Diligent Completion The Company agrees to use its reasonable efforts to cause the completion of the Project as soon as practicable, but in any event on or prior to the end of the Investment Period.
Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:
Agreement Complete This Agreement contains all negotiations and agreements between the BCA and the Governmental Unit. No other understanding regarding this Agreement, whether written or oral, may be used to bind either party.
Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.
Final Completion The full and final completion of all Work in accordance with the Contract Documents.
At Completion all (but not some only, unless the Subscriber so agrees) of the following business shall be transacted:
(a) the Issuer shall issue the Subscription Shares to the Subscriber (or its nominee) free and clear of all Encumbrances and credited as fully paid on terms that they rank pari passu in all respects with the existing issued Shares (including the right to rank in full for all distributions declared, paid or made by the Issuer after the Completion Date) and shall promptly thereafter register (or procure the share registrar to register) the Subscriber as a registered shareholder of the Issuer in respect of the Subscription Shares in the branch register of members of the Issuer maintained by Computershare;
(b) the Issuer shall deliver to the Subscriber, each in form and substance to the reasonable satisfaction of the Subscriber:
(i) a certified true copy of the Board resolutions approving and/or ratifying the matters below:
(A) approving the terms of, and the transactions contemplated by, this Agreement and resolving that the Issuer executes this Agreement;
(B) authorising a specified person or persons to execute this Agreement on the Issuer’s behalf;
(C) authorising a specified person or persons, on behalf of the Issuer, to sign, execute and/or despatch all documents and notices to be signed, executed and/or despatched by it under or in connection with this Agreement; and
(D) a specimen of the signature of each person authorised by the resolution referred to in Clause 4.3(b)(i)(B) above;
(ii) the original definitive share certificates in respect of the Subscription Shares in the name of the Subscriber (or its nominee);
(iii) a certified true copy of the confirmation letter issued by Computershare confirming that the Subscriber (or its nominee) is the registered holder of the Subscription Shares;
(iv) a copy of the approval from the HKSE for the listing of, and permission to deal in, all the Subscription Shares; and
(v) a closing certificate, dated as at the Completion Date and addressed to the Subscriber from the Issuer, executed by a Director (or another duly authorised signatory) and substantially in the form set out in Schedule 2, and attaching thereto as exhibits all supporting documents, showing such fulfilment.
Sale : Completion On Or Before The Completion Date
a. Within ninety (90) days from the date of successful sale (the expiry date of which period referred to as “the Completion Date”), the Purchaser shall deposit with the Assignee’s Solicitors simultaneously:-
(i) The balance of the purchase price i.e a sum equivalent to 90% of the successful bid price (referred to as “the Balance Sum”) either by way of IBG or XXXXXX or bank draft or cashier’s order crossed “A/C PAYEE ONLY” made payable to HONG XXXXX BANK BERHAD. The amount of the bank draft or cashier’s order shall include outstation clearing charges which shall be borne by the Purchaser, failing which the deficiency shall be recoverable from the Purchaser; and
(ii) A copy of the requisite consents or confirmations (as the case may be) of the Developer and/or Proprietor and/or State Authorities and/or relevant bodies approving the sale (including transfer or assignment) in favour of the Purchaser, if necessary and/or required, subject firstly to the Assignee being satisfied with the conditions if imposed, otherwise the Assignee may elect to terminate the sale under Xxxxxx 11. - Extension
b. The Completion Date will not be extended unless the Purchaser shall have at least fourteen (14) days before the Completion Date applied in writing for an extension of time to the Assignee and the Assignee may at its absolute discretion without assigning any reason whatsoever either:-
(i) Reject such request in which event all monies paid by the Purchaser hitherto including the Deposit shall be forfeited absolutely and immediately for which the Purchaser shall not be entitled to nor have any or further reimbursements, claims and demands whatsoever in nature and howsoever caused against the Assignee, the Assignee’s Solicitors, the Auctioneer or their respective servants or agents and any other party on account thereof; or
(ii) Agree to grant an extension of time subject to conditions imposed by the Assignee including but not limited to the imposition of non- refundable late payment charges / compensation charges on the balance unpaid or outstanding purchase price at such rate as the Assignee shall determine and to be calculated on a daily basis for the whole duration of the extended period granted and also to pay such sum within the time and in the manner as stipulated by the Assignee. Such decision by the Assignee shall be binding on the Purchaser. - Charges
c. Notwithstanding any contrary terms and conditions which may be imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto on the Assignee in granting the consent or confirmation (as the case may be) to the sale herein, it is hereby agreed that only arrears of quit rent, assessment rate and service charges (collectively referred to as “the Outstanding Charges”) within a period of six (6) years prior to the date of successful sale of the Property which are lawfully and rightfully due and payable to the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto up to the date of successful sale of the Property shall be deducted from the purchase price upon receipt of the Balance Sum PROVIDED THAT the Assignee reserves the right to refuse to pay nor shall the Assignee be obliged to pay:-
(i) Any Outstanding Charges that are time-barred i.e. charges which have remained unpaid for more than six (6) years prior to the date of successful sale of the Property irrespective of any payment or acknowledgement or judgment made or obtained on the said charges;
(ii) Any Outstanding Charges that are excessively charged resulted from eg duplicate or double counting, wrong calculation or any other similar circumstances;
(iii) Any Outstanding Charges wrongfully imposed including but not limited to being charged without any basis whatsoever; and/or
(iv) Any bills issued by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto for the Outstanding Charges but only received by the Assignee or the Assignee’s Solicitors more than seventy-five (75) days from the date of the successful sale. Such decision by Assignee on what is due and payable shall be binding on the Purchaser of which the Purchaser hereby expressly agrees.
d. The Outstanding Charges due and payable immediately after the date of successful sale of the Property shall be solely borne and paid by the Purchaser.
e. Where applicable, it shall be the duty of the Purchaser to obtain at the Purchaser’s own costs the particulars as stated in Section 22D(4) of the Housing Development (Control and Licensing) Act 1966 and to obtain copies of the charges payable from the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto and to forward copies thereof together with the calculations as to the apportionment of the respective parties’ liability thereof to the Assignee’s Solicitors for the Assignee’s approval. For this purpose, the Purchaser shall also furnish the Assignee’s Solicitors with the Purchaser’s account details in order for the Assignee to process payment of the Assignee’s portion of the Outstanding Charges pursuant to and in accordance with Clause 8(c) above.
f. In the event the Purchaser shall pay such arrears (if any) of the Outstanding Charges in advance to the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto:-
(i) The Purchaser is not entitled to deduct the payment towards the arrears (if any) from the Balance Sum;
(ii) Due apportionment and reimbursement for the payment (if any) made by the Purchaser towards the arrears shall only be made after the Assignee has received the Balance Sum and subject to the Assignee’s approval and other provisions of these Conditions of Sale. For this purpose, the Purchaser shall produce receipts evidencing payment together with the Purchaser’s account details in order for the Assignee to reimburse the Purchaser in accordance with this Clause 8(f)(ii) accordingly.
g. Nothing herein shall impose any obligation on the part of the Assignee to pay any outstanding water, electricity, telephone, utilities, gas, sewerage, taxes, rates, bills, any type of interest, fine, penalty, losses incurred by reason of any breach of written laws, late payment charges, damages, compensation, other form of maintenance or management charges (including but not limited to security charges, charges incurred in relation to car park / accessory parcel, deposits, sinking / building / common / maintenance / management fund), costs for renovation / alteration / additional works, contribution, subscription, licence, dues, levies, insurance, premium, rents, commission, fees, costs and expenses (including but not limited to legal fees, disbursements, stamp duty, registration fees, administrative or vetting fees and transfer costs), other outgoings and charges in any form whatsoever (including for any increase in area of the Property imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto irrespective of whether the same was imposed or incurred before the date of successful auction, any penalty thereof in connection with incidental to or pursuant to the Assignment the Memorandum of Transfer and all other documents necessary for affecting the transfer or subsequent transfer [as the case may be] or assigning the beneficial ownership of the Property to the Purchaser or that as may be due to or imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto notwithstanding that the Developer and/or Proprietor and/or State Authorities and/or relevant bodies and/or third parties entitled thereto may require such payments to be made by the Assignee). The Purchaser hereby expressly agrees that such costs and expenses shall be solely borne and paid by the Purchaser.
h. Any other costs, expenses and charges not specifically mentioned and/or specified in Clause 8.c, Clause 8.d, Clause 8.e, Clause 8.f and Clause 8.g hereof which are outstanding shall be solely borne and paid by the Purchaser.
i. Upon payment of all monies mentioned and/or specified in Clause 6.d, Clause 7.a, Clause 8.a(i), Clause 8.c, Clause 8.d, Clause 8.e, Clause 8.f, Clause 8.g and Clause 8.h above and subject to the fulfillment of Clause 9 below by the Purchaser, the Assignee shall:-
(i) Execute or cause to be executed as soon as possible at the Purchaser’s own costs and expenses (including legal fees, stamp duty and registration fees) an Assignment (in the form and substance acceptable to and upon the terms and conditions stipulated by the Assignee at its absolute discretion) in favour of the Purchaser of all the rights title interests and benefits under the Sale and Purchase Agreement entered into between the Developer and/or Proprietor of the Property and the Assignor or the original purchaser(s) when the Assignor is not the original purchaser of the Property. Where applicable, the Assignee shall be entitled to have a sufficient covenant of indemnity inserted in the Assignment in order for the Purchaser to assume all liabilities and obligations pertaining to the Property. The Assignee shall not be required to assign the Property to any person other than the Purchaser; and
(ii) Deliver to the Purchaser or the Purchaser’s Solicitors the duly executed Assignment and certified true copy(ies) of the Sale and Purchase Agreement and previous Assignment within the Assignee’s custody. If any of the aforesaid documents is not available, the Assignee shall use its best endeavors to provide certified true copy(ies) or such other acceptable documentary evidence of previous transactions thereof.
j. Where applicable, the Purchaser undertakes to forward to the Developer the duly stamped Assignment, the duly stamped Proclamation of Sale and the Memorandum together with the full payment of all sums and outgoings due to the Developer under the Sale and Purchase Agreement as required by Section 22D(2) of the Housing Development (Control and Licensing) Act 1966 within fourteen (14) days from the date of stamping of the Assignment and to forward a copy of the cover letter or acknowledgment of receipt by the Developer to the Assignee or the Assignee’s Solicitors within seven (7) days after the issuance of the cover letter or acknowledgment of receipt. - Charge / Transfer
k. If the separate document of title or strata title for the Property has been issued whether before on or after the date of auction sale, the Assignee shall not be required to procure a Memorandum of Transfer nor to register its charge as prescribed by the National Land Code 1965 or Sarawak Land Code or the Land Ordinance Cap. 68 of the Laws of Sabah (where applicable) in favour of the Purchaser from the Developer and/or Proprietor (as the case may be).
l. The transfer of the Property from the Developer and/or Proprietor (as the case may be) shall be prepared and procured by the Purchaser at the Purchaser’s own costs (including costs of transfer from the Developer and/or Proprietor to the Assignor where necessary) and expenses who undertakes to pay such sums and comply with the conditions (if any) imposed by the Developer and/or Proprietor and/or State Authorities and/or relevant bodies pertaining to the registration of such transfer of the Property.
m. The Purchaser undertakes to inform the local authority of the change of ownership and to file the necessary form within fourteen (14) days from the date of stamping of the Assignment.
Construction Completion The related Construction shall have been completed substantially in accordance with the related Plans and Specifications, the related Deed and all Applicable Laws, and such Leased Property shall be ready for occupancy and operation. All fixtures, equipment and other property contemplated under the Plans and Specifications to be incorporated into or installed in such Leased Property shall have been substantially incorporated or installed, free and clear of all Liens except for Permitted Liens.
On Completion the Seller shall deliver to the Buyer:
(a) a completed and signed transfer of the Sale Shares to the Buyer or as it directs and the related share certificate;
(b) a power of attorney in agreed form appointing the Buyer as attorney pending the Buyer’s registration as a member of the Company with power on the Seller’s behalf to execute and deliver all deeds and documents and to do all acts and things and exercise all rights which the Buyer would be entitled to execute, deliver and do and exercise if the Buyer was registered as the holder of the Sale Shares with power to sub-delegate this power and power to appoint a substitute attorney in addition to the Buyer;
(c) the statutory books of each Group Company (including any separate sheet minutes in respect of the Subsidiary, if applicable) complete and accurate up to Completion and any company seal(s), certificates of incorporation, certificates of incorporation on change of name and all share certificates of each Group Company;
(d) a signed deed addressed by the Seller to the Buyer and to the Company and all Group Companies acknowledging that there is no outstanding indebtedness owing at Completion from any Group Company to the Seller or to any Seller’s Associate or vice versa;
(e) letters of resignation in agreed form from each director of each Group Company and the secretary of each Group Company (if any);
(f) a letter, in agreed form, from the Seller confirming that upon Completion it has ceased to be a registrable relevant legal entity (within the meaning of section 790C of the Companies Act 2006) in relation to the Company;
(g) the Disclosure Letter;
(h) the consultancy agreement in the agreed form between the Company and Xxxxxxx Xxxxxxx signed by the parties;
(i) deeds of release in the agreed form between each of the employees of the Group Companies previously granted share awards by the Seller and the Seller in relation to the provision of such share awards in the Seller;
(j) earn-in letter agreements in the agreed form executed by certain of the employees of the Group Companies (as determined by the Buyer) in relation to the potential issue of additional shares in Xxxxxxxx.xxx Limited to such persons;
(k) an intellectual property assignment in the agreed form from the Seller in favour of the Company;
(l) an intellectual property assignment in the agreed from XXXX00.Xxx Limited (UK) in favour of the Company; and
(m) a settlement agreement in the agreed form duly executed by Xxxxxx Xxxxxx (together with the associated advisers certificate) dated at least one Business Day prior to the date of the assignments referred to at clauses 6.2(k) and (I) above.
Project Completion Report At the completion of construction and once a Project is placed in service, the Subrecipient must submit a Project Completion Report that includes the total number of units built and leased, affordable units built and leased, DR-MHP units built and leased, an accomplishment narrative, and the tenants names, demographics and income for each DR-MHP unit.
