (30) days from receipt of the notice of arbitration to which the joinder or intervention relates. The arbitral tribunal shall resolve any disputes as to whether the joinder or intervention is admissible under the terms of this Clause and whether and to what extent any other pending arbitration proceedings between Parties shall be stayed or discontinued in the interest of efficiency. The tribunal’s decision shall be binding. For the avoidance of doubt, the term “claim” as used in this Clause includes any claim, counterclaim, crossclaim, or claim by or against a joined or intervening Party. 11.11 In order to facilitate the comprehensive resolution of related disputes, and upon request of any party to the arbitration proceeding, the arbitration tribunal may consolidate the arbitration proceeding with any other arbitration proceeding relating to this Agreement or any related agreement (s). The arbitration tribunal shall not consolidate such arbitrations unless it determines that (i) there are issues of fact or law common to the two proceedings such that a consolidated proceeding would be more efficient than separate proceedings, and (ii) no party would be prejudiced as a result of such consolidation through undue delay or otherwise.
Governing Law, Jurisdiction and Dispute Resolution The rights and obligations of the Parties under the Agreement shall be governed by and construed in accordance with the laws of India. The TDSAT, to the exclusion of all other courts, shall have exclusive jurisdiction in respect of any dispute between the Parties arising out of or in connection with or as a result of this Agreement.
Governing Law; Disputes 15.1 The laws of the State of New York, U.S.A. govern this Agreement, and the relationships created by it, except for its laws regarding conflicts of law and arbitrability; the Federal Arbitration Act governs all issues of arbitrability. Neither party may bring a claim more than two years after the underlying cause of action first accrues. 15.2 Each party agrees to give the other prompt written notice of any claim, controversy, or dispute arising under or related to this Agreement, and both parties agree to engage in good faith discussions to resolve the matter. If that fails to resolve the matter promptly, upon the election of either party, the parties will participate in a non-binding mediation before a mutually agreed mediator. Any controversy, claim or dispute which is not resolved through the procedures set forth above within 60 days following the initial notice (or such longer period as the parties may agree) will be resolved by arbitration before a sole arbitrator who is an attorney, under the then-current Commercial Arbitration Rules of the American Arbitration Association. The duty and right to arbitrate will extend to any employee, officer, director, shareholder, agent, or affiliate, of a party to the extent that right or duty arises through a party or is related to this Agreement. The decision and award of the arbitrator will be final and binding, and the award rendered may be entered in any court having jurisdiction. The arbitrator is directed to hear and decide potentially dispositive motions in advance of a hearing on the merits by applying the applicable law to undisputed facts and documents. The arbitration will be held in Atlanta, Georgia, U.S.A. This Section 15.2, and the obligation to mediate and arbitrate, will not apply to claims for infringement, misappropriation or misuse of a party’s intellectual property or Confidential Information, or collection of sums owed to NCR Voyix under this Agreement. A party may at any time seek from a court of competent jurisdiction an injunction or other equitable relief in aid of arbitration. The arbitrator will not have authority to award punitive damages, non- compensatory damages, or any damages other than direct damages, nor have authority to award direct damages inconsistent with the limitations and exclusions set forth in this Agreement. The United Nations Convention for the International Sale of Goods does not apply to this Agreement.
Governing Law; Resolution of Disputes This Agreement and the rights and obligations hereunder shall be governed by and construed in accordance with the laws of the State of Wisconsin. Any dispute arising out of this Agreement shall, at the Executive’s election, be determined by arbitration under the rules of the American Arbitration Association then in effect (in which case both parties shall be bound by the arbitration award) or by litigation. Whether the dispute is to be settled by arbitration or litigation, the venue for the arbitration or litigation shall be Milwaukee, Wisconsin or, at the Executive’s election, if the Executive is not then residing or working in the Milwaukee, Wisconsin metropolitan area, in the judicial district encompassing the city in which the Executive resides; provided, that, if the Executive is not then residing in the United States, the election of the Executive with respect to such venue shall be either Milwaukee, Wisconsin or in the judicial district encompassing that city in the United States among the thirty cities having the largest population (as determined by the most recent United States Census data available at the Termination Date) which is closest to the Executive’s residence. The parties consent to personal jurisdiction in each trial court in the selected venue having subject matter jurisdiction notwithstanding their residence or situs, and each party irrevocably consents to service of process in the manner provided hereunder for the giving of notices.
