PRECONSTRUCTION OR RENOVATION Sample Clauses

PRECONSTRUCTION OR RENOVATION. (a) In the event the PROJECT's Units, amenities or facilities are unavailable for occupancy due to construction or renovation, AFFILIATE will advise each purchaser of a Vacation Interest at the PROJECT, prior to enrollment with INTERVAL, that said purchaser will not be entitled to utilize the INTERVAL NETWORK until his/her Unit Week and the PROJECT are available for occupancy as reasonably determined by INTERVAL The PROJECT shall be deemed "unavailable for occupancy" until such time as INTERVAL determines in its good faith judgment that the PROJECT is sufficiently complete to be desirable for exchange (e.g., Units complete and fully furnished, amenities available for use, and remaining construction does nor interfere with the use and enjoyment of completed Units, amenities and facilities). An Individual Member in good standing who is unable to use the exchange privilege due to construction and/or renovation at the PROJECT shall be entitled to use such other benefits, privileges and discounts as may be afforded to Individual Members from time to time.
Sample 1
AutoNDA by SimpleDocs
PRECONSTRUCTION OR RENOVATION. (a) In the event the accommodations or facilities of any Approved Club Resort are unavailable for occupancy due to construction or renovation, AFFILIATE will advise each purchaser of a Vacation Interest in the CLUB prior to enrollment with INTERVAL, that the purchaser will not be entitled to utilize the INTERVAL NETWORK until his/her Unit Week and the Approved Club Resort are available for occupancy as reasonably determined by INTERVAL. An Approved Club Resort shall be deemed "unavailable for occupancy" until such time as INTERVAL determines in its good faith judgment that such resort is sufficiently complete to be desirable for exchange (e.g., Units complete and fully furnished, amenities available for use, any ongoing construction does not interfere with the use and enjoyment of completed Units, amenities and facilities). An Individual Member in good standing who is unable to use the exchange privilege due to construction and/or renovation at an Approved Club Resort shall be entitled to use such other benefits, privileges and discounts as may be afforded to Individual Members from time to time.
Sample 1

Related to PRECONSTRUCTION OR RENOVATION

  • Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.

  • Construction of the Project The Corporation hereby represents that it has caused the Project to be completed and acknowledges that it shall not be entitled to any reimbursement for the cost of construction of the Project from the Authority, the Trustee or the Holders of the Bonds, nor shall it be entitled to any diminution or postponement of the payments required to be paid by the Corporation pursuant to this Participation Agreement or the Corporation Obligations. Section 3.04.

  • Construction of Project Purchaser shall (i) perform the Final Assembly Work which is set forth in Exhibit P hereto, (ii) perform all civil works (including roads, grading, maintenance facilities, meteorological towers and other items); (iii) perform all electrical works (including collection lines, Electrical Infrastructure, Transmission Facilities, Interconnection Facilities and other items); (iv) provide and install a remote terminal unit and cabling to the Substation, meteorological towers, and communications lines for the SCADA System to the Substation; and (v) provide any other items required for the operation of the Project; and

  • Construction of Tenant Improvements Promptly following approval of the Final TI Working Drawings, Landlord shall apply for and use reasonable efforts to obtain the necessary permits and approvals to allow construction of Landlord’s TI Work. Upon receipt of such permits and approvals, Landlord shall, at Tenant’s expense (subject to the application of the Tenant Improvement Allowance provided in this Workletter, and subject to any other applicable provisions of the Lease or of this Workletter expressly making any specific item of expense or cost the responsibility of Landlord), diligently construct and complete Landlord’s TI Work substantially in accordance with the Approved TI Plans, subject to Unavoidable Delays and Tenant Delays (if any). Such construction shall be performed in a good and workmanlike manner and shall conform to all applicable governmental codes, laws and regulations in force at the time such work is completed. Without limiting the generality of the foregoing, Landlord shall be responsible for compliance of Landlord’s TI Work with the requirements of the Americans with Disabilities Act and all similar or related requirements pertaining to access by persons with disabilities, but nothing in this sentence shall be construed to make Landlord responsible for bearing the cost of any such compliance, to the extent the compliance work is reasonably attributable to or related to the particular nature or design of the Tenant Improvements or is for any other reason expressly made Tenant’s cost or responsibility under any applicable provision of the Lease or of this Workletter. Landlord shall have the right, in its sole discretion, to decide whether and to what extent to use union labor on or in connection with Landlord’s Work, and shall use the TI General Contractor to construct all of Landlord’s TI Work. Landlord and Tenant shall each have a right to approve all subcontractors engaged in connection with the construction of the Tenant Improvements and to review and approve all competitive bids for any elements of the Tenant Improvements, such approval in each instance not to be unreasonably withheld, conditioned or delayed by either party.

  • Construction or Rehabilitation of Mortgaged Property No Mortgage Loan was made in connection with the construction or rehabilitation of a Mortgaged Property or facilitating the trade-in or exchange of a Mortgaged Property;

  • CONSTRUCTION OF PREMISES Landlord will diligently perform “Landlord’s Work” and Tenant will diligently perform “Tenant’s Work” (if any) as described in the Workletter attached as Exhibit “F” in accordance with the Workletter and the rest of this Lease. Landlord’s Work will be deemed substantially completed even if Landlord has not completed “punch list” or other minor items, as long as (i) Landlord agrees to use reasonable efforts to complete these items within thirty (30) days of signing the punch-list, excluding any items which require special materials or equipment that are unavailable; and (ii) the punch-list items can be completed after Tenant’s occupancy without causing substantial interference with Tenant’s use of the Premises. Tenant’s final punch list will be submitted to Landlord with in fifteen (15) days after Landlord notifies Tenant that Landlord’s Work is substantially completed. Substantial completion of Landlord’s Work will be deemed to have occurred on the earlier of: the date as of which Landlord’s architect certifies in good faith that Landlord’s Work has been substantially completed in substantial conformance with the plans and specifications therefore (or the date as of which such substantial completion would have occurred but for any delays or Tenant’s Work for which Tenant is responsible); or the date that the applicable governmental authorities issue a temporary or final certificate of occupancy for the Premises (or the date as of which such a certificate of occupancy reasonable could have been issued but for any delays or Tenant’s Work for which Tenant is responsible). If and as long as Tenant does not interfere in any way with the construction process (by causing disharmony, scheduling or coordinating difficulties, etc.) Tenant, may, at Tenant’s sole risk and expense, enter the Premises 30 days prior to the substantial completion of Landlord’s Work (“Early Access Period”) for the purposes of installing Tenant’s decorations, movable furniture and business fixtures. The determination of such interference by Landlord shall be conclusive. The Early Access Period shall commence upon Tenant’s receipt of Landlord’s notice of same. For the time period commencing on the date that Landlord’s Work is substantially complete and ending on the date that is ten days after such substantial completion (the “Fixture Period”), Tenant shall have the right to access the Premises for the purposes of installing its furniture, fixtures, audio/visual, security, and other equipment Any access by Tenant prior to the Lease Commencement Date shall be subject to all the terms and conditions of this Lease, except that Tenant shall not be obligated to pay rent during the Fixture Period.

  • Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.

  • Demolition Landlord shall have the right to terminate this Lease if Landlord proposes or is required, for any reason, to remodel, remove, or demolish the Building or any substantial portion thereof. Such cancellation shall be exercised by Landlord by the service of not less than ninety (90) days' written notice of such termination. Such notice shall set forth the date upon which the termination will be effective. No money or other consideration shall be payable by Landlord to Tenant for Landlord's exercise of this right, and the right is hereby reserved to Landlord and all purchasers, successors, assigns, transferees, and ground tenants of Landlord, as the case may be, and is in addition to all other rights of Landlord. Tenant has read the foregoing and understands that Landlord has a right to terminate this Lease as provided above.

  • Construction of the Improvements Once development of the Property has commenced, the construction of the Improvements shall be pursued with due diligence and continuity, in a good and workmanlike manner, and in accordance with sound building and engineering practices, all applicable governmental requirements, and the Development Plan. Borrower shall not permit cessation of work for a period in excess of thirty (30) days during any period of time during which development on the Property is scheduled to be performed without the prior written consent of Lender, which may be given or withheld in Lender’s sole discretion, except for delays due to strikes, riots, acts of God, war, unavailability of labor or materials, governmental laws, regulations or restrictions and Borrower shall promptly notify Lender of any such delays; provided, however, that in no event shall work cease for a period in excess of sixty (60) days regardless of the cause. Borrower shall cause all materials supplied for, or intended to be utilized in, the development of any part of the Property, but not affixed to or incorporated into the Property, to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards, as required by Lender, to prevent loss, theft, damage, or commingling with other materials or projects.

  • Commencement of Construction Construction of the Project will start within thirty (30) days after notification to the Developer by the Owner, or as soon thereafter as weather and ground conditions permit.

Time is Money Join Law Insider Premium to draft better contracts faster.