Support Structure means an existing or new structure that supports or can support a mobile service facility, including a mobile service support structure, utility pole, water tower, building, or other structure.
Project Start Date means the first Milestone Start Date specified in Schedule B;
Project Schedule means a document that, with respect to each Phase of the Project, identifies, coordinates and integrates the anticipated design and construction schedules, the Contracting Authority’s and Owner's responsibilities, government authority reviews and other activities as are necessary for the timely completion of the Work.
Attachment Facilities means the facilities necessary to physically connect a Customer Facility to the Transmission System or interconnected distribution facilities.
Completion of work means completion of the entire contracted work. Exhaustion of quantity of any particular item mentioned in the bid document shall not imply completion of work or any component thereof.
Wireless support structure means a freestanding structure designed to support or capable of supporting small cell wireless facilities. Wireless support structure does not include a utility pole.
technical specification means, with respect to any Software, the document setting forth the technical specifications for such Software and included in the Statement of Work.
construction site means a workplace where construction work is being performed;
Design Change is a change in work and/or materials shown in the Schedule of Items and described in Plans or specifications that has been mutually agreed to in writing or ordered by Contracting Officer. Changes of a minor nature (such as adjustment in horizontal and vertical alignment, that do not exceed specified tolerance, necessary to maintain or balance earthwork quantities substantially as designed) and variation in quantities, as described in B5.251, shall not be considered Design Changes.
Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;
Implementation Schedule means the Implementation Schedule in Section VII of the tendering documents.
Configuration means State-specific changes made to the Software without Source Code or structural data model changes occurring.
Additional Work to mean additions or deletions or modifications to the amount, type or value of the Work and Services as required in this Contract, as directed and/or approved by the County.
Technical Specifications means the detailed requirements for the Work furnished by the Architect and set forth in Book 3 of the Contract Documents.
Installation means that the System or a Subsystem as specified in the Contract is ready for Commissioning as provided in GCC Clause 26 (Installation).
Installation Site means the site at which the Product is originally installed.
Development Schedule shall have the meaning set forth in Section 1.1.
Unmanned aircraft means an aircraft that is not:
Schedule of Work means that schedule attached to the Interconnection Construction Service Agreement setting forth the timing of work to be performed by the Constructing Entity pursuant to the Interconnection Construction Service Agreement, based upon the Facilities Study and subject to modification, as required, in accordance with Transmission Provider’s scope change process for interconnection projects set forth in the PJM Manuals. Scope of Work:
Operations Support Systems (OSS means the suite of functions which permits CLEC to interface to the ILEC for pre-ordering, ordering, provisioning, maintenance/ repair and billing as described in the Attachment 07 – Operations Support Systems (OSS) herein.
Scope of Work means the description of Services and Deliverables specified in the Contract and as may be amended.
Design flow means the average annual flow or average daily flow specified in an approved facilities plan or approved plans and specifications, the flow specified in a WPDES permit, or the flow required to meet performance standards.
Functional Specifications means the descriptions of features and functions of the Application as expressly set forth in Quote.
Constructional Plant means all appliances or things whatever nature required in or about the execution, completion or maintenance of the works or temporary works (as hereinafter defined) but does not include materials or other things intended to form or forming part of the permanent work or temporary housing, hutting, office, stores, etc.,
Statement of Work means the description of activities performed in completing the Project, as specified in the Contract and as may be amended.
Service Specification means and include detailed description, statements to technical data, performance characteristics, and standards (Indian as well as) as applicable and as specified in the Contract as well as those specifications relating to Industry standards and codes applicable to the performance of the work, work performance quality and the specifications affecting the works or any additional specification required to be produced by the DCO to meet the design criteria.