Performance Bonds/Guarantee Sample Clauses

Performance Bonds/Guarantee. As security for the fulfilment of Contractor’s obligations regarding the realization of the Works and for the fulfilment of his obligations regarding the realization of the long-term maintenance services and payment by the Contractor of any amount due to Principal pursuant to this Agreement the Contractor will provide the Principal with the following performance bonds and Guarantee which can be called on demand by the Principal, issued by a surety in the format as attached to this Agreement as Annex 12 and Annex 13. The performance bonds shall be governed by Netherlands law, and are only to secure the performance of Contractor’s obligations as it relates to this Agreement. • Design-Build Performance and Payment Bond provided by the local site contractor (“Site Contractor”) in an amount equal to 100% of the value of their scope of the Agreement, to be issued within 3 weeks from the date of the agreement with the Site Contractor, and to be valid until the contractual date of completion and acceptance of the Works. • Design-Build Performance and Payment Bond provided by Anaergia, in an amount equal to 100% of the balance of the Works value (calculated as the contract price for the Works less the value of the Site Contractor scope), to be issued within 3 weeks from the date of this Agreement, and to be valid until the contractual date of the completion and acceptance of the Works. • Maintenance Performance bond provided by Anaergia, in an amount equal to 100% of the value of the annual maintenance and operation work (excluding pass through costs), to be issued upon the completion and acceptance of the Works, valid for one year and extended, renewed or replaced, so that it remains in effect until the end of the long-term maintenance period. Notwithstanding any Contractor cure rights in any other parts of this Agreement, if the Principal plans to invoke the security, the Principal shall first notify the Contractor by registered letter with details of the Contractor default. Contractor shall have thirty (30) days from the receipt of such notice to cure applicable defaults detailed in the Principal’s notice. Should the thirty (30) day cure period expire and such default(s) continues uncured, the Principal shall be entitled to invoke the security, unless the Court of Arbitration for the Building Industry or the Dispute Adjudication Board rules otherwise in a dispute to be filed by the Contractor within 14 days of dispatch of the notification referred to in this par...
Sample 1
AutoNDA by SimpleDocs

Related to Performance Bonds/Guarantee

  • Performance Bonds Buyer shall have obtained, or caused to be obtained, in the name of Buyer, replacements for Seller’s and/or Seller’s Affiliates’ bonds, letters of credit and guarantees, and such other bonds, letters of credit and guarantees to the extent required by Section 7.05.

  • SBIC Guarantee The Borrower will not, nor will it permit any of its Subsidiaries to, cause or permit the occurrence of any event or condition that would result in any recourse to any Obligor under any Permitted SBIC Guarantee.

  • Performance Bond (a) The MCO must obtain a performance bond with a one (1) year term. The performance bond must be renewable and renewal must occur no later than the first day of each subsequent State Fiscal Year. The performance bond must continue to be in effect for one (1) year following the expiration of the final renewal period. MCO must obtain and maintain the performance bonds in the form prescribed by HHSC and approved by TDI, naming HHSC as Obligee, securing MCO’s faithful performance of the terms and conditions of this Contract. The performance bonds must comply with Chapter 843 of the Texas Insurance Code and 28 T.A.C. §11.1805. At least one (1) performance bond must be issued. The amount of the performance bond(s) should total $100,000.00 for each MCO Program within each Service Area that the MCO covers under this Contract. Performance bonds must be issued by a surety licensed by TDI, and specify cash payment as the sole remedy. MCO must deliver each renewal prior to the first day of the State Fiscal Year.

  • The Guarantee Each Guarantor hereby jointly and severally with the other Guarantors guarantees, as a primary obligor and not merely as a surety to each Secured Party and their respective permitted successors and assigns, the prompt payment in full when due (whether at stated maturity, by required prepayment, declaration, demand, by acceleration or otherwise) of the principal of and interest (including any interest, fees, costs or charges that would accrue but for the provisions of (i) the Title 11 of the United States Code after any bankruptcy or insolvency petition under Title 11 of the United States Code and (ii) any other Debtor Relief Laws) on the Loans made by the Lenders to, and the Notes held by each Lender of, the Borrower, and all other Secured Obligations from time to time owing to the Secured Parties by any Loan Party or any Subsidiary under any Loan Document or any Secured Hedge Agreement or any Treasury Services Agreement, in each case strictly in accordance with the terms thereof (such obligations, including any future increases in the amount thereof, being herein collectively called the “Guaranteed Obligations”); provided, however, that Guaranteed Obligations shall exclude all Excluded Swap Obligations. The Guarantors hereby jointly and severally agree that if the Borrower or other Guarantor(s) shall fail to pay in full when due (whether at stated maturity, by acceleration or otherwise) any of the Guaranteed Obligations, the Guarantors will promptly pay the same in cash, without any demand or notice whatsoever, and that in the case of any extension of time of payment or renewal of any of the Guaranteed Obligations, the same will be promptly paid in full when due (whether at extended maturity, by acceleration or otherwise) in accordance with the terms of such extension or renewal.

  • Subsidiary Guarantee For value received, each of the Subsidiary Guarantors named (or deemed herein to be named) below hereby jointly and severally fully and unconditionally guarantees to the Holder of the Security upon which this Subsidiary Guarantee is endorsed, and to the Trustee on behalf of such Holder, the due and punctual payment of the principal of (and premium, if any) and interest on such Security when and as the same shall become due and payable, whether at the Stated Maturity, by acceleration, call for redemption, offer to purchase or otherwise, according to the terms thereof and of the Indenture referred to therein and to cover all the rights of the Trustee under Section 607. In case of the failure of the Company punctually to make any such payment, each of the Subsidiary Guarantors hereby jointly and severally agrees to cause such payment to be made punctually when and as the same shall become due and payable, whether at the Stated Maturity or by acceleration, call for redemption, offer to purchase or otherwise, and as if such payment were made by the Company. Each of the Subsidiary Guarantors hereby jointly and severally agrees that its obligations hereunder shall be absolute and unconditional, irrespective of, and shall be unaffected by, the validity, regularity or enforceability of such Security or the Indenture, the absence of any action to enforce the same or any release, amendment, waiver or indulgence granted to the Company or any other guarantor, or any consent to departure from any requirement of any other guarantee of all or of any of the Securities of this series, or any other circumstances which might otherwise constitute a legal or equitable discharge or defense of a surety or guarantor; provided, however, that, notwithstanding the foregoing, no such release, amendment, waiver or indulgence shall, without the consent of such Subsidiary Guarantor, increase the principal amount of such Security, or increase the interest rate thereon, or alter the Stated Maturity thereof. Each of the Subsidiary Guarantors hereby waives the benefits of diligence, presentment, demand of payment, any requirement that the Trustee or any of the Holders protect, secure, perfect or insure any security interest in or other lien on any property subject thereto or exhaust any right or take any action against the Company or any other Person or any collateral, filing of claims with a court in the event of insolvency or bankruptcy of the Company, any right to require a proceeding first against the Company, protest or notice with respect to such Security or the indebtedness evidenced thereby and all demands whatsoever, and covenants that this Subsidiary Guarantee will not be discharged except by complete performance of the obligations contained in such Security and in this Subsidiary Guarantee. Each Subsidiary Guarantor agrees that if, after the occurrence and during the continuance of an Event of Default with respect to Securities of this series, the Trustee or any of the Holders are prevented by applicable law from exercising their respective rights to accelerate the maturity of the Securities of this series, to collect interest on the Securities of this series, or to enforce or exercise any other right or remedy with respect to the Securities of this series, such Subsidiary Guarantor agrees to pay to the Trustee for the account of the Holders, upon demand therefor, the amount that would otherwise have been due and payable had such rights and remedies been permitted to be exercised by the Trustee or any of the Holders. No reference herein to the Indenture and no provision of this Subsidiary Guarantee or of the Indenture shall alter or impair the Subsidiary Guarantee of any Subsidiary Guarantor, which is absolute and unconditional, of the due and punctual payment of the principal (and premium, if any) and interest on the Security upon which this Subsidiary Guarantee is endorsed. Each Subsidiary Guarantor shall be subrogated to all rights of the Holder of this Security against the Company in respect of any amounts paid by such Subsidiary Guarantor on account of this Security pursuant to the provisions of its Subsidiary Guarantee or the Indenture; provided, however, that such Subsidiary Guarantor shall not be entitled to enforce or to receive any payments arising out of, or based upon, such right of subrogation until the principal of (and premium, if any) and interest on this Security and all other Securities of this series issued under the Indenture shall have been paid in full. This Subsidiary Guarantee shall remain in full force and effect and continue to be effective should any petition be filed by or against the Company for liquidation or reorganization, should the Company become insolvent or make an assignment for the benefit of creditors or should a receiver or trustee be appointed for all or any part of the Company’s assets, and shall, to the fullest extent permitted by law, continue to be effective or be reinstated, as the case may be, if at any time payment and performance of the Securities of this series is, pursuant to applicable law, rescinded or reduced in amount, or must otherwise be restored or returned by any Holder of the Securities of this series, whether as a “voidable preference,” “fraudulent transfer,” or otherwise, all as though such payment or performance had not been made. In the event that any payment, or any part thereof, is rescinded, reduced, restored or returned, the Securities of this series shall, to the fullest extent permitted by law, be reinstated and deemed reduced only by such amount paid and not so rescinded, reduced, restored or returned. The Subsidiary Guarantors or any particular Subsidiary Guarantor shall be released from this Subsidiary Guarantee upon the terms and subject to certain conditions provided in the Indenture. By delivery to the Trustee of a supplement to the Indenture referred to in the Security upon which this Subsidiary Guarantee is endorsed in accordance with the terms of the Indenture, each Person that becomes a Subsidiary Guarantor after the date of first issuance of the Securities of this series will be deemed to have executed and delivered this Subsidiary Guarantee for the benefit of the Holder of the Security upon which this Subsidiary Guarantee is endorsed with the same effect as if such Subsidiary Guarantor were named below and had executed and delivered this Subsidiary Guarantee. All terms used in this Subsidiary Guarantee which are defined in the Indenture shall have the meanings assigned to them in such Indenture. This Subsidiary Guarantee shall not be valid or obligatory for any purpose until the certificate of authentication on the Security upon which this Subsidiary Guarantee is endorsed shall have been executed by the Trustee under the Indenture by manual signature. Reference is made to the Indenture for further provisions with respect to this Subsidiary Guarantee. This Subsidiary Guarantee shall be governed by and construed in accordance with the laws of the State of New York.

  • Parent Guarantee (a) The Parent Guarantor will hereby irrevocably and unconditionally guarantee on a senior basis, as a primary obligor and not merely as a surety, to each Holder, the Trustee, the Collateral Agent and their successors and assigns the Guaranteed Obligations. The Parent Guarantor further agrees that the Guaranteed Obligations may be extended or renewed, in whole or in part, without notice or further assent from the Parent Guarantor, and that no extension or renewal of any Guaranteed Obligation shall release the obligations of the Parent Guarantor hereunder. The obligations of the Parent Guarantor hereunder shall be joint and several with the Subsidiary Guarantees of the Subsidiary Guarantors. The Parent Guarantor waives presentation to, demand of payment from and protest to the Issuer of any of the Guaranteed Obligations and also waives notice of protest for nonpayment. The Parent Guarantor waives notice of any default under the Securities or the Guaranteed Obligations. The obligations of the Parent Guarantor hereunder shall not be affected by (i) the failure of any Holder, the Trustee or the Collateral Agent to assert any claim or demand or to enforce any right or remedy against the Issuer or any other Person under this Indenture, the Securities or any other agreement or otherwise; (ii) any extension or renewal of this Indenture, the Securities or any other agreement; (iii) any rescission, waiver, amendment or modification of any of the terms or provisions of this Indenture, the Securities or any other agreement; (iv) the release of any security held by the Collateral Agent on behalf of each Holder and the Trustee for the Guaranteed Obligations or any Subsidiary Guarantor; or (v) the failure of any Holder, the Trustee or the Collateral Agent to exercise any right or remedy against any other guarantor of the Guaranteed Obligations. The Parent Guarantor hereby waives any right to which it may be entitled to have its obligations hereunder divided among itself and the Subsidiary Guarantors, such that the Parent Guarantor’s obligations would be less than the full amount claimed. The Parent Guarantor hereby waives any right to which it may be entitled to have the assets of the Issuer first be used and depleted as payment of the Issuer’s or the Parent Guarantor’s obligations hereunder prior to any amounts being claimed from or paid by the Parent Guarantor hereunder. The Parent Guarantor hereby waives any right to which it may be entitled to require that the Issuer be sued prior to an action being initiated against the Parent Guarantor. The Parent Guarantor further agrees that its Parent Guarantee constitutes a guarantee of payment, performance and compliance when due (and not a guarantee of collection) and waives any right to require that any resort be had by any Holder, the Trustee or the Collateral Agent to any security held for payment of the Guaranteed Obligations.

  • Guarantees of Notes 75 Section 10.01. Subsidiary Guarantees 75 Section 10.02. [Reserved] 76 Section 10.03. Guarantors May Consolidate, etc., on Certain Terms 76 Section 10.04. Releases of Subsidiary Guarantees 77 Section 10.05. Execution and Delivery of Guaranty 77 Section 10.06. Limitation on Guarantor Liability 77

  • Subordination of Guarantee The guarantee and other liabilities and obligations of the Depositor under this Agreement shall constitute unsecured obligations of the Depositor and shall rank subordinate and junior in right of payment to all Senior Indebtedness (as defined in the Indenture) of the Depositor to the extent and in the manner set forth in the Indenture with respect to the Debentures, and the provisions of Article XIII of the Indenture will apply, mutatis mutandis, to the obligations of the Depositor hereunder. The obligations of the Depositor hereunder do not constitute Senior Indebtedness (as defined in the Indenture) of the Depositor.

  • Release of Guarantee The Note Guarantees hereunder may be released in accordance with Section 10.2 of the Indenture.

  • Confirmation of Guarantee The Guarantor hereby confirms and agrees that (i) the Guarantee is and shall continue to be in full force and effect and is otherwise hereby ratified and confirmed in all respects; and (ii) the Guarantee is and shall continue to be an unconditional and irrevocable guarantee of all of the Obligations (as defined in the Guarantee).

Time is Money Join Law Insider Premium to draft better contracts faster.