Payment for Improvements If payment is made directly to contractors, Tenant shall (i) comply with Landlord's requirements for final lien releases and waivers in connection with Tenant's payment for work to contractors, and (ii) sign Landlord's standard contractor's rules and regulations. If Tenant orders any work directly from Landlord, Tenant shall pay to Landlord an amount equal to five percent of the cost of such work to compensate Landlord for all overhead, general conditions, fees and other costs and expenses arising from Landlord's involvement with such work. If Tenant does not order any work directly from Landlord, Tenant shall reimburse Landlord for Landlord's reasonable, actual, out-of-pocket costs and expenses actually incurred in connection with Landlord's review of such work.
Disbursements for Site Improvements All payments made by the OPWC for site improvements or other work shall be made directly to the Contractor that performed the work and originated the invoice, unless the request is for disbursement to the Recipient.
Additional Improvements Common Area Operating Expenses shall not include Real Property Taxes specified in the tax assessor's records and work sheets as being caused by additional improvements placed upon the Industrial Center by other lessees or by Lessor for the exclusive enjoyment of such other lessees. Notwithstanding Paragraph 10.1 hereof, Lessee shall, however, pay to Lessor at the time Common Area Operating Expenses are payable under Paragraph 4.2, the entirety of any increase in Real Property Taxes if assessed solely by reason of Alterations, Trade Fixtures or Utility Installations placed upon the Premises by Lessee or at Lessee's request.
Initial Improvements Subtenant may, at its option and subject to the provisions of the Prime Lease, including, without limitation, Article 8 thereof, complete certain initial improvements to prepare the Demised Premises for Subtenant’s occupancy thereof as described in the Work Letter Agreement attached hereto and made a part hereof as Exhibit B (the “Initial Improvements”), at Subtenant’s sole cost and expense without any contribution or improvement allowance from Sublandlord described in the Work Letter Agreement attached hereto and made a part hereof as Exhibit B); provided, however, Subtenant shall not make or permit anyone to make any Initial Improvements without the prior written consent of Sublandlord, which shall not be unreasonably withheld or delayed, and of Prime Landlord in accordance with the Prime Lease. In connection with the foregoing, Subtenant shall submit to Sublandlord, for prior written approval by Sublandlord, which shall not be unreasonably withheld or delayed, and Prime Landlord, complete plans and specifications for any and all Initial Improvements; including, without limitation, schematic designs and work drawings. Any and all costs and expenses associated with the acquisition of cabling, equipment, furniture, security systems, or other personal property for Subtenant or the Demised Premises or the installation or placement of any of the foregoing within the Demised Premises or with the project management for the performance of the Initial Improvements (collectively, “Subtenant’s Personal Property and Services”), shall be paid for by and be the sole responsibility of Subtenant. Sublandlord acknowledges and agrees that Subtenant shall not be required to remove any Initial Improvements upon the expiration or earlier termination of this Sublease unless the removal is required by Prime Landlord or Sublandlord is otherwise obligated to pay Prime Landlord the costs of any removal of any Initial Improvements pursuant to Section 8(e) of the Prime Lease.
Capital Improvements From and after Final Completion, Tenant shall not replace or materially alter the Project, or any part thereof (except as provided to the contrary with respect to Fixtures in Article 13), or make any addition thereto, whether voluntarily or in connection with repairs required by this Lease (collectively, “Capital Improvements”), unless Tenant shall comply with the following requirements and, if applicable, with the additional requirements set forth in Section 11.10:
(a) No Capital Improvements shall be undertaken, as applicable, until Tenant shall have procured from all Governmental Authorities and paid for all permits, consents, certificates and approvals for the proposed Capital Improvements which are required to be obtained prior to the commencement of the proposed Capital Improvements (collectively, “Improvement Approvals”). The FCRHA shall not unreasonably refuse to join or otherwise unreasonably refuse to cooperate in the application for any such Improvement Approvals, provided such application is made without cost, expense or liability (contingent or otherwise) to the FCRHA. True copies of all such Improvement Approvals shall be delivered by Tenant to the FCRHA prior to commencement of the proposed Capital Improvements.
(b) The Premises after completion of such Capital Improvements, shall have a value at least equal to the value of the Premises immediately before construction of such Capital Improvements. In addition, the Project shall at all times remain in substantial conformity with the original Plans and Specifications therefor (except to the extent specifically consented to by the FCRHA, in its sole but reasonable discretion).
(c) All Capital Improvements shall be made with reasonable diligence and continuity (subject to Unavoidable Delays) and in a good and workmanlike manner and in compliance with (i) all Improvement Approvals, (ii) if required pursuant to Section 11.10(a) or (b), in substantial accordance with the plans and specifications for such Capital Improvements as approved by the FCRHA, and (iii) all Applicable Laws.
(d) No construction of any Capital Improvement shall be commenced until Tenant shall have delivered to the FCRHA certificates of insurance and copies of the declaration page(s) for the insurance required by Exhibit D. Such insurance policies shall comply with the terms of Section 7.02 above.
Payment for Project Services As full consideration for the Services to be performed by Contractor, City agrees to pay Contractor as set forth in accordance with the bid and not to exceed fee of $215,500.00 for the project. A monthly progress payment in the amount of ninety-five percent (95%) of the value of the work completed may be made every thirty (30) days upon application by the Contractor and certification by the Project Manager that such work has been completed. Partial payments will be made once each month as the work satisfactorily progresses and after acceptance by the authorized City representative. The progress estimates shall be based upon materials in place, or on the job site and invoiced, and labor expended thereon. From the total of the amount ascertained will be deducted an amount equivalent to five percent (5%) of the whole, which five percent (5%) will be retained by the City until after completion of the entire Contract in an acceptable manner. Any time after fifty percent (50%) of the value of the work has been completed, the City will make any of the remaining partial payments in full. No such estimates or payments shall be required to be made, when, in the judgment of the City Project Manager, the work is not proceeding in accordance with the provision of the Contract, or when in his judgment the total value of the work done since last estimate amounts to less than Five Hundred Dollars ($500.00). The cost of materials conforming to the plans and specifications (materials being those which are required to be contained and incorporated in a finished contract bid item) delivered to the project and not at the time incorporated in the work, may also be included in the estimate for payment. No such estimate or payment shall be construed to be an acceptance of any defective work or improper material. The Contractor shall be responsible for, and shall not remove from the project any material that has been included in the estimate for payment. Final payment shall be made upon the Project Manager certifying that the Contractor has satisfactorily completed the work in conformity with the Contract Documents.
Payment for Working Overtime (a) For all work done outside ordinary hours, the rates of pay will be time and a half for the first two hours and double time thereafter.
(b) Except as provided in clause 8.4, in computing overtime each day’s work will stand alone.
(c) To avoid doubt, overtime provisions for shift workers are contained in clause 10.7.
Construction of the Tenant Improvements (a) Tenant shall construct and install the Tenant Improvements in a good and workmanlike manner, in compliance with all Laws and in accordance with this Exhibit B. Tenant’s proposed architect/engineer, general contractor, and fire protection, plumbing, HVAC and electrical subcontractors are subject to Landlord’s prior approval. Promptly following the selection and approval of the architect/engineer, Tenant shall forward to said architect/engineer (and copy Landlord on the transmittal) Landlord’s building standards heretofore delivered to Tenant, and Tenant shall cause said architect/engineer to comply with said building standards. Promptly following the selection and approval of the general contractor, Tenant shall forward to said general contractor (and copy Landlord on the transmittal) Landlord’s fire protection, plumbing, HVAC and electrical specifications and Landlord’s rules of conduct, all of which have been delivered to Tenant prior to the date of this Lease, and Tenant shall cause said general contractor to comply with said specifications and rules of conduct. At Landlord’s request, Tenant shall coordinate a meeting among Landlord (who will reasonably make its representative available for such meeting), Tenant and Tenant’s general contractor to discuss the Building systems and other matters related to the construction of the Tenant Improvements.
(b) Promptly following the date hereof, Tenant shall prepare and submit to Landlord a set of permittable construction drawings (the “CDs”), based on the preliminary plans attached hereto as Exhibit B-2 and made a part hereof (the “Preliminary Plans”), covering all work to be performed by Tenant in constructing the Tenant Improvements. Tenant shall have no right to make any Tenant Improvements that would materially alter the exterior appearance of the Building or the Building systems without Landlord’s prior approval. Landlord shall have fifteen (15) days after receipt of the CDs in which to review the CDs and in which to give Tenant written notice of its approval of the CDs or its requested changes to the CDs in reasonably sufficient detail so as to allow Tenant to make the requested changes (provided that Landlord shall not be permitted to request a change that is inconsistent with the Preliminary Plans). If Landlord requests any changes to the CDs, Tenant shall make such changes and shall, within fifteen (15) days of its receipt of Landlord’s requested changes (if any), submit the revised portion of the CDs to Landlord. Landlord shall have five (5) business days after receipt of the revised CDs in which to review said revised CDs and in which to give to Tenant written notice of its approval of the revised CDs or its requested changes thereto. This process shall continue until such time, if at all, that Landlord approves the CDs in accordance with this Section 2. Tenant shall at all times in its preparation of the CDs, and of any revisions thereto, act reasonably and in good faith. Landlord shall at all times in its review of the CDs, and any revisions thereto, act reasonably and in good faith.
Additional Requirements for Sleeping Rooms The Contractor shall provide departing Attendees a secured area for storing belongings.
PAYMENT FOR WORK The H-GAC Customer is responsible for making payment to the Contractor upon delivery and acceptance of the goods or completion of the services and submission of the subsequent invoice.
