Title Commitment and Survey (a) Buyer has received and reviewed a copy of the Title Commitment and the Existing Survey. Buyer is solely responsible for obtaining any updated title commitments, surveys, or any other title related matters Buyer desires with respect to the Assets at Buyer’s sole cost and expense. Buyer shall have until not later than 5:00 p.m. Eastern Time on the date that is no later than ten (10) days prior to the end of the Due Diligence Period (the “Title Report Objection Date”), to notify Seller’s attorney in writing (the “Title Report Objection Notice”) as to any items shown on the Title Commitment (as updated if applicable) that Buyer believes are not Permitted Exceptions. Buyer’s failure to timely deliver the Title Report Objection Notice on or prior to the 5:00 p.m. Eastern Time on the Title Report Objection Date shall constitute Buyer’s irrevocable acceptance of the Title Commitment and Buyer shall be deemed to have unconditionally waived any right to object to any matters set forth therein. If Buyer timely delivers a Title Report Objection Notice, Seller shall have seven (7) days after receipt of such notice to notify Buyer (i) that Seller will remove or cause to be removed such objectionable exceptions from title on or before the Closing, in which case the provisions of subsection 8.3(b) shall apply; or (ii) that Seller elects not to cause such exceptions to be removed at which time Buyer may elect, prior to the end of the Due Diligence Period, to accept the Title in its current condition or terminate this Agreement in which event the Deposit shall be promptly delivered to Seller and the parties shall have no further obligations to each other except for those that expressly survive the termination of this Agreement. Nothing in this subsection shall require Seller, despite any election by Seller to attempt to discharge any title exceptions, to take or bring any action or proceeding or any other steps to remove any title exception or to expend any moneys therefor, other than with respect to the Pre-Effective Date Seller Encumbrances, Post Effective Date Monetary Encumbrances and Post Effective Date Seller Encumbrances (as hereinafter defined) pursuant to Section 8.3 of this Agreement.
Title Commitment (a) Purchaser has ordered a title insurance commitment with respect to the Real Property issued, by the Title Company (the “Title Commitment”). On or before July 25, 2013, Purchaser shall provide to Seller the Title Commitment, together with legible copies of the title exceptions listed thereon. On or before August 8, 2013 (the “Title Objection Date”), Purchaser shall notify Seller in writing, if there are (i) any monetary liens or other title exceptions that Purchaser objects to (“Title Objections”) or (ii) any Survey Objection. In the event Seller does not receive written notice of any Title Objections or Survey Objection by the Title Objection Date, TIME BEING OF THE ESSENCE, then Purchaser will be deemed to have accepted or waived such exceptions to title set forth on the Title Commitment as permitted exceptions (as accepted or waived by Purchaser, the “Permitted Exceptions”) and shall be deemed to have waived its right to object to any Survey Objection.
(b) After the Title Objection Date, if the Title Company raises any new exception to title to the Real Property, Purchaser’s counsel shall have five (5) Business Days after he or she receives notice of such exception (the “New Objection Date”) (or as promptly as possible prior to the Closing if such notice is received with less than five (5) Business Days prior to the Closing), to provide Seller with written notice if such exception constitutes a Title Objection. In the event Seller does not receive notice of such Title Objection by the New Objection Date, Purchaser will be deemed to have accepted the exceptions to title set forth on any updates to the Title Commitment as Permitted Exceptions.
(c) All taxes, water rates or charges, sewer rents and assessments, plus interest and penalties thereon, which on the Closing Date are liens against the Real Property and which Seller is obligated to pay and discharge will be credited against the Purchase Price (subject to the provision for apportionment of taxes, water rates and sewer rents herein contained) and shall not be deemed a Title Objection. If on the Closing Date there shall be security interests filed against the Real Property, such items shall not be Title Objections if (i) the personal property covered by such security interests are no longer in or on the Real Property, or (ii) such personal property is the property of a Tenant, and Seller executes and delivers an affidavit to such effect, or the security interest was filed more than five (5) year prior to the Closing Date and was not renewed.
(d) If on the Closing Date the Real Property shall be affected by any lien which, pursuant to the provisions of this Agreement, is required to be discharged or satisfied by Seller, Seller shall not be required to discharge or satisfy the same of record provided the money necessary to satisfy the lien is retained by the Title Company at Closing, and the Title Company either omits the lien as an exception from the title insurance commitment or insures against collection thereof from out of the Real Property, and a credit is given to Purchaser for the recording charges for a satisfaction or discharge of such lien.
(e) No franchise, transfer, inheritance, income, corporate or other tax open, levied or imposed against Seller or any former owner of the Property, that may be a lien against the Property on the Closing Date, shall be an objection to title if the Title Company insures against collection thereof from or out of the Real Property and/or the Improvements, and provided further that Seller deposits with the Title Company a sum of money or a parental guaranty reasonably acceptable to the Title Company and sufficient to secure a release of the Property from the lien thereof. If a search of title discloses judgments, bankruptcies, or other returns against other persons having names the same as or similar to that of Seller, Seller will deliver to Purchaser an affidavit stating that such judgments, bankruptcies or other returns do not apply to Seller, and such search results shall not be deemed Title Objections.
Title Commitments Prior to Closing, Seller shall cooperate with Buyer and use Commercially Reasonable Efforts to assist Buyer if Buyer desires to obtain American Land Title Association ("ALTA") title insurance commitments (collectively, the "Title Commitments," and each a "Title Commitment"), in final form, from one or more title insurance companies (collectively, the "Title Company"), committing the Title Company (subject only to the satisfaction of any industry standard requirements contained in the Title Commitment) to issue ALTA (or its local equivalent) form of title insurance policies in an amount acceptable to the Buyer and the Title Company insuring good, valid, indefeasible fee simple title to the Real Property in Buyer, in all cases, at Buyer's sole expense and in the respective amounts that Buyer requests prior to Closing, subject to no Encumbrances or other exceptions to title other than Permitted Encumbrances (collectively the "Title Policies"). On or prior to the Closing Date, Seller shall execute and deliver, or cause to be executed and delivered, to the Title Company, at no cost to Seller, any customary affidavits, standard gap indemnities, evidence of corporate existence and authority, and similar documents reasonably requested by the Title Company in connection with the issuance of the Title Commitments or the Title Policies; provided that such efforts and Buyer's request for Title Policies or Title Commitments shall, in no event, result in any delay in the consummation of the transactions contemplated by this Agreement, except to the extent caused by or resulting from Seller's breach of this Agreement; and provided further, that nothing in this Section 6.17 shall obligate Seller to execute or deliver any document that affects, in a manner adverse to Seller, Seller's liability to Buyer as expressed herein and in the Special Warranty Deed.
Preliminary Title Report (a) Not later than four (4) business days after the date of this Agreement, Seller, with Buyer's assistance and cooperation as necessary, shall arrange for the Title Company to prepare and deliver to Buyer a preliminary title report (the "Title Report") covering the Real Property dated not earlier than the date of this Agreement, such report showing all matters of record and all items which would be shown as exceptions on a ALTA owner's policy of title insurance, together with a recent ALTA survey of the Real Property certified by a licensed land surveyor and a legible copy of each recorded document underlying any exceptions shown in the Title Report. Subject only to the following permitted exceptions (the "Permitted Exceptions"), Seller shall cause all exceptions to title to the Real Property set forth in such Title Report to be removed prior to the Closing: (1) the standard printed exceptions contained in the Title Company's form of Owner's Policy; (2) building restrictions and zoning regulations heretofore or hereafter adopted by any municipal or other public authority relating to the Property; (3) current property taxes not yet delinquent; (4) the exceptions approved by Buyer in accordance with Section 5.13(b); and (5) any exception to which Buyer, in Buyer's sole discretion, specifically and expressly consents in writing prior to the Closing. Buyer shall pay all fees and costs associated with obtaining the Title Report.
(b) Buyer shall have until 5:00 p.m. (Los Angeles time) on the fifth (5th) calendar day following Buyer's receipt of the Title Report to disapprove, in Buyer's sole discretion, any matters set forth in the Title Report; provided, however, that Buyer may not disapprove of the exceptions described in items (1), (2) and (3) of Section 5.13(a). If Buyer timely disapproves of any matters set forth in the Title Report, other than with respect to the exceptions described in items (1), (2) and (3) of Section 5.13(a), Seller shall have three (3) business days to indicate in writing whether Seller will cause such disapproved matters to be removed as exceptions to title prior to or concurrently with the Closing. Seller's failure to timely respond shall be deemed to constitute Seller's irrevocable agreement to remove all such disapproved matters as exceptions to title. If Seller timely indicates that it is unwilling to remove any such disapproved matters as exceptions to title, Buyer may elect to (i) proceed with the transaction contemplated hereby and take title subject to such disapproved matters, or (ii) terminate this Agreement. Buyer's failure to make such election within three (3) business days after being informed of Seller's decision shall be deemed an election of option (i). If Buyer terminates this Agreement pursuant to this Section 5.13(b), the Deposit (and all interest accrued thereon) shall be returned to Buyer, and the parties shall have no further obligations to one another except for any obligations that, by their terms, survive the termination of this Agreement.
Title Objections On or before the expiration of the Inspection Period, herein defined, Purchaser, at Purchaser's expense, may obtain a title commitment issued by Escrow Agent, which shall provide a commitment to insure title to the Real Property on the full-coverage, standard, revised ALTA Owner's Policy of title insurance, Form B (the "Title Commitment") in the amount of the Purchase Price subject, however, to the Permitted Exceptions (to which Purchaser does not object), but without exception as to mechanics or similar liens, free and clear of any and all other mortgages, liens, judgments, leases, encumbrances, parties in possession, licenses, covenants, conditions, restrictions, easements, encroachments and any other matters of any nature affecting the title except as permitted in this Agreement. Within ten (10) days of receipt by Purchaser of the Title Commitment and the Survey, Purchaser shall advise Seller in writing of any objections to the Title Commitment (including any of the Permitted Exceptions) and the Survey and, if no objections are so submitted by Purchaser within the applicable time period, it shall be deemed that the Title Commitment and the Survey are satisfactory, and Purchaser has no objections thereto. If Purchaser does advise Seller in writing of any objections, Seller shall have ten (10) days after the receipt of such statement of objections in which to notify Purchaser as to whether it will cure or remove such objections, Seller having no obligation to do so. If Seller notifies Purchaser that it will not cure or remove such objections, or if Seller is deemed to have elected not to cure such objections, then within ten (10) days after the receipt by Purchaser of such notice from Seller, or upon expiration of such ten (10) day period, Purchaser shall elect to either (i) terminate this Agreement, whereupon this Agreement shall be of no further force and effect, the Xxxxxxx Money shall be returned to Purchaser, and no party hereto shall have any further rights, liabilities or obligations hereunder or (ii) waive such objections to Seller's title. Failure by Purchaser to elect either alternative within such ten (10) day period shall be deemed an election to waive such objections. If Seller sends no notice to Purchaser within said ten (10) days, Seller shall be deemed to have elected not to cure any such title objections.
Title Report If no Additional Mortgage Policy is required with respect to such Additional Mortgaged Property, a title report issued by the Title Company with respect thereto, dated not more than 30 days prior to the date such Additional Mortgage is to be recorded and satisfactory in form and substance to Administrative Agent;
Title Policy and Survey A. TITLE POLICY: Seller shall furnish to Buyer at Seller’s Buyer’s expense an owner policy of title insurance (Title Policy) issued by (Title Company) in the amount of the Sales Price, dated at or after closing, insuring Buyer against loss under the provisions of the Title Policy, subject to the promulgated exclusions (including existing building and zoning ordinances) and the following exceptions:
(1) Restrictive covenants common to the platted subdivision in which the Property is located.
(2) The standard printed exception for standby fees, taxes and assessments.
(3) Liens created as part of the financing described in Paragraph 3.
(4) Utility easements created by the dedication deed or plat of the subdivision in which the Property is located.
(5) Reservations or exceptions otherwise permitted by this contract or as may be approved by Xxxxx in writing.
(6) The standard printed exception as to marital rights.
(7) The standard printed exception as to waters, tidelands, beaches, streams, and related matters.
(8) The standard printed exception as to discrepancies, conflicts, shortages in area or boundary lines, encroachments or protrusions, or overlapping improvements:
(i) will not be amended or deleted from the title policy; or
(ii) will be amended to read, "shortages in area" at the expense of Buyer Seller.
(9) The exception or exclusion regarding minerals approved by the Texas Department of Insurance.
Title and Survey Matters 4.1 As soon as practicable after the Closing Date, Seller shall deliver to Purchaser a standard owner's policy of title insurance issued by the Title Insurer/Escrow Agent ("TITLE POLICY"). The Title Policy shall insure marketable title to the Property in the amount of the Purchase Price, free and clear of all liens, encumbrances and exceptions whatsoever, save and except only for those easements, restrictions and other matters of record affecting title to the Property which are Permitted Exceptions (as hereinafter defined).
4.2 Purchaser shall have until the end of the Due Diligence Period (as hereinafter defined) in which to review the title commitment and as-built survey to be delivered by Seller pursuant to Section 5.1, and to obtain any modifications, endorsements or other revisions to either the title commitment or the survey required by Purchaser, at Purchaser's cost. If Purchaser is unable to obtain any modification, endorsement or other revision to the title commitment or survey required by Purchaser, or if any items remain on the title commitment or survey which are not acceptable to Purchaser ("UNPERMITTED EXCEPTIONS"), then on or before the end of the Due Diligence Period, Purchaser shall so notify Seller (an "OBJECTION NOTICE"). Seller has a period of ten (10) days after the date of the Objection Notice in which Seller, using good faith efforts, shall attempt to remove such Unpermitted Matters or remedy same in a manner satisfactory to Purchaser in its sole and absolute discretion, or have the Title Insurer/Escrow Agent commit to insure against loss or damage that may be occasioned by such exceptions (in endorsements satisfactory to Purchaser). If Seller does not cure any Unpermitted Exceptions to Purchaser's satisfaction within such period, then Purchaser may either (a) terminate this Agreement by giving written notice to Seller of such termination not later than five (5) days following the end of the ten (10) day cure period, in which event the Xxxxxxx Money, and all interest earned thereon, shall be returned to Purchaser and neither party shall have any further obligations or liabilities hereunder or (b) accept such Unpermitted Exceptions. Any item not specified in the Objection Notice or subsequently accepted by Purchaser shall be a "PERMITTED EXCEPTION". Seller shall be obligated to remove prior to Closing all mortgages and other liens or encumbrances of a definite or ascertainable monetary amount, and if Seller fails to do so, Purchaser may elect to terminate this Agreement. At the Closing, and as a further condition of Purchaser's performance of its obligations hereunder, Seller shall cause the Title Insurer/Escrow Agent to deliver to Purchaser the Title Policy or a marked-up and signed commitment to deliver same.
Title Policy The Title Company shall be prepared to issue, upon payment of the title premium at its regular rates, a title policy in the amount of the Purchase Price, insuring title to the Property is vested in the Purchaser or its designee or assignee, subject only to the Permitted Exceptions, with such endorsements as shall be reasonably required by the Purchaser.
Preliminary Matters 3.1. At least five (5) days prior to the pre-construction meeting described in Section 3.2, Contractor shall submit to Consultant for Consultant’s review and acceptance:
3.1.1. A progress schedule in the indicated form: Bar Chart Modified Critical Path Method (“CPM”) CPM Computerized CPM (CPM is interpreted to be generally as outlined in the Association of General Contractors (“AGC”) publication, “The Use of CPM in Construction.”) The progress schedule shall indicate the start and completion dates of the various stages of the Work, and shall show an activity network for the planning and execution of the Work. Included with the progress schedule shall be a narrative description of the progress schedule. The progress schedule must be updated monthly by Contractor, submitted as part of each Application for Payment, and must be acceptable to Consultant.
3.1.2. A preliminary schedule of Shop Drawing submissions; and
3.1.3. In a lump sum contract or in a contract that includes lump sum bid items of Work, a preliminary schedule of values for all of the Work that includes quantities and prices of items aggregating the Contract Price and that subdivides the Work into component parts in sufficient detail to serve as the basis for progress payments during construction. Such prices will include a breakdown of labor, equipment, materials, and an appropriate amount of overhead and profit applicable to each item of Work, which amounts Contractor must confirm in writing at the time of submission. In addition, after award but prior to the submission of the progress schedule, Consultant, Contract Administrator, and Contractor shall meet with all utility owners and secure from them a schedule of utility relocation; provided, however, that neither Consultant nor Town shall be responsible for the nonperformance by the utility owners.
3.2. At a time specified by Consultant, but before Contractor starts the Work at the Project site, a conference attended by Contractor, Consultant, and others as deemed appropriate by Contract Administrator, will be held to discuss the schedules referred to in Section 3.1; to discuss procedures for handling Shop Drawings and other submittals and for processing Applications for Payment; and to establish a working understanding among the Parties as to the Work.
3.3. Within thirty-five (35) days from the Project Initiation Date set forth in the applicable Notice to Proceed, a conference attended by Contractor, Consultant, and others, as appropriate, will be held to finalize the schedules submitted in accordance with Section 3.1. Within forty-five
