Powers and Duties of the Adjudicator Sample Clauses

Powers and Duties of the Adjudicator. In reaching his decision the Adjudicator shall act impartially and set his own procedure; and at his absolute discretion may take the initiative in ascertaining the facts and the law as he considers necessary in respect of the referral which may include the following: 1 using his own knowledge and/or experience; 2 opening up, reviewing and revising any certificate, opinion, decision, requirement or notice issued, given or made under the Contract as if no such certificate, opinion, decision, requirement or notice had been issued, given or made; 3 requiring from the Parties further information than that contained in the notice of referral and its accompanying documentation or in any written statement provided by the Parties including the results of any tests that have been made or of any opening up;
Sample 1
AutoNDA by SimpleDocs

Related to Powers and Duties of the Adjudicator

  • Powers and Duties Each Lender irrevocably authorizes each Agent to take such action on such Lender’s behalf and to exercise such powers, rights and remedies hereunder and under the other Credit Documents as are specifically delegated or granted to such Agent by the terms hereof and thereof, together with such powers, rights and remedies as are reasonably incidental thereto. Each Agent shall have only those duties and responsibilities that are expressly specified herein and the other Credit Documents. Each Agent may exercise such powers, rights and remedies and perform such duties by or through its agents or employees. No Agent shall have, by reason hereof or any of the other Credit Documents, a fiduciary relationship in respect of any Lender; and nothing herein or any of the other Credit Documents, expressed or implied, is intended to or shall be so construed as to impose upon any Agent any obligations in respect hereof or any of the other Credit Documents except as expressly set forth herein or therein.

  • Duties of the Agent (a) The Agent shall promptly forward to a Party the original or a copy of any document which is delivered to the Agent for that Party by any other Party.

  • Duties of the City City shall make available to Consultant all data and information in the City's possession which City deems necessary to the preparation and execution of the work, and City shall actively aid and assist Consultant in obtaining such information from other agencies and individuals as necessary. The Director may authorize a staff person to serve as his or her representative for conferring with Consultant relative to Consultant's services. The work in progress hereunder shall be reviewed from time to time by City at the discretion of City or upon the request of Consultant. If the work is satisfactory, it will be approved. If the work is not satisfactory, City will inform Consultant of the changes or revisions necessary to secure approval.

  • Duties of the Committee The Committee will be responsible for developing recommendations based on consensus (agreement and/or abstinence constitutes consensus) for the CAAT retirees' group insurance plans. The duties of the Committee are to:

  • Duties of City CITY shall provide pertinent information regarding its requirements for the project. CITY shall examine documents submitted by CONSULTANT and shall render decisions pertaining thereto promptly, to avoid unreasonable delay in the progress of CONSULTANT'S work.

  • DUTIES OF THE CONTRACTOR shall be to provide services in accordance with Exhibit A, Statement of Work, which is attached hereto and made a part hereof. The performance of these duties shall be at times and places within the limits of District policy at the discretion of the Contractor.

  • Duties of the Parties JHU is not a commercial organization. It is an institute of research and education. Therefore, JHU has no ability to evaluate the commercial potential of any PATENT RIGHTS or LICENSED PRODUCT or other license or rights granted in this Agreement. It is therefore incumbent upon Company to evaluate the rights and products in question, to examine the materials and information provided by JHU, and to determine for itself the validity of any PATENT RIGHTS, its freedom to operate, and the value of any LICENSED PRODUCTS or SERVICES or other rights granted.

  • Rights and Duties of Warrant Agent (1) In the exercise of the rights and duties prescribed or conferred by the terms of this Indenture, the Warrant Agent shall exercise that degree of care, diligence and skill that a reasonably prudent warrant agent would exercise in comparable circumstances. No provision of this Indenture shall be construed to relieve the Warrant Agent from liability for its own gross negligent action, wilful misconduct, bad faith or fraud under this Indenture.

  • SCOPE AND DUTIES Client hires Attorney for the purpose of domestic relations litigation. Attorney shall provide those legal services reasonably required to represent Client, and shall take reasonable steps to keep Client informed of progress and to respond to Client’s inquiries. Client shall be truthful with Attorney, cooperate in the preparation and trial of the case, appear on reasonable notice for depositions and Court appearances, keep Attorney informed of developments, abide by this Agreement, pay Attorney’s bills on time and keep Attorney advised of Client’s address, telephone number, and whereabouts. Client agrees not to compromise the claim without discussing the matter with Attorney, in advance, and Attorney is not authorized to compromise the claim without Client’s consent. OTHER TERMS: None.

  • Responsibilities of the District 12.1. The District shall examine the documents submitted by the Architect and shall render decisions so as to avoid unreasonable delay in the process of the Architect’s Services.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!