Completion Certificate Upon completion of Construction Works and the Independent Engineer determining the Tests to be successful, it shall forthwith issue to the Concessionaire and the Authority a certificate substantially in the form set forth in Schedule-J (the “Completion Certificate”).
Project Completion Report At the completion of construction and once a Project is placed in service, the Subrecipient must submit a Project Completion Report that includes the total number of units built and leased, affordable units built and leased, DR-MHP units built and leased, an accomplishment narrative, and the tenants names, demographics and income for each DR-MHP unit.
Inspection Checklist (check one) ☐ In order to avoid disagreements about the condition of the Premises, at the time of accepting possession of the Premises, Tenant will complete the Inspection Checklist incorporated herein by reference and attached hereto as Exhibit B and record any damage or deficiencies that exist at the commencement of the Term. Landlord will be liable for the cost of any cleaning or repair to correct damages found at the time of the inspection. Tenant will be liable for the cost of any cleaning and/or repair to correct damages found at the end of the Term if not recorded on the inspection checklist, normal wear and tear excepted. ☐ The Tenant is NOT required to complete an inspection checklist.
Project Reports; Completion Report 1. The Recipient shall monitor and evaluate the progress of the Project and prepare Project Reports in accordance with the provisions of Section 2.06 of the Standard Conditions and on the basis of indicators agreed with the World Bank. Each Project Report shall cover the period of one (1) calendar semester, and shall be furnished to the World Bank not later than one (1) month after the end of the period covered by such report.
Checklist The Service will be able to respond more quickly to a VCP request if the request is carefully prepared and complete. The checklist in Appendix C is designed to assist Plan Sponsors and their representatives in preparing a submission that contains the information and documents required under this revenue procedure. The checklist in Appendix C must be completed, signed, and dated by the Plan Sponsor or the Plan Sponsor's representative, and should be placed on top of the submission. A photocopy of this checklist may be used.
Final Certificate, Design Professional’s Certificate of Final Completion The Certificate issued by the Design Professional stating that all work has been completed in accordance with the terms of the Contract Documents. See Section 6,
Construction Progress Schedule; Overall Project Schedule The Contractor shall submit for review by the Design Professional and approval by the Owner a Construction Progress Schedule based upon the Design Professional’s Preliminary Design and Construction Schedule and prepared using a CPM (Critical Path Method) process within sixty days after the Effective Date of the Contract, utilizing a full-featured software package in a form satisfactory to the Design Professional and Owner, showing the dates for commencement and completion of the Work required by the Contract Documents, including coordination of mechanical, plumbing, and electrical disciplines, as well as coordination of the various subdivisions of the Work within the Contract. Milestones must be clearly indicated and sequentially organized to identify the critical path of the Project. The Construction Schedule will be developed to represent the CSI specification divisions. It shall have the minimum number of activities required to adequately represent to the Owner the complete scope of Work and define the Project’s (and each Phase’s if phased) critical path and associated activities. The format of the Construction Progress Schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, inspections for Material Completion and Occupancy Date, and Final Completion Date. The Contractor shall submit, along with the Construction Progress Schedule, the Submittal Schedule for approval by the Design Professional, correlating the associated approval dates for the documents with the Construction Progress Schedule. Upon recommendation by the Design Professional and approval by the Owner, the Construction Progress Schedule shall become the Overall Project Schedule, which shall be utilized by the Design Professional, Owner and Contractor. The Contractor must provide the Design Professional and the Owner with monthly updates of the Overall Project Schedule indicating completed activities and any changes in sequencing or activity durations, including approved change orders. See also Article 3.3.5.
Final Project Report Prepare a Final Project Report that addresses, to the extent feasible, comments made by the Grant Manager on the Draft Final Project Report. Submit one (1) reproducible master and an electronic copy of the final. Upload an electronic copy of the final report in pdf format to the FAAST system.
Exhibit D - Debarment Certification By signing and submitting this Contract, the Contractor is agreeing to abide by the debarment requirements as set out below. • The certification in this clause is a material representation of fact relied upon by County. • The Contractor shall provide immediate written notice to County if at any time the Contractor learns that its certification was erroneous or has become erroneous by reason of changed circumstances. • Contractor certifies that none of its principals, affiliates, agents, representatives or contractors are excluded, disqualified or ineligible for the award of contracts by any Federal agency and Contractor further certifies to the best of its knowledge and belief, that it and its principals: • Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded by any Federal Department or Agency; • Have not been convicted within the preceding three-years of any of the offenses listed in 2 CFR 180.800(a) or had a civil judgment rendered against it for one of those offenses within that time period; • Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (Federal, State, or Local) with commission of any of the offenses listed in 2 CFR 180.800(a); • Have not had one or more public transactions (Federal, State, or Local) terminated within the preceding three-years for cause or default. • The Contractor agrees by signing this Contract that it will not knowingly enter into any subcontract or covered transaction with a person who is proposed for debarment, debarred, suspended, declared ineligible, or voluntarily excluded from participation in this covered transaction. • Any subcontractor will provide a debarment certification that includes the debarment clause as noted in preceding bullets above, without modification.
Owner Certification During the term of this Contract, the Owner certifies that: