Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
No Duty to Collect Amounts Due From Dividend and Transfer Agent The Custodian shall not be under any duty or obligation to take action to effect collection of any amount due to the Trust from any Dividend and Transfer Agent of the Trust nor to take any action to effect payment or distribution by any Dividend and Transfer Agent of the Trust of any amount paid by the Custodian to any Dividend and Transfer Agent of the Trust in accordance with this Agreement.
Quarterly Portfolio of Investments Services Subject to the receipt of all Required Data, and as a component of the Services, the Administrator will use such Required Data from each Trust, State Street’s internal systems, and other data providers to prepare a draft portfolio of investments (the “Portfolio of Investments”), compliant with GAAP, as of each Trusts’ first and third fiscal quarter-ends. · Each Trust acknowledges and agrees that it will be responsible for (i) reviewing and approving each such Portfolio of Investments, (ii) incorporating such information into such Trust’s filing mechanism, (iii) attaching each of its Portfolio of Investments to its first and third fiscal quarter-end N-PORT filings, and (iv) submitting such Portfolios of Investments as part of such N-PORT filings electronically to the SEC.
Severability; Maximum Payment Amounts If any provision of this Agreement is prohibited by law or otherwise determined to be invalid or unenforceable by a court of competent jurisdiction, the provision that would otherwise be prohibited, invalid or unenforceable shall be deemed amended to apply to the broadest extent that it would be valid and enforceable, and the invalidity or unenforceability of such provision shall not affect the validity of the remaining provisions of this Agreement so long as this Agreement as so modified continues to express, without material change, the original intentions of the parties as to the subject matter hereof and the prohibited nature, invalidity or unenforceability of the provision(s) in question does not substantially impair the respective expectations or reciprocal obligations of the parties or the practical realization of the benefits that would otherwise be conferred upon the parties. The parties will endeavor in good faith negotiations to replace the prohibited, invalid or unenforceable provision(s) with a valid provision(s), the effect of which comes as close as possible to that of the prohibited, invalid or unenforceable provision(s). Notwithstanding anything to the contrary contained in this Agreement or any other Transaction Document (and without implication that the following is required or applicable), it is the intention of the parties that in no event shall amounts and value paid by the Company and/or any of its Subsidiaries (as the case may be), or payable to or received by any of the Buyers, under the Transaction Documents (including without limitation, any amounts that would be characterized as “interest” under applicable law) exceed amounts permitted under any applicable law. Accordingly, if any obligation to pay, payment made to any Buyer, or collection by any Buyer pursuant the Transaction Documents is finally judicially determined to be contrary to any such applicable law, such obligation to pay, payment or collection shall be deemed to have been made by mutual mistake of such Buyer, the Company and its Subsidiaries and such amount shall be deemed to have been adjusted with retroactive effect to the maximum amount or rate of interest, as the case may be, as would not be so prohibited by the applicable law. Such adjustment shall be effected, to the extent necessary, by reducing or refunding, at the option of such Buyer, the amount of interest or any other amounts which would constitute unlawful amounts required to be paid or actually paid to such Buyer under the Transaction Documents. For greater certainty, to the extent that any interest, charges, fees, expenses or other amounts required to be paid to or received by such Buyer under any of the Transaction Documents or related thereto are held to be within the meaning of “interest” or another applicable term to otherwise be violative of applicable law, such amounts shall be pro-rated over the period of time to which they relate.
Withholding; No Additional Amounts; Tax Event and Redemption All amounts due on this Note will be made without any applicable withholding or deduction for or on account of any present or future taxes, duties, levies, assessments or other governmental charges of whatever nature imposed or levied by or on behalf of any governmental authority, unless such withholding or deduction is required by law. Unless otherwise specified on the face hereof, the Trust will not pay any additional amounts to the Holder of this Note in respect of such withholding or deduction, any such withholding or deduction will not give rise to an event of default or any independent right or obligation to redeem this Note and the Holder will be deemed for all purposes to have received cash in an amount equal to the portion of such withholding or deduction that is attributable to such Holder’s interest in this Note as equitably determined by the Trust.
Payment of Reimbursement Amount To effect the expense reimbursement provided for in this Agreement, the Fund may offset the appropriate Reimbursement Amount against the management fees, Rule 12b-1 fees and/or shareholder servicing fees payable under the Investment Management Agreement, Rule 12b-1 Plan and/or the Shareholder Servicing Agreement. Alternatively, the Reimbursement Amount shall be paid directly by IICO, IDI and/or WISC. Such offset shall be taken, or such direct payment shall be paid, two times per year within 30 days following the date of a Fund’s applicable semi-annual or annual reporting period.
Indemnity for Returned Payments If, after receipt of any payment of, or proceeds applied to the payment of, all or any part of the Obligations, the Agent or any Lender is for any reason compelled to surrender such payment or proceeds to any Person, because such payment or application of proceeds is invalidated, declared fraudulent, set aside, determined to be void or voidable as a preference, impermissible setoff, or a diversion of trust funds, or for any other reason, then the Obligations or part thereof intended to be satisfied shall be revived and continue and this Agreement shall continue in full force as if such payment or proceeds had not been received by the Agent or such Lender, and the Borrower shall be liable to pay to the Agent, and hereby does indemnify the Agent and the Lenders and hold the Agent and the Lenders harmless for, the amount of such payment or proceeds surrendered. The provisions of this Section 4.9 shall be and remain effective notwithstanding any contrary action which may have been taken by the Agent or any Lender in reliance upon such payment or application of proceeds, and any such contrary action so taken shall be without prejudice to the Agent's and the Lenders' rights under this Agreement and shall be deemed to have been conditioned upon such payment or application of proceeds having become final and irrevocable. The provisions of this Section 4.9 shall survive the termination of this Agreement.
Distributions Payable in Cash; Redemption Payments In the event that the Board of the Investment Company shall declare a distribution payable in cash, the Investment Company shall deliver to FTIS written notice of such declaration signed on behalf of the Investment Company by an officer thereof, upon which FTIS shall be entitled to rely for all purposes, certifying (i) the amount per share to be distributed, (ii) the record and payment dates for the distribution, and (iii) that all appropriate action has been taken to effect such distribution. Once the amount and validity of any dividend or redemption payments to shareholders have been determined, the Investment Company shall transfer the payment amounts from the Investment Company's accounts to an account or accounts held in the name of FTIS, as paying agent for the shareholders, in accordance with any applicable laws or regulations, and FTIS shall promptly cause payments to be made to the shareholders.
Distributions Upon Income Inclusion Under Section 409A of the Code Upon the inclusion of any portion of the benefits payable pursuant to this Agreement into the Executive’s income as a result of the failure of this non-qualified deferred compensation plan to comply with the requirements of Section 409A of the Code, to the extent such tax liability can be covered by the Executive’s vested accrued liability, a distribution shall be made as soon as is administratively practicable following the discovery of the plan failure.
