Preliminary Matters 3.1. At least five (5) days prior to the pre-construction meeting described in Section 3.2, Contractor shall submit to Consultant for Consultant’s review and acceptance:
3.1.1. A progress schedule in the indicated form: Bar Chart Modified Critical Path Method (“CPM”) CPM Computerized CPM (CPM is interpreted to be generally as outlined in the Association of General Contractors (“AGC”) publication, “The Use of CPM in Construction.”) The progress schedule shall indicate the start and completion dates of the various stages of the Work, and shall show an activity network for the planning and execution of the Work. Included with the progress schedule shall be a narrative description of the progress schedule. The progress schedule must be updated monthly by Contractor, submitted as part of each Application for Payment, and must be acceptable to Consultant.
3.1.2. A preliminary schedule of Shop Drawing submissions; and
3.1.3. In a lump sum contract or in a contract that includes lump sum bid items of Work, a preliminary schedule of values for all of the Work that includes quantities and prices of items aggregating the Contract Price and that subdivides the Work into component parts in sufficient detail to serve as the basis for progress payments during construction. Such prices will include a breakdown of labor, equipment, materials, and an appropriate amount of overhead and profit applicable to each item of Work, which amounts Contractor must confirm in writing at the time of submission. In addition, after award but prior to the submission of the progress schedule, Consultant, Contract Administrator, and Contractor shall meet with all utility owners and secure from them a schedule of utility relocation; provided, however, that neither Consultant nor Town shall be responsible for the nonperformance by the utility owners.
3.2. At a time specified by Consultant, but before Contractor starts the Work at the Project site, a conference attended by Contractor, Consultant, and others as deemed appropriate by Contract Administrator, will be held to discuss the schedules referred to in Section 3.1; to discuss procedures for handling Shop Drawings and other submittals and for processing Applications for Payment; and to establish a working understanding among the Parties as to the Work.
3.3. Within thirty-five (35) days from the Project Initiation Date set forth in the applicable Notice to Proceed, a conference attended by Contractor, Consultant, and others, as appropriate, will be held to finalize the schedules submitted in accordance with Section 3.1. Within forty-five
Preliminary Design § 4.3.1 Upon the Owner’s issuance of a written consent to proceed under Section 4.2.3, the Design-Builder shall prepare and submit a Preliminary Design to the Owner. The Preliminary Design shall include a report identifying any deviations from the Owner’s Criteria, and shall include the following:
.1 Confirmation of the allocations of program functions;
.2 Site plan; .3 Building plans, sections and elevations;
Preliminary Plans Tenant shall prepare and submit to Landlord for approval schematics of the Tenant Improvements prepared in conformity with the applicable provisions of this Exhibit F (the “Preliminary Plans”). The Preliminary Plans shall contain sufficient information and detail to accurately describe the proposed design to Landlord and such other information as Landlord may reasonably request. Landlord shall notify Tenant in writing within ten (10) business days after receipt of the Preliminary Plans whether Landlord approves or objects to the Preliminary Plans and of Landlord’s specific objections to the Preliminary Plans (if any). Landlord’s failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If Landlord reasonably objects to the Preliminary Plans, then Tenant shall revise the Preliminary Plans to remedy Landlord’s objections. Tenant shall then resubmit the revised Preliminary Plans to Landlord for approval, such approval not to be unreasonably withheld, conditioned or delayed. Landlord’s approval of or objection to any revised Preliminary Plans and Tenant’s correction of the same shall continue as provided above for the original Preliminary Plans until Landlord has approved the Preliminary Plans in writing. The Preliminary Plans that are approved by Landlord without objection shall be referred to as the “Approved Preliminary Plans.”
PRELIMINARY RECITALS Executive’s employment with the Company has terminated.
Preliminary Approval Order “Preliminary Approval Order” means the order of the Court preliminarily approving this Settlement Agreement.
Preliminary 1. Short title
Preliminary Approval A. As soon as practicable after this Agreement is fully executed, for settlement purposes only, the Plaintiffs and Co-Lead Counsel shall request the Court to make preliminary findings, enter the Preliminary Approval Order granting conditional certification of the Class, subject to final findings and ratification in the Final Order and Judgment, and appoint the Plaintiffs as class representatives and Co-Lead Counsel as counsel for the Class. Neither Defendant nor Defendant’s Counsel will object to such requests for the purposes of effectuating the Settlement. Such agreement not to object to class certification shall extend only as necessary to effectuate the Settlement. As set forth in the draft Preliminary Approval Order, the Plaintiffs shall request the Court to enter an order:
1. preliminarily approving and finding this Agreement and the Settlement as being fair, reasonable, and adequate;
2. conditionally certifying the Litigation as a settlement class action under Rule 23(b)(3) and (e) of the Federal Rules of Civil Procedure;
3. appointing Plaintiffs as class representatives and Co-Lead Counsel as counsel for the Class;
4. preliminarily approving the form, manner, and content of the Class Notice, as provided herein, and finding that notice is fair, reasonable, and the best notice practicable under the circumstances in connection with notifying the Class Members of their rights and responsibilities under the Settlement and satisfying due process and Rule 23 of the Federal Rules of Civil Procedure;
5. appointing the Settlement Administrator to send Class Notice and administer the Settlement;
6. providing that Class Members will have until a date certain to object to or file a request for exclusion from the Settlement, as provided herein;
Preliminary Examination 24.1 The Purchaser will examine the bids to determine whether they are complete, whether any computational errors have been made, whether required sureties have been furnished, whether the documents have been properly signed, and whether the bids are generally in order. 24.2 Arithmetical errors will be rectified on the following basis. If there is a discrepancy between the unit price and the total price that is obtained by multiplying the unit price and quantity, the unit price shall prevail, and the total price shall be corrected. If the Supplier does not accept the correction of the errors, its bid will be rejected, and its bid security may be forfeited. If there is a discrepancy between words and figures, the amount in words will prevail. 24.3 The Purchaser may waive any minor informality, nonconformity, or irregularity in a bid which does not constitute a material deviation, provided such waiver does not prejudice or affect the relative ranking of any Bidder. 24.4 Prior to the detailed evaluation, pursuant to ITB Clause 25 the Purchaser will determine the substantial responsiveness of each bid to the bidding documents. For purposes of these Clauses, a substantially responsive bid is one which conforms to all the terms and conditions of the bidding documents without material deviations. Deviations from, or objections or reservations to critical provisions, such as those concerning Bid Security (ITB Clause 15), Applicable Law (GCC Clause 30), and Taxes and Duties (GCC Clause 32), will be deemed to be a material deviation. The Purchaser’s determination of a bid’s responsiveness is to be based on the contents of the bid itself without recourse to extrinsic evidence.
Preliminary Design Phase 30 percent plans)
A. Proceed with Preliminary Design Phase after the completion of the Conceptual phase which includes: Acceptance by Owner of the Conceptual Report and any other Study and Report Phase deliverables; selection by Owner of a recommended solution; issuance by Owner of any instructions for use of Project Strategies, Technologies, and Techniques, or for inclusion of sustainable features in the design, and Indication by Owner of any specific modifications or changes in the scope, extent, character, or design requirements of the Project desired by Owner.
1. Prepare Preliminary Design Phase documents consisting of final design criteria, preliminary drawings, outline specifications, and written descriptions of the Project.
2. Include on plans, property lines, structure locations, ownership names and contact information.
3. In preparing the Preliminary Design Phase documents, use any specific applicable Project Strategies, Technologies, and Techniques authorized by Owner during or following the Study and Conceptual Phase, and include sustainable features, as appropriate, pursuant to Owner’s instructions.
4. Provide necessary field surveys, topographic and utility mapping for Engineer’s design purposes. Comply with the scope of work and procedure for the identification and mapping of existing utilities as defined by Section A1.03 “Utility Requirements” and Section A1.04 “Survey Services”
5. Visit the Site as needed to prepare the Preliminary Design Phase documents.
6. Advise Owner if additional reports, data, information, or services of the types described are necessary and assist Owner in obtaining such reports, data, information, or services.
7. Continue to assist Owner with Project Strategies, Technologies, and Techniques that Owner has chosen to implement.
8. Based on the information contained in the Preliminary Design Phase documents, prepare a revised opinion of probable Construction Cost, and assist Owner in tabulating the various cost categories which comprise Total Project Costs.
9. Obtain and review Owner’s instructions regarding Owner’s procurement of construction services (including instructions regarding advertisements for bids, instructions to bidders, and requests for proposals, as applicable), Owner’s construction contract practices and requirements, insurance and bonding requirements, electronic transmittals during construction, and other information necessary for the finalization of Owner’s bidding-related documents (or requests for proposals or other construction procurement documents), and Construction Contract Documents. Also obtain and review copies of Owner’s design and construction standards, Owner’s standard forms, general conditions, supplementary conditions, text, and related documents or content for Engineer to include in the draft bidding-related documents (or requests for proposals or other construction procurement documents), and in the draft Construction Contract Documents, when applicable.
10. Development communication plan for project: considering the use of door hangers, letters, public meetings, changeable message boards.
11. Furnish 6 review copies of the Preliminary Design Phase documents, opinion of probable Construction Cost, and any other Preliminary Design Phase deliverables to Owner by established due date, and review them with Owner. Owner shall submit to Engineer any comments regarding the furnished items.
12. Revise the Preliminary Design Phase documents, opinion of probable Construction Cost, and any other Preliminary Design Phase deliverables in response to Owner’s comments, as appropriate, and furnish to Owner 6 copies of the revised Preliminary Design Phase documents, revised opinion of probable Construction Cost, and any other deliverables by the specified due date.
13. Engineer’s services under the Preliminary Design Phase will be considered complete on the date when Engineer has delivered to Owner the revised Preliminary Design Phase documents, revised opinion of probable Construction Cost, and any other Preliminary Design Phase deliverables.
Final Plans When authorized by the CITY prepare final plans for the PROJECT based upon com- ments as agreed upon as a result of the office check review. Major items of work included in devel- opment of final plans are:
(a) Prepare engineering plans (which shall include construction sequencing and traffic con- trol), supplemental specifications, special provisions and construction cost estimates, or esti- mates of the quantities of work for the PROJECT.
