Changes to Services The Parties acknowledge and agree that there will be changes to the scope of the Services during the Contract Period. The Customer may amend the Stories that are comprised within the Minimum Marketable Features of a Release at any time during the Release at no additional charge and without adopting the Change Control Procedure set out in Clause 28 above provided that: the Customer shall not be entitled to make any changes to the Stories that form the subject of a Sprint following the mutual agreement by the Parties of the Sprint Plan for that Sprint; new Stories and/or changes to existing Stories may only be introduced if: existing Stories with an equivalent number of Story Points are removed; or existing Stories are reduced in size by the equivalent number of Story Points, such that the total number of Story Points for the Release remains constant throughout the Release. The Supplier shall consider any request by the Customer to increase the number of Story Points for a Release, and may, subject to the Change Control Procedure set out at Clause 28, agree to such request.
Changes to Project Should the Subgrantee wish to make changes to the outcomes, Scope of Work, equipment to be purchased, key personnel, expenditures or deliverables, the Subgrantee must request permission to revise the project. This is done by submitting a Change Request. Changes within a budget category that are more than ten percent (10%) of the award or that move funds from one budget category to another require submission of a Change Request. Approval must be obtained from the Division before the changes are implemented in the project. Approval will be granted for changes that are consistent with the intent of the approved application or prior Change Requests. Changes to the project must be requested using the Change Request in the DOS Grants System at xxxxxxxxx.xxx.
Changes to Scope of Work The City of Nashua may, at any time, by written order, make changes to the general scope, character, or cost of this contract and in the services or work to be performed, either increasing or decreasing the scope, character, or cost of Independent Contractor's performance under the contract. Independent Contractor shall provide to the City of Nashua within 10 calendar days, a written proposal for accomplishing the change. The proposal for a change shall provide enough detail, including personnel hours for each sub-task and cost breakdowns of tasks, for the City of Nashua to be able to adequately analyze the proposal. The City of Nashua will then determine in writing if Independent Contractor should proceed with any or all of the proposed change. If the change causes an increase or a decrease in Independent Contractor's cost or time required for performance of the contract as a whole, an equitable adjustment shall be made and the contract accordingly modified in writing. Any claim of Independent Contractor for adjustment under this clause shall be asserted in writing within 30 days of the date the City of Nashua notified Independent Contractor of the change. When Independent Contractor seeks changes, Independent Contractor shall, before any work commences, estimate their effect on the cost of the contract and on its schedule and notify the City of Nashua in writing of the estimate. The proposal for a change shall provide enough detail, including personnel hours for each sub-task and cost breakdowns of tasks, for the City of Nashua to be able to adequately analyze the proposal. The City of Nashua will then determine in writing if Independent Contractor should proceed with any or all of the proposed change. Except as provided in this paragraph, Independent Contractor shall implement no change unless the City of Nashua in writing approves the change. Unless otherwise agreed to in writing, the provisions of this contract shall apply to all changes. The City of Nashua may provide verbal approval of a change when the City of Nashua, in its sole discretion, determines that time is critical or public health and safety are of concern. Any verbal approval shall be confirmed in writing as soon as practicable. Any change undertaken without prior City of Nashua approval shall not be compensated and is, at the City of Nashua's election, sufficient reason for contract termination.
Changes to Service We may, from time to time, modify the Service to reflect improvements and other changes and modifications to our network. In addition, we reserve the right to discontinue or limit Service as required to comply with or satisfy our obligations under applicable laws or regulations, including when changes to or interpretations of such laws and regulations have a material, adverse effect on the business, technical or economic feasibility of providing Service, as determined by us in our reasonable judgment.
Changes to the Terms of Use We may revise and update these Terms of Use from time to time in our sole discretion. All changes are effective immediately when we post them, and apply to all access to and use of the Website thereafter. Your continued use of the Website following the posting of revised Terms of Use means that you accept and agree to the changes. You are expected to check this page from time to time so you are aware of any changes, as they are binding on you.
Changes to the Website We may update the content on this Website from time to time, but its content is not necessarily complete or up-to-date. Any of the material on the Website may be out of date at any given time, and we are under no obligation to update such material.
Changes to the Services We provide Services in a multi- user environment and must therefore reserve the right to modify and discontinue Services. We may modify a Service at any time without degrading its functionality or security features For current subscriptions, we may degrade the functionality of a Service or discontinue a Service only in case of (i) legal requirements; (ii) changes in the Services imposed by Siemens’ subcontractors; (iii) the termination of our relationship with a provider of software and/or services used by us which are material for the provision of such Service; (iv) lack of customer acceptance; and/or (v) security risks. We will notify you of any material degradation of functionality or the discontinuation of a Service and the effective date at least 80 days prior to such change, and you may terminate the modified Service 30 days prior to the change effective date. In the event of such termination or discontinuation of a Service, we will refund any prepaid amounts for the applicable Service on a pro-rata basis for the remaining Subscription Term. We do not maintain prior versions of a Service.
NETWORK CHANGES 3.1. Sprint shall provide notice of network changes and upgrades in accordance with §§ 51.325 through 51.335 of Title 47 of the Code of Federal Regulations. Sprint may discontinue any interconnection arrangement, Telecommunications Service, or Network Element provided or required hereunder due to network changes or upgrades after providing CLEC notice as required by this Section. Sprint agrees to cooperate with CLEC and/or the appropriate regulatory body in any transition resulting from such discontinuation of service and to minimize the impact to customers, which may result from such discontinuance of service.
Changes to the Work 7.1 Changes to the Work may be accomplished by preparation of and execution of a change order or construction change directive. Change orders or construction change directives will be preceded by a change proposal request initiated by the Architect. The Construction Manager shall provide prices and details within 30 days of receipt of a change proposal request, and the Architect shall forward the completed change proposal request to the Owner within 15 days after receipt of the information provided by the Construction Manager.
Changes to the Service We reserve the right to terminate, modify, add and remove features from the Service at any time in our sole discretion. You may reject changes by discontinuing use of the Service. Your continued use of the Service will constitute your acceptance of and agreement to such changes. Maintenance to the Service may be performed from time-to-time resulting in interrupted service, delays or errors in the Service and we shall have no liability for any such interruptions, delays or errors.
