Permitted Delays Subsequent Laws
Permitted Delays Subsequent Laws Sample Clauses
Related to Permitted Delays Subsequent Laws
Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.
ADDITIONAL SPECIAL CONTRACT CONDITIONS Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:
Conditions Subsequent The obligation of the Lender Group (or any member thereof) to continue to make Revolving Loans (or otherwise extend credit hereunder) is subject to the fulfillment, on or before the date applicable thereto, of the conditions subsequent set forth on Schedule 3.6 to this Agreement (the failure by Borrowers to so perform or cause to be performed such conditions subsequent as and when required by the terms thereof (unless such date is extended, in writing, by Agent, which Agent may do without obtaining the consent of the other members of the Lender Group), shall constitute an Event of Default).
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Extraordinary Events Regarding Common Stock In the event that the Company shall (a) issue additional shares of the Common Stock as a dividend or other distribution on outstanding Common Stock, (b) subdivide its outstanding shares of Common Stock, or (c) combine its outstanding shares of the Common Stock into a smaller number of shares of the Common Stock, then, in each such event, the Purchase Price shall, simultaneously with the happening of such event, be adjusted by multiplying the then Purchase Price by a fraction, the numerator of which shall be the number of shares of Common Stock outstanding immediately prior to such event and the denominator of which shall be the number of shares of Common Stock outstanding immediately after such event, and the product so obtained shall thereafter be the Purchase Price then in effect. The Purchase Price, as so adjusted, shall be readjusted in the same manner upon the happening of any successive event or events described herein in this Section 4. The number of shares of Common Stock that the Holder of this Warrant shall thereafter, on the exercise hereof as provided in Section 1, be entitled to receive shall be adjusted to a number determined by multiplying the number of shares of Common Stock that would otherwise (but for the provisions of this Section 4) be issuable on such exercise by a fraction of which (a) the numerator is the Purchase Price that would otherwise (but for the provisions of this Section 4) be in effect, and (b) the denominator is the Purchase Price in effect on the date of such exercise.
Reports of unusual occurrence The Contractor shall, during the Maintenance Period, prior to the close of each day, send to the Authority and the Authority’s Engineer, by facsimile or e- mail, a report stating accidents and unusual occurrences on the Project Highway relating to the safety and security of the Users and Project Highway. A monthly summary of such reports shall also be sent within 3 (three) business days of the closing of month. For the purposes of this Clause 15.4, accidents and unusual occurrences on the Project Highway shall include: (a) accident, death or severe injury to any person; (b) damaged or dislodged fixed equipment; (c) flooding of Project Highway; and (d) any other unusual occurrence.
Longer Delays May Apply We may delay your ability to withdraw funds deposited by check into your account an additional number of days for these reasons: • We believe a check you deposit will not be paid. • You deposit checks totaling more than $5,525 on any one day. • You re-deposit a check that has been returned unpaid. • You have overdrawn your account repeatedly in the last six (6) months. • There is an emergency, such as failure of communications or computer equipment. We will notify you if we delay your ability to withdraw funds for any of these reasons, and we will tell you when the funds will be available. They will generally be available no later than the seventh business day after the day of your deposit.
Effectiveness; Conditions Precedent The effectiveness of this Amendment and the amendments to the Fourth Amended Credit Agreement herein provided are subject to the satisfaction of the following conditions precedent: (a) the Administrative Agent shall have received each of the following documents or instruments in form and substance reasonably acceptable to the Administrative Agent: (i) counterparts of this Amendment, duly executed by each Borrower, each Guarantor, the Administrative Agent, each Lender under the Credit Agreement prior to giving effect to this Amendment that will continue as a Lender under the Credit Agreement after giving effect to this Amendment, and each Joining Lender; (ii) Domestic Term Loan Notes executed by WFS and Revolving Notes executed by WFS, World Fuel Services Europe, Ltd. and World Fuel Singapore in favor of each Joining Lender that has requested a Domestic Term Loan Note and a Revolving Note; (iii) such certificates of resolutions or other action, evidencing the authority and capacity (and if requested by the Administrative Agent, identity) of each Responsible Officer thereof authorized to act as a Responsible Officer in connection with this Amendment and the other Loan Documents to which such Loan Party is a party or is to be a party and good standing certificates (if applicable) of each Borrower and each Guarantor from its jurisdiction of organization; (iv) favorable opinions of counsel to the Borrowers, in each case addressed to the Lenders, as to such matters as the Administrative Agent or the Singapore Agent may reasonably request; and (v) a certificate signed by a Responsible Officer of WFS which shall include a list of the Guarantors and the Unrestricted Subsidiaries, if any, as of the Amendment No. 2 Effective Date and the aggregate book value of assets (including Equity Interests but excluding Investments that are eliminated in consolidation) represented by each such Guarantor and Unrestricted Subsidiary, as applicable, on an individual basis as of September 30, 2016 demonstrating compliance with the 70% Guaranty Threshold; (b) an upfront fee shall have been received for the account of each Lender, including any Joining Lender, party hereto, paid to the Administrative Agent for the account of such Lender, in accordance with that certain Joint Fee Letter dated as of October 12, 2016 (the “Joint Fee Letter”) among WFS, Bank of America, Xxxxxxx Lynch, Pierce, Xxxxxx & Xxxxx Incorporated, HSBC Bank USA, National Association, Xxxxx Fargo Bank, National Association and Xxxxx Fargo Securities, LLC; (c) an amendment fee shall have been received for the account of each Existing Lender party hereto, paid to the Administrative Agent for the account of such Existing Lender, in accordance with the Joint Fee Letter; and (d) all other fees and expenses payable to the Administrative Agent (unless waived by the Administrative Agent), the Joint Lead Arrangers, the Singapore Agent and the Lenders (including all fees owing pursuant to any Fee Letter and the reasonable fees and expenses of counsel to the Administrative Agent to the extent invoiced prior to the date hereof) shall have been paid in full (without prejudice to final settling of accounts for such fees and expenses).
