Contract Completion definition

Contract Completion means the schedule Milestone when the Work is completed in accordance with the terms of the Contract Documents and Contractor has satisfied all of its other obligations under the Contract Documents, including but not limited to (1) all governmental authorities have given final, written approval of the Work, (2) a final unconditional certificate of occupancy has been granted and issued to the Owner by the appropriate governmental authorities, (3) the Contractor’s Work is 100 percent complete, and (4) all Punch List items have been completed or corrected, and (5) the Contractor has complied with conditions precedent to final payment and release of retained funds.
Sample 1Sample 2Sample 3
Contract Completion means the point in time when FW Project Manager confirms in writing that the contract has been completed as contracted for and the Contractor is released from any further obligations. All remaining payments due the Contractor shall be approved for payment at this time.
Sample 1Sample 2Sample 3
Contract Completion means when the entire Work, except those items arising from the provisions of GC10 - WARRANTY, has been performed to the requirements of the Contract Documents and is so certified by the TTC’s Representative.
Sample 1Sample 2Sample 3

Examples of Contract Completion in a sentence

  • It is the Contractor's responsibility to submit a schedule that shows Substantial Completion of the Work by the Contract Time for Completion or the Contract Completion Date and any interim deadlines established by the Contract.

  • The schedule shall show completion of the Project at the Contract Completion Date or before.

  • DBEs Must Perform a Useful and Necessary Role in Contract Completion: A DBE does not perform a commercially useful function if the DBE’s role is limited to that of an extra participant in a transaction, contract, or project through which funds are passed in order to obtain the appearance of DBE participation.

  • In some instances, the Time for Completion may be stated in the form of a Contract Completion Date based on a stipulated date of Notice to Proceed.

  • However, a change in the Time for Completion or the Contract Completion Date shall be accomplished only by Change Order.

  • Contractor agrees that the Owner may deduct from the contract price and retain as liquidated damages, and not as penalty or forfeiture, the sum stipulated in this contract for each work day after the Contract Completion Day on which work is not Substantially Complete.

  • The Contractor may attempt to achieve Substantial Completion on or before the Time for Completion or the Contract Completion Date.

  • If any elements of the Work are behind schedule, regardless of whether they may prevent the Work from being completed on time, the Contractor must indicate in writing in the report what measures he is taking and plans to take to bring each such element back on schedule and to ensure that the Time for Completion or Contract Completion Date is not exceeded.

  • The Contractor shall evaluate this information and update the latest accepted schedule as often as necessary to finish within the Contract Time for Completion or before the Contract Completion Date.

  • If the Contractor seeks to change the Time for Completion or the Contract Completion Date to reflect an earlier completion date, he may request or propose such a change.


More Definitions of Contract Completion

Contract Completion means when the entire Work has been performed to the requirements of the Contract Documents.
Sample 1Sample 2Sample 3
Contract Completion means the Contract Completion Date as mentioned in the Contract Completion Certificate issued by the Department’s Representative to the contractor on fulfillment of his obligations in respect of both the Design- Build and the Operation Service;
Sample 1Sample 2
Contract Completion means the schedule Milestone, by which deficiencies listed in the Punch List are corrected, the Contractor's Work is 100 percent complete, and the Contractor has complied with conditions precedent to final payment and release of retained funds.
Sample 1Sample 2Sample 3
Contract Completion a contract for the performance of any E&C -------- ---------- Services shall be deemed to have reached Contract Completion for purposes of this Agreement when (i) the applicable project or scope of work is 100% physically complete, and (ii) all work under the contract has been completed except for warranty work and, if applicable, the job site has been demobilized. With respect to any contract for the performance of any E&C Services that is a Continuing Services Agreement, any particular job order or work order under such E&C Contract shall be deemed to have reached Contract Completion for purposes of this Agreement when such job order meets the criteria set forth in (i) and (ii) above.
Sample 1
Contract Completion means the date of completion of the terms of a contract between a contractor and an eligible business.
Sample 1

Related to Contract Completion

  • Project Completion means the date, as determined by the Division after consultation with the Recipient, that operation of the Project is initiated or is capable of being initiated, whichever comes first.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Construction Completion Date means date of the completion of the Construction Period, which shall be at the expiry of a period of 24 (Twenty Four) months from the Compliance Date or such other date (with the consent of the Authority) by which the overall development of the Project is completed in accordance with the provisions of this Concession Agreement and when the Construction Completion Certificate is issued by Authority as per Article 14.1.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Commissioning means the process for determining the need for and for obtaining the supply of healthcare and related services by the Trust within available resources.

  • Improvement completion assurance means a surety bond, letter of credit,

  • Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out in accordance with the Specification after the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Commissioning Tests means all of the procedures and tests which, in accordance with the Reasonable and Prudent Standard, and in compliance with industry guidelines, practices and standards, are:

  • Contract Work means everything required to be furnished and done by the Contractor by any one or more of the parts of the Contract referred to in Article 1, except Extra Work as hereinafter defined.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Tests on Completion means the tests which are specified in the Contract or agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.

  • Extra Work means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement. Consultant shall not perform, nor be compensated for, Extra Work without written authorization from City’s Representative.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Construction Work means any work in connection with⎯

  • Construction Contractor means a person who undertakes to or offers to undertake to, or purports to have the capacity to undertake to, or submits a bid to, or does himself or by or through others, construct, alter, repair, add to, subtract from, improve, move, wreck, or demolish any building, highway, road, railroad, excavation, or other structure, project, development, or improvement to real property, or to do any part thereof. "Construction contractor" includes subcontractors, specialty contractors, prime contractors, and any person receiving consideration for the general supervision and/or coordination of such a construction project except for remediation contracting. This definition shall govern without regard to whether or not the construction contractor is acting in fulfillment of a contract.

  • Commissioning test means tests applied to a distributed generation facility by the applicant after construction is completed to verify that the facility does not create adverse system impacts and performs to the submitted specifications. At a minimum, the scope of the commissioning tests performed shall include the commissioning test specified in Institute of Electrical and Electronics Engineers, Inc. (IEEE) Standard 1547 Section 5.4 "Commissioning tests".

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Interconnection Feasibility Study means either a Generation Interconnection Feasibility Study or Transmission Interconnection Feasibility Study.

  • Test on Completion means such tests as prescribed in the Contract to be performed by the Contractor before the work is Taken Over by TSECL.